2006-417-2of2 - Laserfiche WebLink

Home Browse Search

graph 10.05 ; provided that, in lieu of executing any the dispute resolution procedures set forth in Article such Change Order, an appeal may be taken from 16; or any such decision in accordance with the provisions of the Contract Documents and applicable Laws and 2. if no such dispute resolution procedures Regulations, but during any such appeal, have been set forth in Article 16, a written notice of CONTRACTOR shall carry on the Work and adhere intention to appeal from ENGINEER's written to the progress schedule as provided in paragraph decision is delivered by OWNER or CONTRAC- 6. 18.A. TOR to the other and to ENGINEER within 30 days after the date of such decision, and a formal 10.04 Notification to Surety proceeding is instituted by the appealing party in a forum of competent jurisdiction within 60 days after A. If notice of any change affecting the general scope the date of such decision or within 60 days after of the Work or the provisions of the Contract Documents Substantial Completion, whichever is later (unless (including, but not limited to, Contract Price or Contract otherwise agreed in writing by OWNER and Times) is required by the provisions of any Bond to be CONTRACTOR), to exercise such rights or given to a surety, the giving of any such notice will be remedies as the appealing party may have with CONTRACTOR's responsibility. The amount of each respect to such Claim, dispute, or other matter in applicable Bond will be adjusted to reflect the effect of any accordance with applicable Laws and Regulations. such change. C. If ENGINEER does not render a formal decision 10.05 Claims and Disputes in writing within the time stated in paragraph 10.05 .11, a decision denying the Claim in its entirety shall be deemed to A. Notice: Written notice stating the general nature have been issued 31 days after receipt of the last submittal of each Claim, dispute, or other matter shall be delivered by of the claimant or the last submittal of the opposing party, the claimant to ENGINEER and the other party to the if any. Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. Notice of the D. No Claim for an adjustment in Contract Price or amount or extent of the Claim, dispute, or other matter with Contract Times (or Milestones) will be valid if not supporting data shall be delivered to the ENGINEER and submitted in accordance with this paragraph 10.05 . the other party to the Contract within 60 days after the start of such event (unless ENGINEER allows additional time for claimant to submit additional or more accurate data in ARTICLE 11 - COST OF THE WORK; CASH support of such Claim, dispute, or other matter). A Claim ALLOWANCES; UNIT PRICE WORK for an adjustment in Contract Price shall be prepared in accordance with the provisions of paragraph 12.01 .B. A Claim for an adjustment in Contract Time shall be prepared 11 . 01 Cost of the Work in accordance with the provisions of paragraph 12.02.B. Each Claim shall be accompanied by claimant's written A. Costs Included: The term Cost of the Work means statement that the adjustment claimed is the entire the sum of all costs necessarily incurred and paid by CON- adjustment to which the claimant believes it is entitled as a TRACTOR in the proper performance of the Work. When result of said event. The opposing party shall submit any the value of any Work covered by a Change Order or when response to ENGINEER and the claimant within 30 days a Claim for an adjustment in Contract Price is determined after receipt of the claimant's last submittal (unless on the basis of Cost of the Work, the costs to be reimbursed ENGINEER allows additional time). to CONTRACTOR will be only those additional or incremental costs required because of the change in the B. ENGINEER 's Decision: ENGINEER will render Work or because of the event giving rise to the Claim. a formal decision in writing within 30 days after receipt of Except as otherwise may be agreed to in writing by the last submittal of the claimant or the last submittal of the OWNER, such costs shall be in amounts no higher than opposing party, if any. ENGINEER's written decision on those prevailing in the locality of the Project, shall include such Claim, dispute, or other matter will be final and only the following items, and shall not include any of the binding upon OWNER and CONTRACTOR unless: costs itemized in paragraph 11 .01 .13. 1 . an appeal from ENGINEER's decision is 1 . Payroll costs for employees in the direct taken within the time limits and in accordance with employ of CONTRACTOR in the performance of the Work under schedules of job classifications 00700 - 32