Laserfiche WebLink
CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other eco- <br />nomic loss arising out of or resulting from such Work suspension. <br />SC -15.02 OWNER May Terminate For Cause <br />SC -15.02.A.5 and SC -15.02.A.6 Add the following new paragraphs immediately after <br />paragraph GC -15.02.A.4: <br />5. CONTRACTOR's violation of Section 02225 — "Erosion Control and Treatment of <br />Dewatering Water From the Construction Site." <br />6. CONTRACTOR's failure to make payment to Subcontractors or Suppliers for <br />materials or labor in accordance with the respective agreements between the <br />CONTRACTOR and the Subcontractors or Suppliers. <br />SC -15.04 CONTRACTOR May Stop Work or Terminate <br />SC -15.04 Delete the following text from the first sentence of paragraph GC -15.04.A: <br />SC -15.04 Delete the following text from the second sentence of paragraph GC -15.04.A: <br />SCA 6 DISPUTE RESOLUTION <br />SC -16.02 Mediation <br />SC -16 Add the following new paragraph immediately after paragraph GC -16.01. <br />SC -16.02 Mediation <br />A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled <br />Claims or counterclaims, disputes, or other matters in question between them <br />arising out of or relating to the Contract Documents or the breach thereof, to <br />mediation by a certified mediator of the 191 Judicial Circuit in Indian River County <br />unless delay in initiating mediation would irrevocably prejudice one of the parties. <br />The mediator of any dispute submitted to mediation under this agreement shall not <br />serve as arbitrator of such dispute unless otherwise agreed. <br />SC -17 Miscellaneous <br />SC -17.06 Liens <br />Add the following new paragraphs immediately after paragraph GC 17.05: <br />SC -17.06 Liens <br />A. This project is a "Public Works" under Chapter 255, Florida Statutes. No <br />merchant's liens may be filed against the OWNER. Any claimant may apply to <br />the OWNER for a copy of this Contract. The claimant shall have a right of action <br />00800-10 <br />00800 - Supplementary Conditions 05-13 rev <br />00800 10F:\Public Works\ENGINEERING DIVISION PROJECTS\1715 Go -Line Bus Tum -Off (90th Avenue)\1-Adm1n\Bid Documents\Master Contract Documents\00800 - <br />Supplementary Conditions 05-13 rev.doc <br />