2012-124A (2) - Laserfiche WebLink

Home Browse Search

6. CONTRACTOR's failure to make payment to Subcontractors or Suppliers for materials or labor in accordance with the respective agreements between the CONTRACTOR and the Subcontractors or Suppliers. SC-15.04 CONTRACTOR May Stop Work or Terminate SC-15.04 Delete the following text from the first sentence of paragraph GC-15.04.A: E)r OWNER fails fGr 30 days to pay CONTRACTOR any surn finally determined to be due� SC-15.04 Delete the following text from the second sentence of paragraph GC-15.04.A: er has failed for 30 days to pay CONTRACTOR any surn finally determined to be dUe; SC-16 DISPUTE RESOLUTION SC-16.02 Mediation SC-16 Add the following new paragraph immediately after paragraph GC-16.01. SCA 6.02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims, disputes, or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties. The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed. SC-17 Miscellaneous Add the following new paragraphs immediately after paragraph GC17.05: SC-17.06 Liens A. This project is a "Public Works" under Chapter 255, Florida Statutes. No merchant's liens may be filed against the OWNER. Any claimant may apply to the OWNER for a copy of this Contract. The claimant shall have a right of action against the CONTRACTOR for the amount due him. Such action shall not involve the OWNER in any expense. Claims against the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in Florida Statutes Section 255.05. The CONTRACTOR shall insert the following paragraph in all subcontracts hereunder: "Notice: Claims for labor, materials and supplies are not assessable against Indian River County and are subject to proper prior notice to (CONTRACTOR'S Name) and to (CONTRACTOR Surety Company Name) pursuant to Chapter 255 of the Florida Statutes This paragraph shall be inserted in every sub- subcontract hereunder." The payment due under the Contract shall be paid by the OWNER to the CONTRACTOR only after the CONTRACTOR has furnished the OWNER with an affidavit stating that all persons, firms or corporations who oosoo-s 00800-supplementary Conditions 06-09 rev.doc 00800 9F:\Public Works\ENGINEERING DIVISION PROJECTS\1210-Sandridge Driving Range Tee Renovation\Admim\bid documents\00800-Supplementary Conditions 06-09 rev.doc