|
of CONTRACTOR's intention to cover the same and er nor any surety for nr ernp!Gyee or anent of
<br /> ENGINEER has not acted with reasonable prompt- any of them-.
<br /> ness in response to such notice.
<br /> 13.06 Correction or Removal of Defective Work
<br /> 13.04 Uncovering Work
<br /> A. CONTRACTOR shall correct all defective
<br /> A. If any Work is covered contrary to the written Work, whether or not fabricated, installed, or
<br /> request of ENGINEER, it must, if requested by ENGI- completed,or, if the Work has been rejected by ENGI-
<br /> NEER, be uncovered for ENGINEER's observation NEER, remove it from the Project and replace it with
<br /> and replaced at CONTRACTOR's expense. Work that is not defective. CONTRACTOR shall pay
<br /> all Claims, costs, losses, and damages (including but
<br /> B. If ENGINEER considers it necessary or not limited to all fees and charges of engineers,
<br /> advisable that covered Work be observed by ENGI- architects, attorneys, and other professionals and all
<br /> NEER or inspected or tested by others, CONTRAC- court or arbitration or other dispute resolution costs)
<br /> TOR, at ENGINEER's request, shall uncover, expose, arising out of or relating to such correction or removal
<br /> or otherwise make available for observation, inspec- (including but not limited to all costs of repair or
<br /> tion, or testing as ENGINEER may require, that replacement of work of others).
<br /> portion of the Work in question, furnishing all neces-
<br /> sary labor, material, and equipment. If it is found that 13.07 Correction Period
<br /> such Work is defective, CONTRACTOR shall pay all
<br /> Claims, costs, losses, and damages(including but not A. if within ape Year after the .tate of Substantial
<br /> limited to all fees and charges of engineers, architects, Gompletion or SUGh lenger period of time may be
<br /> attorneys, and other professionals and all court or r Regulations or by the terms of
<br /> arbitration or other dispute resolution costs) arising out any applicable speGi ll guarantee Fequired by the
<br /> of or relating to such uncovering, exposure, observa- Contfast BeGUraents OF by a"813ifiG PrOViSiOn of the
<br /> tion, inspection, and testing, and of satisfactory ContFaGt DOGIAments, any VVOFk is found to be
<br /> replacement or reconstruction (including but not defeGti,ve or if the repair of any damages to the land
<br /> limited to all-costs of repair or replacement-of-work of - or-areas-made-available-fer-CONTRACTOR's h„-- -- -
<br /> others); and OWNER shall be entitled to an OWNER or pennittedpermitter, b„ Laws Regulations s
<br /> appropriate decrease in the Contract Price. If the Gontemplatert in paragraph 1! n is found to be
<br /> parties are unable to agree as to the amount thereof, defe Kali-promp , fithGUt^^St
<br /> OWNER may make a Claim therefor as provided in to OWNER and ffin aGG nrp with OW 1tier}
<br /> paragraph 10.05. If, however, such Work is not found instFUGtiORS: (0) repair si Bch defective land or yeas or
<br /> to be defective, CONTRACTOR shall be allowed an (ii) correct su^” ldef nti„e Work or, if the defective ;
<br /> increase in the Contract Price or an extension of the Werk has been rejected by OWNER, remove it from
<br /> Contract Times (or Milestones), or both, directly the-P-rejeGt-and-replace-i pith `^park that is not
<br /> attributable to such uncovering, exposure, riy-GerreGt-er-repair er
<br /> observation, inspection, testing, replacement, and remove and replace any damage to ether WOFk to the
<br /> reconstruction. If the parties are unable to agree as to er-lana OF -seas resulting there
<br /> the amount or extent thereof, CONTRACTOR may #Fera. If CONTRACTOR does not promptly comply
<br /> make a Claim therefor as provided in paragraph with the terms of such instructions, or in an
<br /> 10.05. emergency where delay would cause serious risk of
<br /> loss or damage, OWNER may have the defective
<br /> 13.05 OWNER May Stop the Work Work corrected or repaired or may have the rejected
<br /> Work removed and replaced, and all Claims, costs,
<br /> A. If the Work is-defective;or GONTRAGTOR losses, and damages (including but not limited to all
<br /> fails supply suffiGieRt skilled workers or suitable fees and charges of engineers, architects, attorneys,
<br /> materials OF equipment, or fails to peFfoFm the Wb*iA and other professionals and all court or arbitration or
<br /> ,SUGh� - I haat the completed Work,.,i 1 Gonform to other dispute resolution costs)arising out of or relating
<br /> the Gentll:aot Doo.—ments, OWNER May OFdeF CON to such correction or repair or such removal and
<br /> TRACTOR to step the Work, or any portion thereof, replacement (including but not limited to all costs of
<br /> repair or replacement of work of others)will be paid by
<br /> r
<br /> hOwevey��� isnr�ght of OWNER to stop the Work shall CONTRACTOR.
<br /> not give Fise to any duty on the paFt of OWNER to
<br /> exeFGise this right fpr the benefit of GONTRAGPD B "eGial r.r t nGes There a partici la
<br /> any Sub I item of equipment is planed in ngntinUO Us service
<br /> before Substantial Comp an of all the Werk
<br /> , thee
<br /> 00700-General Conditions REV 5-10-13
<br /> 00700-37
<br /> R Public Works\ENGINEERING DIVISION PROJECTS11213C IRC Shooting Range Hunter Eduction ClassroomMminlbid documentsWlaster Contract Documents100700-General
<br /> Conditions REV 5-10-13.doc
<br />
|