2018-202 - Laserfiche WebLink

Home Browse Search

Contract#IRL2018-13 Encumbrance#s GL01-1701($36,000)&GL01- 1895($25,000) contractor and supplier invoices to Recipient and proof of payment.For all approved expenses incurred on or after October 1,2018,Recipient shall be reimbursed for approved costs or the not-to-exceed sum of$61,000,whichever is less.The Council shall not withhold any retainage from this reimbursement.If necessary for audit purposes,Recipient shall provide additional supporting information as required to document invoices. (b) End of Council Fiscal Year Reporting.The Council's fiscal year ends on September 30.Irrespective of the invoicing frequency,the Council is required to account for all encumbered funds at that time.When authorized under the Agreement,submittal of an invoice as of September 30 satisfies this requirement.The invoice shall be submitted no later than October 30.If the Agreement does not authorize submittal of an invoice as of September 30,Recipient shall submit,prior to October 30,a description of the additional work on the Project completed between the last invoice and September 30,and an estimate of the additional amount due as of September 30 for such Work.If there have been no prior invoices,Recipient shall submit a description of the work completed on the Project through September 30 and a statement estimating the dollar value of that work as of September 30. (c) Final Invoice.The final invoice must be submitted no later than 45 days after the Completion Date;provided,however,that when the Completion Date corresponds with the end of the Council's fiscal year(September 30),the final invoice must be submitted no later than 30 days after the Completion Date.Final invoices that are submitted after the requisite date shall be subject to a penalty of 10 percent of the invoice.This penalty may be waived by the Council,in its sole judgment and discretion,upon a showing of special circumstances that prevent the timely submittal of the final invoice.Recipient must request approval for delayed submittal of the final invoice not later than ten(10)days prior to the due date and state the basis for the delay. (d) All invoices shall include the following information:(1)Council contract number;(2) Council encumbrance number;(3)Recipient's name and address(include remit address, if necessary);(4)Recipient's invoice number and date of invoice;(5)Council Project Manager;(6)Recipient's Project Manager;(7)supporting documentation as to cost and/or Project completion(as per the cost schedule and other requirements of the Statement of Work);(8)Progress Report(if required). Invoices that do not correspond with this paragraph shall be returned without action within twenty(20)business days of receipt,stating the basis for rejection. Payments shall be made within forty-five(45) days of receipt of an approved invoice. (e) Travel expenses. If the cost schedule for this Agreement includes a line item for travel expenses,travel expenses shall be drawn from the project budget and are not otherwise compensable. (0 Payments withheld.The Council may withhold or,on account of subsequently discovered evidence,nullify,in whole or in part,any payment to such an extent as may be necessary to protect the Council from loss as a result of:(1)defective work not remedied;(2)failure to maintain adequate progress in the Project;(3)any other material breach of this Agreement.Amounts withheld shall not be considered due and shall not be paid until the ground(s)for withholding payment have been remedied. (g) Annual budgetary limitation. For multi-fiscal year agreements,the Council must budget the amount of funds that will be expended during each fiscal year as accurately as Page 3