Laserfiche WebLink
771 <br />10M r, <br />Unit Price Work: <br />1 11.9 Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, <br />initially the Contract Price will be deemed to include for all Unit Price Work an amount equal <br />to the sum of the established unit prices for each separately identified item of Unit Price Work <br />times the estimated quantity of each items as indicated in the Agreement. The estimated <br />quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of <br />comparison of Bids and determining an initial Contract Price. Determinations of the actual <br />quantities and classifications ofUnit Price Work performed by CONTRACTOR will be made <br />by ENGINEER in accordance with paragraph 9.10 <br />11.10 Each unit price will be deemed to include an amount considered by CONTRACTOR to be <br />adequate to cover CONTRACTOR's overhead and profit for each separately identified item. <br />11.11 Where the quantity of any item of Unit Price Work performed by CONTRACTOR differs <br />materially and significantly from the estimated quantity of such item indicated in the <br />Agreement and there is no corresponding adjustment with respect to any other items of Work <br />and if CONTRACTOR believes that CONTRACTOR has incurred additional expense as a <br />result thereof, CONTRACTOR may make a claim for an increase in the Contract Price in <br />accordance with Article 11 if the parties are unable to agree as to the amount of any such <br />increase. <br />i <br />` ARTICLE 12 - CHANGE OF CONTRACT TIME <br />f <br />12.1 The Contract Time may only be changed by a change order or a written amendment. any <br />claim for an extension or shortening of the contract time shall be based on written notice <br />delivered by the party making claim to the other party and to ENGINEER promptly (but in <br />no event later than thirty (30) days) after the occurrence of the event giving rise to the claim <br />and stating thegeneral nature of the claim. Notice of the extent of the claim with supporting <br />data shall be delivered within sixty (60) days after such occurrence (unless ENGINEER <br />allows an additional period of time to ascertain more accurate data in support of the claim) <br />and shall be accompanied by the claimant's written statement that the adjustment claimed is <br />the entire adjustment to which the claimant has reason to believe it is entitled as a result of <br />the occurrence of said event. All claims for adjustment in the Contract Time shall be <br />determined by ENGINEER in accordance with paragraph 9.11 if OWNER and <br />CONTRACTOR cannot otherwise agree. No claim for an adjustment in the Contract Time <br />will be valid if not submitted in accordance with the requirements of this paragraph 12.1. <br />12.2 The Contract Time will be extended in an amount equal to time lost due to delays beyond the <br />control of CONTRACTOR if a claim is made therefor as provided in paragraph 12.1. Such <br />delays shall include, but not be limited to, acts or neglect by OWNER or others performing <br />additional work as contemplated by Article 7, or to fires, floods, labor disputes, <br />` epidemics, abnormal weather conditions or acts of God. Delays described in this paragraph <br />shall not entitle the CONTRACTOR to any additional compensation. The sole remedy of the <br />GENERAL CONDITIONS <br />GC31 <br />