2000-222 - Laserfiche WebLink

Home Browse Search

111111111 • Paragraph 4.3. 4.3.2 Time Limits an Claims. Claims by either party shall must be initiated within 21 days ancr occurrence of the event giving rise to such Claim or within 21 days after the claimant First recognizes the condition giving rise to the Claim, wllichcvcr is litter. Claims shall must be initiated by written notice to the Architect and the other party. 4.3.3 Continuing Contract Performance. Pending final resolution of a Claim except as otherwise agreed in writing, or as provided in Subparagraph 9.7.1 and Article 14. the Contractor shall proceed diligently with performance of the Contract and the Ohvner shall continue to [Hake payments in accordance with ilia Contract Documents, 4.3.4 Claims for Concealed or Unknown Conditions. If conditions are encountered at the site which are (i) subsurface or otherwise concealed physical conditions which differ materially from those indicated in ilia Contract Documents or (2) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of Ilia character provided for in the Contract Documents, then notice by the observing party shall be given to the other party promptly before conditions are disturbed and in no evens later than 21 days alter first observance of the conditions. The Architect swill promptly investigate such conditions and, if they differ materially and cause an increase or decrease in the Contractor's cost of, or time required for, performance of any part of the Work, will recommend an equitable adjustment in the Contrast Sum or Contract Time. or both. If the Architwi-determines-that-the conditions at the site arc not materially differcin from those indicated in the Contract Documents and that no change in the terms of the Contract is justified, the Architect shall so notify lite Owner and Contractor in writing, stating the reasons. Claims by either party in opposition to such fin�detormination must be made within 21 days after ilia Architect has given notice of the f -dim .deeision: If the conditions encountered arc materially different, the Contract Sunt and Contract Time ,,Ball be equitably adjusted, but if the Owner and Contractor cannot agree that the conditions are matcria9kv different or cannot age on an adjustment in the Contract Swim or Contract Time.. tine matter shall be adjust am slhall-be-referred-to the-A.rehitest-fvr-ilriW determination; subject to further proceedings pursuant to Paragraph 4.4. 4.3.5 Claims for Additional Cost. If the Contractor wishes to make Claim for an increase in the Contract Sum, written notice as provided herein shall be given before proceeding to execute Ilia Work. Such notice shall include to the extent then known h Contractor, full details and substantjatjng datato_rmt evaluation l_yI the Owner and the Architect. If further, or other, information su ucntly nres known to the Contractor, it slla�ll be PMO -M { fumislled to the Owner and the Architect in writing, Prior notice is not required for Claims relating to an emergency endangering life or property arising under Paragraph 10.6. 4,3.6 If ilia Contractor believes additional cost is involved for masons including but not lirniced to (1) a wriilen interpretation from the Architect, (2) an order by the Owner 10 stop the Work where The Contractor was net at ]atilt, (3) a written order for a minor change in the Work issued by the Architect. (4) failure of payment by the Owner, (5) termination or the Contract by the Owner, (6) Owner's suspension or (7) other reasonable grounds, Claim shall be filed in accordance with this Paragraph 4.3, Iailurc to lilt any such laims in accordance with this Paragraph 4.3 shall constitute a Ivaiver ihcroof. 4.3.7 Claims for Additional Time 4.3.7.1 if the Contractor wishes to make Claim for on increase in the Contract Time, written notice as provided herein shall be given- The Contractor's Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In Ilia case of a continuing delay only one Claim is necessary. 4.3.7,2 if adverse weather conditions are the basis rot a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were seasonally abnormal at the 1'roiccl sile_for the period of time, could not have beett reasonably anticipated and had an adverse effect on ilia scheduled Lonstnaclion. 4.3.8 Injury or Damage to Person or Property. If either party to the Contract suffers injury or damage to person or property because of an act or omission of the other party, or of others for whose acts such party is legally responsible, written notice of such injury or damage, whether or not insured, shall be, given to the 11rc1titect a ld- the tyllier party within a reasonable time not exceeding 21 days after discovery, The notice shall provide sufficient detail to enable- the other party to investigate the matter. Atli I)tlC:l Ihn:N7' A2fa1 �[IICPniRAI . l'r3Nnl l'U MNS Ci}"t7 n; L'U\ I'kAC` S- VOR C aN;Si't I V VIl IN - 1997 V .I l I lh VN •AIA - COPYRIGHT YRnit tT 1'I'a7 .'tit HE AWRICAN INtrrt7i17'n SIF ARCIRIT.C71'a, 1735 NEW YORK AVl•:NLn: N.W.. WANHINrITON, D.l, 21usl6-5272. WARNINtVIhtltrvtaut F4iolma,rvirg v'u+Maur 1r:S. LvIpyaijou lawn andwill whjW* illu violatur to ILVp%Pna AXAUXI Wx "vi"l was v^h "mi-Ily rro(lo W %khh PvTutiaviLat utfliv AMA and vwl 1 r 1n.wNwd uwidwt vivlatim wdil die data of ev iti trot) au nolo i ttihxv. litcthrontc Formal A201-1997 User I)ocunlcnl7 VENO -- 7/11/21M. AIA Licensc Number 1041100, which expires on 11111211111 -- Riga all]