2020-226B - Laserfiche WebLink

Home Browse Search

DISTRICT Melisa Diolosa Project Manager St. Johns River Water Management District 525 Community College Parkway, S.E. Palm Bay, Florida 32909-2213 Phone: 321-676-6622 Email: mdiolosa@sjrwmd.com Contract 435822 RECIPIENT Dwight Fulton Project Manager Indian River County 1801 27th Street, Building A Vero Beach, Florida 32960-3388 Phone: 772-226-1821 Email: dfiilton@ircgov.com (b) The District's Project Manager shall have sole responsibility for transmitting instructions, receiving information, and communicating District policies and decisions regarding all matters pertinent to performance of the Project. The District's Project Manager may issue a District Supplemental Instruction (USI) form, Attachment C, to authorize minor adjustments to the Project that are consistent with the purpose of the Project. Both parties must sign the DSI. A DSI may not be used to change the District cost -share or percentage, quantity, quality or the Completion Date of the Project, or to change or modify the Agreement. I. PROGRESS REPORTS AND PERFORMANCE MONITORING. (a) Progress Reports. Recipient shall provide to the District quarterly Project update/status reports as provided in the Statement of Work. Reports will provide detail on progress of the Project and outline any potential issues affecting completion or the overall schedule. Recipient shall use the District's Project Progress Report form, Attachment B. Recipient shall submit the Project Progress Reports to the District's Project Manager and District's Budget Analyst within 15 days after the closing date of each calendar quarter (March 31, June 30, September 30 and December 31). (b) Performance Monitoring. For as long as the Project is operational, the District shall have the right to inspect the operation of the Project during normal business hours upon reasonable prior notice. Recipient shall make available to the District any data that is requested pertaining to performance of the Project. 10. WAIVER. The delay or failure by the District to exercise or enforce any of its rights under this Contract shall not constitute or be deemed a waiver of the District's right thereafter to enforce those rights, nor shall any single or partial exercise of any such right preclude any other or further exercise thereof or the exercise of any other right. 11. FAILURE TO COMPLETE PROJECT (a) Should Recipient fail to complete the Project, Recipient shall refund to the District ail of the funds provided to Recipient pursuant to this Agreement. However, the District, in its sole judgment and discretion, may determine that Recipient has failed to complete the Project due to circumstances that are beyond Recipient's control, or due to a good faith determination that the Project is no longer environmentally or economically feasible. In such event, the District may excuse Recipient from the obligation to return funds provided hereunder. If the Project has not been completed within 30 days after the Completion Date, Recipient shall provide the District with notice regarding its intention as to completion of the Project. The parties shall discuss the status of the Project and may mutually agree to revise the time for Project completion or the scope of the Project. Failure to complete the Project within 90 days after the Completion Date shall be, deemed to constitute failure to complete the Project for the purposes of this provision. (b) in the event the Project constitutes a portion of the total functional project, this paragraph shall apply in the event the total functional project is not completed. In such event, the 90 -day timeframe provided herein shall commence upon the date scheduled for completion of the total functional project at the time of execution of this Agreement, unless extended by mutual IRE