2019-118 - Laserfiche WebLink

Home Browse Search

EXHIBIT A In the event additional building solutions, expanded scope, or additional research be requested by the Owner, EDB Architects will provide them for additional cost at the following hourly rates: Principal Architect Level I CAD Manager Level II CAD Manager Administrator, Accounting Services of Engineering Consultants (if needed) — $165.00 per hr. $ 85.00 per hr. $ 75.00 per hr. $ 50.00 per hr. cost plus 15%. Any agreement to perform Additional Services must be in writing and signed by both parties prior to commencing any work on the Additional Services. E. Fee The Architect shall invoice for completed work plus reimbursable expenses as they are incurred. Invoicing may be in part or whole for each phase of services. Construction Documents Bidding/Permitting Construction Administration Total Fee $7,000.00 $500.00 $1,000.00 $8,500.00 Reimbursable Expenses $500.00 F. Reimbursable expenses Reimbursable expenses will be invoiced as incurred, include the following: Mileage at $ 0.58 per mile. In-house prints 24" X 36" at $ 2.50 each. Special postage or mailing: cost plus 15%. Photocopies @ $0.20 per shee.t CD of all permit documents as a pdf file $25.00. G. Invoicing Invoicing shall be every two weeks based on percentage of completion of deliverables. Payments due the Architect under this Agreement are payable 30 days from the date of the Architect's invoice. Amounts unpaid 30 days after the invoice shall bear interest at 1% per month. If payments due the Architect are not received within 45 days of the date of invoice, the Owner agrees to assume responsibility for the cost of any required collection services, including Architect's time, Attorney's fees, legal fees and court costs. The Architect and his Consultants shall not be required to perform any further work on the project and shall not be held liable for any subsequent associated delays or losses of any kind until outstanding amounts are fully satisfied or legally adjudicated.