8/8/1979 - Laserfiche WebLink

Home Browse Search

AUG 81979 41 PnUF 361 1.3.11 The Architect's decision in matters relating to artistic effect shall be final if consistent with the intent of the Contract Documents. The Architect's decisions on any other claims, disputes or other matters, including those in question between the Owner and the Contractor, shall be subject to arbitration as provided in this Agreement and in the Contract Documents. 1.3.12 The Architect shall have authority to and shall reject work which does not conform to the Contract Documents. Whenever, in the Architect's reasonable opinion, it is necessary or advis- able for the implementation of the intent of the Contract Docu- ments, the Architect will have authority to require special inspection or testing of the work in accordance with the provisions of the Contract Documents, whether or not such work be then fabri- cated, installed or completed. 1.3.13 The Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for conformance with the design concept of the work and compliance with the Contract Documents. Such action shall be taken with reasonable promptness so as to cause no delay. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. 1.3.14 The Architect shall prepare Change Orders for the Owner's approval and execution in accordance with the Contract Documents, and shall have authority to order minor changes in the work not involving an adjustment in the Contract Sum or an extension of the Contract Time which are not inconsistent with the intent of the Contract Documents. 1.3.15 The Architect shall conduct inspections to determine the Dates of Substantial Completion and final completion as to each phase and the project as a whole and shall receive and forward to the Owner for the Owner's review written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall issue a final Certificate for Payment based on completed phases and the total payment. 1.3.16 The extent of the duties, responsibilities and limitations of authority of the Architect as the Owner's representative during construction shall not be modified or extended without written consent of the Owner, the Contractor and the Architect. 1.4 Additional Services: The following Services are not included in Basic Services. They shall be provided if authorized or confirmed in writing by the Owner, and they shall be paid for by the Owner as provided in this Agreement, in addition to the compensation for Basic Services. 1.4.1 Providing financial feasibility or other special studies. 1.4.2 Providing planning surveys, site evaluations, environmental studies or comparative studies of prospective sites, and preparing special surveys, studies and submissions required for approvals of governmental authorities or others having jurisdiction over the Project. 1.4.3 Providing services relative to future facilities, systems and equipment which are not intended to be constructed during the Construction Phase. 1.4.4 Preparing documents of alternate, separate or sequential bids or providing extra services in connection with bidding, negotiation or construction prior to the completion of the Construction Documents Phase, when requested by the Owner, except that both parties agree that the Scope of Professional Services - 4 - _ M