|
13.04 Uncovering Work
<br />A. If any Work is covered contrary to the written
<br />request of ENGINEER, it must, if requested by ENGI-
<br />NEER, be uncovered for ENGINEER's observation
<br />and replaced at CONTRACTOR's expense.
<br />B. If ENGINEER considers it necessary or
<br />advisable that covered Work be observed by ENGI-
<br />NEER or inspected or tested by others, CONTRAC-
<br />TOR, at ENGINEER's request, shall uncover, expose,
<br />or otherwise make available for observation, inspec-
<br />tion, or testing as ENGINEER may require, that portion
<br />of the Work in question, furnishing all necessary labor,
<br />material, and equipment. If it is found that such Work
<br />is defective, CONTRACTOR shall pay all Claims,
<br />costs, losses, and damages (including but not limited
<br />to all fees and charges of engineers, architects,
<br />attorneys, and other professionals and all court or
<br />arbitration or other dispute resolution costs) arising out
<br />of or relating to such uncovering, exposure, observa-
<br />tion, inspection, and testing, and of satisfactory
<br />replacement or reconstruction (including but not limited
<br />to all costs of repair or replacement of work of others);
<br />and OWNER shall be entitled to an appropriate
<br />decrease in the Contract Price. If the parties are
<br />unable to agree as to the amount thereof, OWNER
<br />may make a Claim therefor as provided in paragraph
<br />10.05. If, however, such Work is not found to be
<br />defective, CONTRACTOR shall be allowed an
<br />increase in the Contract Price or an extension of the
<br />Contract Times (or Milestones), or both, directly
<br />attributable to such uncovering, exposure,
<br />observation, inspection, testing, replacement, and
<br />reconstruction. If the parties are unable to agree as to
<br />the amount or extent thereof, CONTRACTOR may
<br />make a Claim therefor as provided in paragraph 10.05.
<br />13.05 OWNER May Stop the Work
<br />13.06 Correction or Removal of Defective Work
<br />A. CONTRACTOR shall correct all defective
<br />Work, whether or not fabricated, installed, or
<br />completed, or, if the Work has been rejected by ENGI-
<br />NEER, remove it from the Project and replace it with
<br />Work that is not defective. CONTRACTOR shall pay
<br />all Claims, costs, losses, and damages (including but
<br />not limited to all fees and charges of engineers,
<br />architects, attorneys, and other professionals and all
<br />court or arbitration or other dispute resolution costs)
<br />arising out of or relating to such correction or removal
<br />(including but not limited to all costs of repair or
<br />replacement of work of others).
<br />13.07 Correction Period
<br />A
<br />CONTRACTOR does not promptly comply with the
<br />terms of such instructions, or in an emergency where
<br />delay would cause serious risk of loss or damage,
<br />OWNER may have the defective Work corrected or
<br />repaired or may have the rejected Work removed and
<br />replaced, and all Claims, costs, losses, and damages
<br />(including but not limited to all fees and charges of
<br />engineers, architects, attorneys, and other
<br />professionals and all court or arbitration or other
<br />dispute resolution costs) arising out of or relating to
<br />such correction or repair or such removal and replace-
<br />ment (including but not limited to all costs of repair or
<br />replacement of work of others) will be paid by
<br />CONTRACTOR.
<br />B.
<br />eadiel: date Of GG PF9Yided 'R the Spedfieati9RG OF b
<br />C. Where defective Work (and damage to other
<br />Work resulting therefrom) has been corrected or
<br />General Conditions - 00700 - 30
<br />
|