2012-021A - Laserfiche WebLink

Home Browse Search

CONTRACTOR shall be allowed an extension of the Contract Times , directly attributable to any such suspension if CONTRACTOR makes a Claim for an extension as provided in paragraph 10 . 05 . CONTRACTOR shall not be allowed an adjustment of the Contract Price and CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other eco- nomic loss arising out of or resulting from such Work suspension . SC - 15 . 02 OWNER May Terminate For Cause SC - 15 . 02 . A . 5 and SC - 15 . 02 . A . 6 Add the following new paragraphs immediately after paragraph GC- 15. 02. A . 4 : 5 . CONTRACTOR ' s violation of Section 02225 — " Erosion Control and Treatment of Dewatering Water From the Construction Site . " 6 . CONTRACTOR ' s failure to make payment to Subcontractors or Suppliers for materials or labor in accordance with the respective agreements between the CONTRACTOR and the Subcontractors or Suppliers . SC - 15 . 04 CONTRACTOR May Stop Work or Terminate SC - 15 . 04 Delete the following text from the first sentence of paragraph GC- 15. 04 . A : er OWNER fails for 30 days to pay CONTRACTOR aRY SUM finally determined to be d6le , SC - 15 . 04 Delete the following text from the second sentence of paragraph GC- 15. 04 . A : er OWNER has failed feF 30 days to pay CONTRACTOR any sum f 0 R@lly determined te be SCA 6 DISPUTE RESOLUTION SC - 16 . 02 Mediation SC- 16 Add the following new paragraph immediately after paragraph GC46. 01 � SC- 16 . 02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims , disputes , or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties . The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed . SC - 17 Miscellaneous Add the following new paragraphs immediately after paragraph GC17005: SC - 17 . 06 Liens A . This project is a " Public Works " under Chapter 255 , Florida Statutes . No merchant ' s liens may be filed against the OWNER . Any claimant may apply to the OWNER for a copy of this Contract . The claimant shall have a right of action 00800-9 00800 - Supplementary Conditions 06-09 rev . doc 00800 9FAPublic Works\ FNGINEER ING DIVISION PROJECTS\ 1136-6th Ave SW_Culverl Replacement N of 23rd St SMAdmim\Contract Documents\00800 Supplementary Conditions 06-09 rev .doc