2021-052B - Laserfiche WebLink

Home Browse Search

IRC -1505 OWNER may terminate this Contract if CONTRACTOR is found to have submitted a false certification as provided under section 287.135(5), Florida Statutes, been placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List,or been engaged in business operations in Cuba or Syria, as defined by section 287.135, Florida Statutes. OWNER may terminate this Contract if CONTRACTOR, including all wholly owned subsidiaries, majority-owned subsidiaries, and parent companies, that exist for the purpose of making profit, is found to have been placed on the Scrutinized Companies that Boycott Israel List or is engaged in a boycott of Israel as set forth in section 215.4725, Florida Statutes. SC -15.04 CONTRACTOR May Stop Work or Terminate SC -15.04 Delete the following text from the first sentence of paragraph GC -15.04.A: SC -15.04 Delete the following text from the second sentence of paragraph GC -15.04.A: SC -16 Dispute Resolution SC -16.02 Mediation SC -16 Add the following new paragraph immediately after paragraph GC -16.01. SC -16.02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims, disputes, or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating mediation would irrevocably prejudice one of the parties. The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed. SC -17 Miscellaneous SC -17.06 Liens Add the following new paragraphs immediately *after paragraph GC17.05: SC -17.06 Liens A. This project is a "Public Works" under Chapter 255, Florida Statutes. No merchant's liens may be filed against the OWNER. Any claimant may apply to the OWNER for a copy of this Contract. The claimant shall have a right of action against the CONTRACTOR for the amount due him. Such action shall not involve the OWNER in any expense. Claims against the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in Florida Statutes Section 255.05. The CONTRACTOR shall insert the following paragraph in Supplementary Conditions - 00800-12 FAPublic Works\ENGINEERING DIVISION PROJECTS\1505-66th Ave Widening_49th St to 69th St\1-Admin0d DocumentsWaster Contract Documents\DIV 0 5 Conditions of the Contract.docx