2013-000 (2) - Laserfiche WebLink

Home Browse Search

Insurance to do business in this state have been met. (b) In the case of the surety insurance company, in addition to the deduction for reinsurance,the amount assumed by any co-surety, the value of any security deposited, pledged or held subject to the consent of the surety and for the protection of the surety shall be deducted. GC 47 INSURANCE. 1. The Contractor shall maintain and pay for such insurance, issued in the name of the Owner and naming the Owner as an Additional Insured, with such coverages as will protect the Owner from contingent liability under the Contract, as set forth in the Special Conditions 2. Coverages. See Special Conditions. 3. The Certificate of Insurance and policy endorsements or riders shall name the County as "ADDITIONAL INSURED" with respect to all Liability coverages. Contractor shall provide evidence of continued coverage in the event of renewal or policy termination. Owner may withhold payment to Contractor until evidence of insurance coverage is received. 4.. These insurance requirements shall not in any manner limit or qualify the liabilities and obligations assumed by Contractor under the Contract. 5. The Contractor shall be entirely responsible for securing Certificates of Insurance coverage as set forth above from all subcontractors who are engaged in the work. GC 48 INDEMNITY. Contractor agrees to protect,defend, reimburse, indemnify and hold the Owner, its agents, employees and elected officers and each of them (collectively), free and harmless at all times from and against any and all claims, liability, expenses, losses, suits, costs, fines and damages, including attorney fees and costs, and causes of action of every kind and character against the Owner by reason of any damage to property or the environment, or bodily injury (including death) incurred or sustained by any party hereto, or of any party acquiring any interest hereunder, and any third or other party whomsoever, or any governmental agency, arising out of or incident to or in connection with Contractor's performance under this Contract, Contractor's acts, omissions or operations hereunder, the site conditions, or the performance, non-performance or purported performances of the Contractor or any breach of the terms of this Contract; to the extent caused by the negligence, recklessness, or intentional wrongful misconduct of Contractor and persons or entities employed or utilized by Contractor in its performance. (§725.06 F.S.) GC 49 DISPUTE RESOLUTION. Final Completion. Notwithstanding any other provision, the parties agree that any unresolved dispute regarding the punch list or any other requirement for Final Completion shall be mediated with the Engineer as the mediator. Waiver of Arbitration. The Owner and Contractor agree expressly waive any and all provisions regarding arbitration, including any and all provisions regarding arbitration as a condition precedent to litigation contained elsewhere in any Contract Documents. GC 50 OWNER'S RIGHT TO TERMINATE CONTRACT FOR CAUSE. If the Contractor should be adjudged bankrupt, or if he should make a general assignment for the benefit of his creditors, or if a receiver should be appointed on account of his insolvency, or if he should persistently or repeatedly refuse or should fail, except in cases for which extension of time is provided, to maintain an established schedule (30 days behind a critical path activity), to supply enough properly skilled workmen or proper materials; or if he should fail to make prompt payments to subcontractors or for material or labor or persistently disregard laws, ordinances or the instructions of the Engineer, or otherwise fails to conform to the Contract requirements or abandons or refuses to perform any work, Owner may without prejudice to any other right or remedy, and after giving the Contractor and its Surety seven (7)calendar days 43