2010-265 - Laserfiche WebLink

Home Browse Search

CONTRACTOR shall be allowed an extension of the Contract Times , directly attributable to any such suspension if CONTRACTOR makes a Claim for an extension as provided in paragraph 10 . 05 . CONTRACTOR shall not be allowed an adjustment of the Contract Price and CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other eco- nomic loss arising out of or resulting from such Work suspension . SC - 15 . 02 OWNER May Terminate For Cause SC- 15 . 02 . A . 5 and SC - 15 . 02 . A . 6 Add the following new paragraphs immediately after paragraph GC- 15. 02. A . 4: 5 . CONTRACTOR 's violation of Section 02225 — " Erosion Control and Treatment of Dewatering Water From the Construction Site . " 6 . CONTRACTOR ' s failure to make payment to Subcontractors or Suppliers for materials or labor in accordance with the respective agreements between the CONTRACTOR and the Subcontractors or Suppliers . SC -15. 04 CONTRACTOR May Stop Work or Terminate SC- 15 . 04 Delete the following text from the first sentence of paragraph GC- 15. 04. A : OF OWNER fails foF 30 days te Pay GONTRACT-OR GIRY 661M fiRally detei:FniRed to be d6le , SC- 15 . 04 Delete the following text from the second sentence of paragraph GC- 15. 04. A : due-7 SC - 16 DISPUTE RESOLUTION SC - 16 . 02 Mediation SC- 16 Add the following new paragraph immediately after paragraph GC- 16. 01 . SC- 16 . 02 Mediation A . OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims , disputes , or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19`h Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties . The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed . SC - 17 Miscellaneous Add the following new paragraphs immediately after paragraph GC 17. 05: SC - 17 . 06 Liens A . This project is a " Public Works " under Chapter 255 , Florida Statutes . No merchant ' s liens may be filed against the OWNER . Any claimant may apply to the OWNER for a copy of this Contract . The claimant shall have a right of action 00800-9 00800 - supplementary Conditions 06-09 rev . doc 00800 9F :\Engineering\Capita1 Projects\0107-53rd St, 58th Ave-US # 1 \Contract Documents\00800 - Supplementary Conditions 06-09 rev.doc