|
allows additional time for claimant to submit additional or more agreed to in writing by OWNER, such costs shall be in amounts
<br /> accurate data in support of such Claim, dispute, or other no higher than those prevailing in the locality
<br />of the Project, shall
<br /> matter). A Claim for an adjustment in Contract Price shall be include only the following items, and shall not include any
<br /> of the
<br /> prepared in accordance with the provisions of paragraph costs itemized in paragraph 11 .01 . B .
<br /> 12. 01 . B . A Claim for an adjustment in Contract Time shall be
<br /> prepared in accordance with the provisions of paragraph 1 . Payroll costs for employees in the direct employ
<br /> 12.02. 13 . Each Claim shall be accompanied by claimant's of CONTRACTOR in the performance of the
<br /> Work
<br /> ' written statement that the adjustment claimed is the entire under schedules of job classifications agreed
<br /> upon by
<br /> adjustment to which the claimant believes it is entitled as a OWNER and CONTRACTOR. Such employees shall
<br /> result of said event. The opposing party shall submit any include without limitation superintendents , foremen, and
<br /> response to ENGINEER and the claimant within 30 days after other personnel employed full time at the Site. Payroll
<br /> receipt of the claimant's last submittal (unless ENGINEER costs for employees not employed full time on the Work
<br /> allows additional time). shall be apportioned on the basis of their time spent on
<br /> the Work. Payroll costs shall include, but not be limited
<br /> B. ENGINEER's Decision: ENGINEER will render a to, salaries and wages plus the cost of fringe benefits ,
<br /> ' formal decision in writing within 30 days after receipt of the last which shall include social security contributions
<br />, unem-
<br /> submittal of the claimant or the last submittal of the opposing ployment, excise, and payroll taxes, workers'
<br /> party, if any. ENGINEER's written decision on such Claim, compensation, health and retirement benefits , bonuses,
<br /> dispute, or other matter will be final and binding upon OWNER sick leave, vacation and holiday pay applicable thereto.
<br /> ' and CONTRACTOR unless: The expenses of performing Work outside of regular
<br /> working hours , on Saturday, Sunday, or legal holidays ,
<br /> 1 . an appeal from ENGINEER's decision is taken shall be included in the above to the extent authorized
<br /> within the time limits and in accordance with the dispute by OWNER.
<br /> resolution procedures set forth in Article 16; or
<br /> ' 2. Cost of all materials and equipment furnished
<br /> 2. if no such dispute resolution procedures have and incorporated in the Work, including costs of
<br /> been set forth in Article 16, a written notice of intention transportation and storage thereof, and Suppliers' field
<br /> to appeal from ENGINEER's written decision is services required in connection therewith. All cash
<br /> delivered by OWNER or CONTRACTOR to the other discounts shall accrue to CONTRACTOR unless
<br /> and to ENGINEER within 30 days after the date of such OWNER deposits funds with CONTRACTOR with
<br /> decision, and a formal proceeding is instituted by the which to make payments , in which case
<br /> the cash
<br /> appealing party in a forum of competent jurisdiction discounts shall accrue to OWNER. All trade discounts,
<br /> within 60 days after the date of such decision or within rebates and refunds and returns from sale of surplus
<br /> 60 days after Substantial Completion, whichever is later materials and equipment shall accrue to OWNER, and
<br /> (unless otherwise agreed in writing by OWNER and CONTRACTOR shall make provisions so that they may
<br /> CONTRACTOR), to exercise such rights or remedies as be obtained.
<br /> ' the appealing party may have with respect to such
<br /> Claim, dispute, or other matter in accordance with 3. Payments made by CONTRACTOR to
<br /> applicable Laws and Regulations. Subcontractors for Work performed by Subcontractors.
<br /> If required by OWNER, CONTRACTOR shall obtain
<br /> ' C. If ENGINEER does not render a formal decision in competitive bids from subcontractors acceptable
<br /> to
<br /> writing within the time stated in paragraph 10.05. 13 , a decision OWNER and CONTRACTOR and shall deliver such
<br /> denying the Claim in its entirety shall be deemed to have been bids to OWNER, who will then determine, with
<br /> the
<br /> issued 31 days after receipt of the last submittal of the claimant advice of ENGINEER, which bids, if any,
<br /> will be
<br /> or the last submittal of the opposing party, if any. acceptable. If any subcontract provides that the
<br /> Subcontractor is to be paid on the basis of Cost of the
<br /> D. No Claim for an adjustment in Contract Price or Work plus a fee, the Subcontractor's Cost of the
<br /> Work
<br /> Contract Times (or Milestones) will be valid if not submitted in and fee shall be determined in the same
<br /> manner as
<br /> ' accordance with this paragraph 10. 05. CONTRACTOR's Cost of the Work and fee as provided
<br /> in this paragraph 11 .01 .
<br /> ARTICLE 11 - COST OF THE WORK; CASH ALLOWANCES ; 4. Costs of special consultants (including but not
<br /> UNIT PRICE WORK limited to engineers , architects , testing laboratories,
<br /> surveyors , attorneys , and accountants ) employed for
<br /> 11 . 01 Cost of the Work services specifically related to the Work.
<br /> A. Costs Included: The term Cost of the Work means 5. Supplemental costs including the following :
<br /> the sum of all costs necessarily incurred and paid by CON- a. The proportion of necessary transportation ,
<br /> TRACTOR in the proper performance of the Work. When the travel , and subsistence expenses of CONTRACTOR's
<br /> value of any Work covered by a Change Order or when a Claim employees incurred in discharge of duties connected
<br /> for an adjustment in Contract Price is determined on the basis with the Work.
<br /> of Cost of the Work, the costs to be reimbursed to
<br /> CONTRACTOR will be only those additional or incremental b. Cost, including transportation and maintenance,
<br /> costs required because of the change in the Work or because of of all materials , supplies , equipment, machinery,
<br /> ' the event giving rise to the Claim. Except as otherwise may be appliances , office, and temporary facilities at
<br /> the Site,
<br /> 00700 . 25
<br />
|