2000-017 - Laserfiche WebLink

Home Browse Search

40 • 2.6.3.2 "file issuance of a (:ertificale for payment shall not be a representation that the Architect has (t) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work, (2) reviewed construction means, methods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the Owner to substantiate the Contractor's right to payment, or (4) ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. 2.6.3.3 'rhe Architect shall maintain a record of the Contractor's Applications for payment. 2.6.4 SUBMITTALS 2.6.4.1 The Architect shJll review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Produce Dala and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract DOC Unlents,'rhe Architect's action shall be taken with such reasonable promptness as to cause no delay in the Work or in the activities of the Owner, Contractor or separate contractors, while allowing sufficient time in the Architect's professional judgment to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Contractor as required by the Contract Documents. The Architect's review shall not constitute approval of safety precautions or, unless otherwise specifically stated by the Architect, of any construction means, methods, techniques, sequences or procedures. "rhe Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. 2.6.4.2 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in accordance with the requirements of the Contract Documents. 2.6.4.3 If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of the Contractor by the Contract Documents, the Architect shall specify appropriate performance and design criteria that such services must satisfy. Shop Drawings and other submittals related to the Work designed or certified by the design professional retained by the Contractor shall bear such professional's written approval when submitted to the Architect. The Architect shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals. 2.6.5 CHANGES IN THE WORK 11 A 1'1 r1 h 11 a t't ter,teC;luistrlu=lillli••�+h�+�-'��F��' + 2.6.5.1 he AF�hitl may PPF" a`bulien in a6GHrcianse wilft the (vonlFasl laosunw tae-Fain,,,,,-�„i,a}�;gs-i}}.}h�F1F-nH6-FlHwivurt; "dFu-edlul.ttaboi-qtr-s<rtut�ab4-a1:::':-::r- C�EleFifiiE/rT-Hf-iile•�inlFBEi'-I-1tN2iwfMEh�rf EenSitikCriH":it:1-{he-ltllent'Hf-th+''��(�T'''"�' hall pFepere, FepFc�du aux} 4eo,4 pr;av{cl I rte-,,, ''ayagFRP p G de9eri4+e-Wd � O O�.Q�.�0 AIL:u:l1FL © s 2.6.5.2 " ' 4)1',07 A I A V 4&i! e =_"Stang, S_i444h °-'W'',Wk -•3t 't3<^�' Ys -"'I! :. - t .,�.••�..,. hall he, AIA DOCUMENT 8141.1997 1 I 5"r ANDARD -C• I @T4F?3l l}a Si6ltiiw .Fc} tuc kis- s -Fe _arrH+ai«µ-Ileier F**ieie=i:%:r �it�^ SERVICES li"''""�--tr..iu:raa4i€;i-?t;-f. •' reperetit+a-ef-addilic»mFdra+wi+>gs*'e-»t'e''' The American institute of Architects • See Attachment 'El'. 1 I 1735 i4aw York Avenue, N.W. Washinut..n, D.C. 20006-5292 WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.