2012-204A - Laserfiche WebLink

Home Browse Search

pursuant to paragraph 10. 05; provided that, in 10 . 05 Claims and Disputes lieu of executing any such Change Order, an appeal may be taken from any such decision in A. Notice: Written notice stating the general accordance with the provisions of the Contract nature of each Claim , dispute, or other matter shall be Documents and applicable Laws and Regula- delivered by the claimant to ENGINEER and the other tions, but during any such appeal , party to the Contract promptly ( but in no event later CONTRACTOR shall carry on the Work and than 30 days) after the start of the event giving rise adhere to the progress schedule as provided in thereto. Notice of the amount or extent of the Claim , paragraph 6. 18 .A. dispute, or other matter with supporting data shall be delivered to the ENGINEER and the other party to the 10 . 04 Notification to Surety Contract within 60 days after the start of such event (unless ENGINEER allows additional time for claimant A. If notice of any change affecting the general to submit additional or more accurate data in support scope of the Work or the provisions of the Contract of such Claim , dispute, or other matter) . A Claim for Documents (including , but not limited to, Contract an adjustment in Contract Price shall be prepared in Price or Contract Times) is required by the provisions accordance with the provisions of paragraph 12. 01 . 13. of any Bond to be given to a surety, the giving of any A Claim for an adjustment in Contract Time shall be such notice will be CONTRACTOR's responsibility. prepared in accordance with the provisions of The amount of each applicable Bond will be adjusted paragraph 12. 02. 6 . Each Claim shall be accom- to reflect the effect of any such change. panied by claimant's written statement that the adjust- ment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The opposing party shall submit any response to ENGINEER and the claimant within 30 days after receipt of the claimant's last submittal (unless ENGINEER allows additional time) . B . ENGINEER's Decision: ENGINEER will render a formal decision in writing within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any. ENGINEER's written decision on such Claim , dispute, or other matter will be final and binding upon OWNER . and CONTRACTOR unless: 1 . an appeal from ENGINEER's decision is taken within the time limits and in accordance with the dispute resolution procedures set forth in Article 16; or 26 if no such dispute resolution procedures have been set forth in Article 16, a written notice of intention to , appeal from ENGINEER's written decision is delivered by OWNER or CONTRACTOR to the other and to ENGINEER within 30 days after the date of such decision , and a formal proceeding is instituted by the appealing party in a forum of competent jurisdiction within 60 days after the date of such decision or within 60 days after Substantial Completion , whichever is later (unless otherwise agreed in writing by OWNER and CONTRACTOR) , to exercise such rights or remedies as the appealing party may have with respect to such Claim , dispute, or other matter in accordance with applicable Laws and Regulations. 00700 - General Conditions REV 0447.doc 00700 - 31 FAPublic Works\ENGINEERING DIVISION PROJECTSN 102-Old Dixie Hwy Swk 8th St to SR 60-LAMdmimlbid documentsUNaster Contract Dorwments100700 - General Conditions REV 04-07.doc