1999-338A - Laserfiche WebLink

Home Browse Search

EI 11,8,2 CONTRACTOR's costs for unloading and handling on the site, labor, installation costs, overhead, profit and other expenses omtemplated for the allowances have been included in the Contract Price and nut in the allowances. No demand for additional payment on account of any thereof of any thereof will be valid. Prior to final payment, an appropriate Change Order will be issued as recommended by ENGINEER to reflect actual amounts due CON'T'RACTOR on account of Work covered by allowances, and tate Contract Price shall be correspondingly adjusted. Unit Price Work: 11:4 Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Pnce will be deemed to include for all Unit Price Work an amount equal to the sum of the established unit prices for each separately identified item of Unit Price Work tines the estimated quantity of each items as indicated in the Agreement. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by CONTRACTOR will be made by ENGINEER in accordance with paragraph 9,10 11,10 Each unit price will be deemed to include an amount considered by CONTRACTOR to be adequate to cover CONTRACTOR's overhead and profit for each separately identified item.. 11.11 Where the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and significantly from the estimated quantity of such item indicated in the Agreement and there is no corresponding adjustment with respect to any other items of Work and if CONTRACTOR believes that CONTRACTOR has incurred additional expense as a result thereof, CONTRACTOR may make a claim for an increase in the Contract Price in accordance with Article I 1 if the parties are unable to agree as to the amount of any suchutcrease, ARTICLE 12 - CHANGE OF CONTRACT TIM 12.1 The Contract Time may only be changed by a change order or a written amendment. any claim for an extension or shortening of the contract time shall be based on written notice delivered by the party making claim to the outer party and to ENGINEER promptly (but in no event later than thirty (30) days) after the occurrence of the event giving rise to the claire and stating the general nature of the claim. Notice of the extent of the claire with supporting data sha]I be delivered within sixty (60) days after such occurrence (unless ENGINEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time shall be determined by ENGINEER in accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree. No claim far an adjustment in the Contract Time will be valid if not submitted in accordance with the requirements of this paragraph 12, 1. 12.2 The Contract Time .viIi be extended in an amount equal to time lost due to delays beyond the control of CONTRACTOR if a claim is made therefor as provided in paragraph 12.1. Such delays shall include, but not be limited to, acts or neglect by OWNER or others performing additional work as contemplated by Article 7, or to fires, f7ouds, labor disputes, epidemics, abnormal weather conditions 6,, or acts of God. Delays described in this paragraph shall not entitle the CONTRACTOR to any additional compensation. The sole remedy of the CONTRACTOR shall be an extension of time obtained in accordance with Article 12. lr GENERAL CONDITIONS L GC — 26 fid