1999-245 - Laserfiche WebLink

Home Browse Search

41111111 performing additional work as contemplated by Article 7, or to fires, floods, labor disputes, epldemics, abnormal weather conditions or acts of God. Delays described in this paragraph shall not entitle the CONTRACTOR to any additional compensation. The sole remedy of the CONTRACTOR shall be an extension of time obtained in accordance with Article 12. 12,3 All time limits stated in the Contract Documents are of the essence of the Agreement. The provisions of this Article '12 shall not exclude recovery for damages (including but not limited to fees and charges of engineers, architects, attomeys and other professionals and court and arbitration costs) for delay by either pasty. W19 "MI Keli. Warranty and Guarantee - 13.1 CONTRACTOR warrants and guarantees to OWNER and ENGINEER that all Work will be in accordance with the Contract Documents and will not be defective. Prompt notice of all defects shall be given to CONTRACTOR. All deflective Work, whether or not in place, may be rejected, corrected or accepted as provided in this Article 13. Tests and inspections: 13.3 CONTRACTOR shall dive ENGINEER timely notice of readiness of the Work for all required inspections or tests. 13.1 The OWNER will retain and pay for an independent materials testing laboratory to accomplish certain tests. Time only testy to be provided by the OWNER shall be the inim tests for density and thickness of backfill, stabilized subgrade, base course and asphaltic concrete surfaces; Dearing value of stabilized subgrade; and Portland cement concrete cylinder tests. Subsequent tests required after the initial tests to verify compliance with the Contract Documents in areas falling the first test shall be paid for by the CONTRACTOR by back charge to subsequent applications for payment. Ail other tests required in the Contract Document shall be provided by the CONTRACTOR- The CONTRACTOR shall assume full responsibility therefor, pay all costs in connection therewith and furnish ENGINEER the required certificates of inspection, testing or approval, CONTRACTOR shall also be responsible for and shall pay all costs in connection with any inspection or testing required in connection with OWNER's or ENGINEER's acceptance of a Supplier of materials or equipment proposed to be incorporated in the Work, or of materials or equipment submitted for approval prior to CONTRACTOR', Mirrhn-ge ther€+nf fnr incorporation in the Work. 13.5 All Inspections, tests or approvals other than those required by laws or Regulations of any public, body having jurisdiction shall be performed by organizations acceptable to OWNER and CONTRACTOR for by ENGINEER if so specified). 13.6 If any Work (including the work of others) that is to be inspected, tested or approved is covered without written concurrence of ENGINEER, it must, if requested by ENGINEER, be uncovered for observation. Such uncovering shall be at CONTRACTOR's expense unless CONTRACTOR has given ENGINEER timely notice of CONTRACTOR's intention to cover the same and ENGINEER has not acted with reasonable promptness in response to such notice. GENERAL CONDITIONS SGC - 29