2022-009 - Laserfiche WebLink

Home Browse Search

re"EreMM - - • SC -16 DISPUTE RESOLUTION SC -16.02 Mediation SC -16 Add the following new paragraph immediately after paragraph GC -16.01. SC -16.02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims, disputes, or other matters in question between them arising out of or relating to `he Contract Documents or the breach thereof, to mediation by a certified mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating mediation would irrevocably prejudice one of the parties. The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed. SC -17 Miscellaneous SC -17.06 Liens Add the following new paragraphs immediately after paragraph GC 17.05: SC -17.06 Liens A. This project is a "Public Works" under Chapter 255, Florida Statutes. No merchant's liens may be filed against the OWNER. Any claimant may apply to the OWNER for a copy of this Contract. The claimant shall have a right of action against the CONTRACTOR for the amount due him. Such action shall not involve the OWNER in any expense. Claims against the CONTRACTOR are subject to timely prior notica to the CONTRACTOR as specified in Florida Statutes Section 255.05. The CONTRACTOR shall insert the following paragraph in all subcontracts hereunder: "Notice: Claims for labor, materials and supplies are not assessable against Indian River Countv and are 3ubiect to proper prior notice to (CONTRACTOR'S Name) and to (CONTRACTOR Surety Company Name) pursuant to Chapter 255 of the Florida Statutes. This paragraph shall be inserted in every sub - subcontract hereunder." The payment due under the Contract shall be paid by the OWNER to the CONTRACTOR only after the CONTRACTOR has furnished the OWNER with an affidavit stating that all persons, firms or corporations who are defined in Section 713.C1, Florida Statutes, who have furnished labor or materials, employed directly or indirectly in the Work, have been paid in full. The OWNER may rely on said affidavit at face value. The CONTRACTOR does hereby release, remiss and quit -claim any and all rights he may enjoy perfecting any lien or any other type of statutory common law or equitable lien against the job. ++END OF SUPPLEMENTARY CONDITIONS++ 00800-11 00800 - Supplementary Conditions REV 10-18.doc 00800 11F \Public Works\ENGINEERING DIVISION PRO, ECTS\1638 6th Avenue US -1 to 21st Street Resurfacing (SCOP)\1-Admin\Bids\Bid Documents\Master Contract Documents\00800 -Supplementary Conditions REV 10-18.doc