Laserfiche WebLink
IRC -1639 <br />OWNER may terminate this Contract if CONTRACTOR, including all wholly owned <br />subsidiaries, majority-owned subsidiaries, and parent companies, that exist for the <br />purpose of making profit, is found to have been placed on the Scrutinized Companies that <br />Boycott Israel List or is engaged in a boycott of Israel as set forth in section 215.4725, <br />Florida Statutes. <br />SC -15.04 CONTRACTOR May Stop Work or Terminate <br />SC -15.04 Delete the following text from the first sentence of paragraph GC -15.04.A: <br />SC -15.04 Delete the following text from the second sentence of paragraph GC -15.04.A: <br />SC -16 Dispute Resolution <br />SC -16.02 Mediation <br />SC -16 Add the following new paragraph immediately after paragraph GC -16.01. <br />SC -16.02 Mediation <br />A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or <br />counterclaims, disputes, or other matters in question between them arising out of or <br />relating to the Contract Documents or the breach thereof, to mediation by a certified <br />mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating <br />mediation would irrevocably prejudice one of the parties. The mediator of any dispute <br />submitted to mediation under this agreement shall not serve as arbitrator of such dispute <br />unless otherwise agreed. <br />SC -17 Miscellaneous <br />SC -17.06 Liens <br />Add the following new paragraphs immediately after paragraph GC17.05: <br />SC -17.06 Liens <br />A. This project is a "Public Works" under Chapter 255, Florida Statutes. No merchant's liens <br />may be filed against the OWNER. Any claimant may apply to the OWNER for a copy of <br />this Contract. The claimant shall have a right of action against the CONTRACTOR for the <br />amount due him. Such action shall not involve the OWNER in any expense. Claims against <br />the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in <br />Florida Statutes Section 255.05. The CONTRACTOR shall insert the following paragraph in <br />all subcontracts hereunder: <br />"Notice: Claims for labor, materials and supplies are not assessable against Indian River <br />County and are subject to proper prior notice to (CONTRACTOR'S Name) and to <br />(CONTRACTOR Surety Company Name), pursuant to Chapter 255 of the Florida Statutes. <br />Supplementary Conditions - 00800-12 <br />F:\PublicWorks\ENGINEERING DIVISION PROJECTS\1639 69th Stree. 66th Avenue to US -1 Resurfacing (SCOP)\1-Admin\Bids\Bid Documents - Advertisement\DIV <br />0 3 Conditions of the Contract - 20211207.docx <br />