2000-236 - Laserfiche WebLink

Home Browse Search

40 410 12.1 The Contact Time may only be changed by a change order or a written amendment. any claim for an extension or shortening of the contract time shall be based on written notice delivered by the party making claim to the other party and to ENGINEER promptly (but in no event later than thirty (30) days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within sixty (60) days after such occurrence (unless ENGINEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to bclieve it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time shall be determined by ENGINEER in accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree. No claim for an adjustment in the Contract Time will be valid if not submitted in accordance with the requirements of this paragraph 12.1. 12.2 The Contract Time will be extended in an amount equal to time lost due to delays beyond the control of CONTRACTOR if a claim is made therefor as provided in paragraph 12.1. Such delays shall include, but not be limited to, acts or neglect by OWNER or others performing additional work as contemplated by Article 7, or to fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God. Belays described in this paragraph shall not entitle the CONTRACTOR to any additional compensation. The sole remedy of the CONTRACTOR shall be an extension of time obtained in accordance with Article 12. 12.3 All time limits stated in the Contract Documents are of the essence of the Agreement. The provisions of this Article 12 shall not exclude recovery for damages (including but not limited to fees and charges of engineers, architects, attorneys and other professionals and court and arbitration costs) for delay by either party. AH11 ME 11 - WARRANTY AND GUARANIM; REMOVAL OR ACC nF,FT7,- W[l� Warranty and Guarantee: 13.1 CONTRACTOR warrants and guarantees to OWNER and ENGINEER that all Work will be in accordance with the Contract Documents and will not be defective. Prompt notice of all defects shall be given to CONTRACTOR. All defective Work, whether or not in place, may be rejected, corrected or accepted as provided in this Article 13. Tests and Inspections: 13.3 CONTRACTOR shall give ENGINEER timely notice of readiness of the Work for all required inspections or tests. 13.4 The OWNER will retain and pay for an independent materials testing laboratory to accomplish certain tests. The only tests to be provided by the OWNER shall be the initial tests for density and thickness of backfill, stabilized subgrade, base course and asphaltic concrete surfaces; bearing value of stabilized subgrade; and Portland cement concrete cylinder tests. Subsequent tests required after the initial tests to verify compliance with the Contract Documents in areas failing the first test shall be paid for by the CONTRACTOR by back charge to subsequent applications for payment. All other tests required in the Contract Document shall be provided by the CONTRACTOR. The CONTRACTOR shall assume full responsibility therefor, pay all costs in connection therewith and furnish ENGINEER the required certificates of inspection, testing or approval, CONTRACTOR shall also be responsible for and shall pay all costs in connection with any inspection or testing required in connection with OWNER's or ENGINEER's acceptance of Supplier of materials or equipment proposed to be incorporated in the Work, or of materials or equipment submitted for approval prior to CONTRACTOR's purchase thereof for incorporation in the Work. GENERAL CONDITIONS Ge -26