2.7 The COUNTY shall give prompt written notice to the CONSULTANT whenever the COUNTY
<br />observes or otherwise becomes aware of any development that affects the timing or delivery of the
<br />CONSULTANT's Services. If the CONSULTANT has been delayed in completing its Services through
<br />no fault or negligence of either the CONSULTANT or any sub -consultant, and, as a result will be unable
<br />to perform fully and satisfactorily under the provisions of this Agreement, then the CONSULTANT
<br />shall promptly notify the Project Manager. In the COUNTY's sole discretion, and upon the submission
<br />to the COUNTY of evidence of the causes of the delay, the Work Order shall be modified in writing as
<br />set forth in this Agreement, subject to the COUNTY'S rights to change, terminate, or stop any or all of
<br />the Services at any time in accordance with this Agreement.
<br />2.8 The CONSULTANT shall not be considered in default for a failure to perform if such failure arises
<br />out of causes reasonably beyond the CONSULTANT's control and through no fault or negligence of the
<br />CONSULTANT. The parties acknowledge that adverse weather conditions, acts of God, or other
<br />unforeseen circumstances of a similar nature such as epidemic or pandemic, may necessitate
<br />modifications to this Agreement. If such conditions and circumstances do in fact occur, then the COUNTY
<br />and CONSULTANT shall mutually agree, in writing, to the modifications to be made to this Agreement.
<br />3. RESPONSIBILITIES OF THE CONSULTANT
<br />3.1 The CONSULTANT agrees to perform all necessary Services in connection with the assigned
<br />Project(s) as set forth in the Work Orders and in this Agreement.
<br />3.2 The CONSULTANT will endeavor not to duplicate any previous work done on any Project. Before
<br />execution of a Work Order, the CONSULTANT shall consult with the COUNTY to clarify and define the
<br />COUNTY's requirements for the Project.
<br />3.3 The CONSULTANT agrees to complete the Project within the time frame specified in the Work
<br />Order.
<br />3.4 The CONSULTANT will maintain an adequate staff of qualified personnel.
<br />3.5 The CONSULTANT will comply with all present and future federal, state, and local laws,
<br />rules, regulations, policies, codes, and guidelines applicable to the Services performed under this
<br />Agreement.
<br />3.6 The CONSULTANT, as a part of the consideration hereof, does hereby covenant and agree
<br />that: (1) in connection with the furnishing of Services to the COUNTY hereunder, no person shall be
<br />excluded from participation in, denied the benefits of, or otherwise subjected to discrimination in
<br />regard to the services to be performed by CONSULTANT under this Agreement on the grounds of
<br />such person's race, color, creed, national origin, religion, physical disability, age, or sex; and (2) the
<br />CONSULTANT shall comply with all existing requirements concerning discrimination imposed by
<br />any and all applicable local, state, and federal rules, regulations, or guidelines; as such rules,
<br />regulations, or guidelines may be from time to time amended.
<br />3.7 The CONSULTANT shall during the entire term of this Agreement, procure and keep in full force,
<br />effect, and good standing any and all necessary licenses, registrations, certificates, permits, and any and
<br />all other authorizations as are required by local, state, or federal law, in order for the CONSULTANT to
<br />render its Services as described in this Agreement. The CONSULTANT shall also require all sub -
<br />consultants to comply by contract with the provisions of this section.
<br />3.8 The CONSULTANT will prepare all necessary sketches and completed application forms to
<br />accompany the COUrTTY's applications for any required federal, state, or local permits. The
<br />2023o62 Agreement - 3
<br />
|