2008-307D - Laserfiche WebLink

Home Browse Search

SC- 14 . 0413 Add the following new paragraph immediately after paragraph GC 14. 048: C . At the time of delivery of the tentative certificate of Substantial Completion , Engineer will deliver to Owner and Contractor a written recommendation as to division of responsibilities pending final payment between Owner and Contractor with respect to security, operation , safety, and protection of the Work , maintenance , heat, utilities , insurance , and warranties and guarantees SC -16 DISPUTE RESOLUTION SC -16 . 02 Mediation SC- 16 Add the following new paragraph immediately after paragraph GC- 16. 01 . SC- 16 . 02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims , disputes , or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties . The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed . SC -17 Miscellaneous Add the following new paragraphs immediately after paragraph GC17. 05: SC- 17 . 06 Liens A. This project is a " Public Works" under Chapter 255 , Florida Statutes . No merchant's liens may be filed against the OWNER . Any claimant may apply to the OWNER for a copy of this Contract . The claimant shall have a right of action against the CONTRACTOR for the amount due him . Such action shall not involve the OWNER in any expense . Claims against the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in Florida Statutes Section 255 . 05 . The CONTRACTOR shall insert the following paragraph in all subcontracts hereunder: " Notice : Claims for labor, materials and supplies - are not assessable against Indian River County and are subject to proper prior notice to (CONTRACTOR' S Name ) and to (CONTRACTOR Surety Company Name ) , pursuant to Chapter 255 of the Florida Statutes . This paragraph shall be inserted in every sub- subcontract hereunder. " The payment due under the Contract shall be paid by the OWNER to the CONTRACTOR only after the CONTRACTOR has furnished the OWNER with an affidavit stating that all persons , firms or corporations who are defined in Section 713 . 01 , Florida Statutes , who have furnished labor or materials , employed directly or indirectly in the Work , have been paid in full . The OWNER may rely on said affidavit at face value . The CONTRACTOR does hereby release , remiss and quit-claim any and all rights he may enjoy perfecting any lien or any other type of statutory common law or equitable lien against the job . + + END OF SUPPLEMENTARY CONDITIONS + + 00800-8 00800 - Supplementary Conditions REV 04-07 .doe 00800 8F:\Engineering\Special Projects\Eagle Trace Phase ZContract Documents\Eagle Trace Subdivision Phase 11\00800 - Supplementary Conditions REV 04-07.doc