2012-056A - Laserfiche WebLink

Home Browse Search

1 . changes in the Work which are : ( i ) The opposing party shall submit any response to ordered by OWNER pursuant to paragraph ENGINEER and the claimant within 30 days after 10 . 01 .A, ( ii ) required because of acceptance of receipt of the claimant's last submittal (unless defective Work under paragraph 13 . 08 .A or ENGINEER allows additional time ) . OWNER's correction of defective Work under paragraph 13 . 09 , or ( iii ) agreed to by the parties ; B . ENGINEER 's Decision: ENGINEER will render a formal decision in writing within 30 days after 2 , changes in the Contract Price or receipt of the last submittal of the claimant or the last Contract Times which are agreed to by the submittal of the opposing party, if any. ENGINEER's parties , including any undisputed sum or written decision on such Claim , dispute , or other amount of time for Work actually performed in matter will be final and binding upon OWNER and accordance with a Work Change Directive ; and CONTRACTOR unless : 3 , changes in the Contract Price or Contract Times which embody the substance of1 � an appeal from Eman Rin decision any written decision rendered by ENGINEER is taken within the time limits its and n accordance with the dispute resolution pursuant to paragraph 10 . 05 ; provided that, in procedures set forth in Article 16 ; or lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract 2 have such dispute resolution Documents and applicable Laws and Re ula- procedures e been set forth in Article 16 , a 9 written notice of intention to appeal from tions , but during any such appeal , ENGINEER's written decision is delivered by CONTRACTOR shall carry on the Work and OWNER or CONTRACTOR to the other and to adhere to the progress schedule as provided in ENGINEER within 30 days after the date of paragraph 6 . 18 .A, such decision , and a formal proceeding is instituted by the appealing party in a forum of 10 . 04 Notification to Surety competent jurisdiction within 60 days after the A . If notice of any change affectin the °neral date of such decision or within 60 days after 9 9 Substantial Completion , whichever is later scope of the Work or the provisions of the Contract Documents ( including , but not limited to , Contract (unless otherwise agreed in writing by OWNER and CONTRACTOR) , to exercise such rights or Price or Contract Times ) is required by the provisions of any Bond to be given to a sure the giving of an remedies as the appealing party may have with ty, g g y respect to such Claim , dispute , or other matter such notice will be CONTRACTOR's responsibility. in accordance with applicable Laws and The amount of each applicable Bond will be adjusted Regulations , to reflect the effect of any such change . 10 . 05 Claims and Disputes C . If ENGINEER does not render a formal decision in writing within the time stated in paragraph A. Notice: Written notice stating the general 10 . 05 . 6 , a decision denying the Claim in its entirety nature of each Claim , dispute , or other matter shall be shall be deemed to have been issued 31 days after delivered by the claimant to ENGINEER and the other receipt of the last submittal of the claimant or the last party to the Contract promptly (but in no event later submittal of the opposing party, if any. than 30 days ) after the start of the event giving rise thereto . Notice of the amount or extent of the Claim , D . No Claim for an adjustment in Contract Price dispute , or other matter with supporting data shall be or Contract Times (or Milestones ) will be valid if not delivered to the ENGINEER and the other party to the submitted in accordance with this paragraph 10 . 05 . Contract within 60 days after the start of such event ( unless ENGINEER allows additional time for claimant to submit additional or more accurate data in support ARTICLE 11 - COST OF THE WORK ; CASH of such Claim , dispute , or other matter) . A Claim for ALLOWANCES ; UNIT PRICE WORK an adjustment in Contract Price shall be prepared in accordance with the provisions of paragraph 12 . 01 . B0 A Claim for an adjustment in Contract Time shall be 11 . 01 Cost of the Work prepared in accordance with the provisions of paragraph 12 . 02 . 8 . Each Claim shall be accomA.- panied by claimant's written statement that the adjust- means the sum of allcostsco is necessard: The termililytinncuof rlre aond ment claimed is the entire adjustment to which the paid by CONTRACTOR in the proper performance of claimant believes it is entitled as a result of said event . the Work . When the value of any Work covered by a - 30 00700 - General Conditions REV 04-07.doc F :\Public Works\ENGINEERING DIVISION PROJECTS\98106-66th Ave Ph 2 4th St to 16th( 7St(\Adm m\bid documents\00700 - General Conditions REV 04-07 . doc