Laserfiche WebLink
right of OWNER to stop the Work shall not give rise to any duty on the part of <br /> OWNER to exercise this right for the benefit of CONTRACTOR , any <br /> Subcontractor, any Supplier, any other individual or entity, or any surety for, or <br /> employee or agent of any of them . <br /> 14 . 02 Progress Payments <br /> SC- 14 . 02 . 13 . 5 . Delete paragraph GC- 14. 02. B. 5. d in its entirety and insert the following paragraph <br /> in its place: <br /> d . ENGINEER has actual knowledge of the occurrence of any of the events <br /> enumerated in paragraph 15 . 02 . A; or <br /> SC- 14 . 02 . 13 . 5 . Add the following sentences at the end of paragraph GC- 14. 02. 8. 5: <br /> .I. <br /> e . OWNER has been required to pay ENGINEER or ENGINEER's Consultant <br /> additional compensation because of CONTRACTOR delays or rejection of <br /> defective Work; or <br /> f. OWNER has been required to pay an independent testing laboratory for <br /> subsequent inspections , tests , or approvals taken after initial failing <br /> inspections , tests , or approvals . <br /> .. SC- 14 . 02 . C . 1 . Delete paragraph GC- 14. 02. C. 1 in its entirety and insert the following <br /> paragraph in its place : <br /> C . Payment Becomes Due <br /> 1 . Payment shall be made by OWNER to CONTRACTOR according to the Florida <br /> Prompt Payment Act. <br /> SC -16 DISPUTE RESOLUTION <br /> .. SC -16 . 02 Mediation <br /> SC- 16 Add the following new paragraph immediately after paragraph GC- 16. 01 . <br /> r <br /> SC- 16 . 02 Mediation <br /> A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled <br /> Claims or counterclaims , disputes , or other matters in question between them <br /> arising out of or relating to the Contract Documents or the breach thereof, to <br /> mediation by a certified mediator of the 19th Judicial Circuit in Indian River County <br /> unless delay in initiating arbitration would irrevocably prejudice one of the parties . <br /> The mediator of any dispute submitted to mediation under this agreement shall not <br /> serve as arbitrator of such dispute unless otherwise agreed . <br /> SC -17 Miscellaneous <br /> •• Add the following new paragraphs immediately after paragraph GC 17. 05: <br /> SC- 17 . 06 Liens <br /> A. This project is a " Public Works " under Chapter 255 , Florida Statutes . No <br /> 0016-00800 - Supplementary Conditions <br /> 008008 <br /> FAEngineering\Capital Projects\0016 & 0236- 41st Street Improvements\0016 & 4236-41st St Contract Docs\0016-00800 - SupplementaryConditions.doc Rev. 05/01 <br />