2021-069 - Laserfiche WebLink

Home Browse Search

Amounts unpaid 30 days after the invoice shall bear interest at 1.5% per month. If payments due the Architect are not received within 45 days of the date of invoice, the Owner agrees to assume responsibility for the cost of any required collection services, including Architect's time. Attorney's fees, legal fees and court costs. The Architect and his Consultants shall not be required to perform any further work on the project and shall not be held liable for any subsequent associated delays or losses of any kind until outstanding amounts are fully satisfied or legally adjudicated. H. General 1) As an instrument of service, all original documents remain the property of the Architect and may not be reproduced in any form or modified fashion, without the written consent of the Architect. 2) The Architect shall invoice every two weeks. Invoices will be based on completed work for the services defined in Article E plus any additional services and reimbursable expenses accumulated during that period. Note: Architect's Reimbursable Expenses are listed in Article F of this agreement. 3) If payments due the Architect are not received within 45 days of the date on the invoice, the Owner agrees to assume responsibility for the cost of all required collection services, legal fees, mediation or court costs, incurred in the interest of collecting these fees. 4) In the event of any delinquent or disputed invoices, the Owner agrees that the Architect and his Professional Consultants may cease all ongoing efforts on the project until the outstanding invoice is paid or legally adjudicated. 5) Disputes regarding this agreement shall be settled in the following order of precedence: Party to Party, Mediation, and Legal Adjudication. This agreement can be terminated by either party with (7) seven calendar days written notice. The Architect and his subcontractors shall be compensated for all work completed up to the date of termination notice, including any reimbursable expenses incurred to the date. 6) The Architect shall be compensated 6% as a fee for the cost of Additive Change Orders generated by the Owner during the Construction Phase. There shall be no deduction of the Architect's fee on Deductive Change Orders if the item(s) were originally designed into the project and approved by the Owner or contracted for construction by the General Contractor. 7) The Architect shall provide architectural services for the Project as described in this Agreement in a manner consistent with locally accepted standards for professional skill and care. 8) EDB maintains Professional Liability insurance. In recognition of the relative risks, rewards and benefits of the Project to both the Owner and EDB, the risks have been allocated such that the Owner agrees, to the fullest extent permitted by law, to limit the