2012-227A - Laserfiche WebLink

Home Browse Search

§ 14.3.2 The Contract Sum and Contract Time shall be adjusted for increases in the cost and time caused by suspension, delay or interruption as described in Section 14. 3 . 1 . Adjustment of the Contract Sum shall include it profit. No' adjustment shall be made to the extent .1 that performance is, was or would have been so suspended, delayed or interrupted by another cause for which the Contractor is responsible; or .2 that an equitable adjustment is made or denied under another provision of the Contract. § 14.4 TERMINATION BY THE OWNER FOR CONVENIENCE § 14.4.1 The Owner may, at any time, terminate the Contract for the Owner' s convenience and without cause. § 14 41 Upon receipt of written notice from the Owner of such termination for the Owner' s convenience, the Contractor. shall .1DUNcease operations as directed by the Owner in the notice; .2 Aake actions necessary, or that the Owner may direct, for the protection and preservation of the Work; and .3 except ' for Work'- directed to be performed prior to the effective date of termination stated in the notice, terminate all existing subcontracts and purchase orders and enter into no further subcontracts and purchase orders. § 14.4.3 In case of such termination for the Owner' s convenience, the Contractor shall be entitled to receive payment for Work executed, and costs incurred by reason of such termination, along with reasonable overhead and profit on the Work not executed. ARTICLE 15 CLAIMS AND DISPUTES §15 1 CLAIMS § 15.1 ,1 DEFINITION A Claim is wdemand or assertion by one of the parties seeking, as a matter of right, payment of money, or other relief with ,respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question between the Owner and Contractor arising out of or relating to the Contract. The responsibility to substantiate Claims shall rest with the party making the Claim . § 15.1 .2 NOTICE OF CWMS Claims by either the Owner or Contractor.must be initiated by written notice to the other party and to the Initial Decision Maker with a `copy sent to the Architect; if the Architect is not serving as the Initial Decision Maker. Claims by either party must be mitiated within 21 days after occurrence of the event giving rise to such Claim or 13 within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. § 15 13 CONTINUING CONTRACT PERFNut- L ORMANCE 66 t6 6 Pending 56666 final resolution of a Claim; except as otherwise agreed in writing or as provided in Section 9. 7 and Article 14, the Contractor shall proceed 'dilgently with performance of the Contract and the Owner shall continue to make payments in accordance with -the Contract Documents. The Architect will prepare Change Orders and issue Certificates for Payment in accordance with the decisions of the Initial Decision Maker. § 15. 1 .4 CLAIMS FOR ADDITIONAL COST 66 If the Contractor wishes to make a Claim for an increase in the Contract Sum, written notice as provided herein shall 6 . 1 61 It be given before proceeding to execute the Work. Prior notice is not required for Claims relating to an emergency endangering life or property arising under Section 10.4 . § 15.1 .5 CLAIMS FOR ADDITIONAL TIME § 15. 1 .5.1 If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided 66 1 herein shall be, given. The Contractor' s Claim shall include an estimate of cost and of probable effect of delay on 1.6 ,6 Iprogress of the Work. In the case of a continuing delay, only one Claim is necessary. § 15.1 .5.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably anticipated and had an adverse effect on the scheduled construction. Init. AIA Document A201 TM . 2007. Copyright ® 1911 , 1915, 1918, 19259 1937, 1951 , 1958, 1961 , 1963, 1966, 1970, 1976, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING : This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized 3 reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 11 :28: 34 on 12/21 /2012 under Order No.4386727979 1 which expires on 02/05/2013, and is not for resale. User Notes : (811102566) i