The URL can be used to link to this page

Home My WebLink About2008-260AIndian River County Purchasing Division 1800 27th Street Vero Beach, FL 32960 Phone (772) 567-8000 Ext. 1986 Fax (772) 770-5095 ADDENDUM NO. 1 Date. June 12, 2008 Y S MIL NO RE WOM Project Name: I" Road from 35th Avenue to 32"d Avenue & 10th Court SW from Oslo Road (9th Street SW) to 7th Street SW Bid Number: 2008062 Bid Opening Date: Friday, July 11, 2008 at 2:00 p.m. TO ALL PROSPECTIVE BIDDERS: TO PROSPECTIVE BIDDERS AND OTHERS CONCERNED; This ADDENDUM is intended to clarify, correct, or change the Bidding Requirements of the Contract Documents. Therefore, it hereby supercedes anything to the contrary in the Bidding Requirements or contract Documents. This ADDENDUM is hereby made a part of and shall be attached to the subject Bidding Requirements and Contract Documents. The Bid Opening date Wednesday, July 11, 2008 at 2:00 pm is hereby amended to Friday, July 11, 2008 at 2:00 pm. All questions about the meaning or intent of the Bidding Documents are to be submitted to ENGINEER in writing. Interpretations or clarifications considered necessary by ENGINEER in response to such questions will be issued by Addenda mailed or delivered to all parties through the Issuing Office as having received the Bidding Documents. Questions received less than five days prior to the date for opening of Bids may not be answered. Only questions answered by Addenda will be binding. Oral and other interpretations or clarifications will be without legal effect. Addenda may be issued to clarify, correct, or change the Bidding Documents as deemed advisable by OWNER or ENGINEER. 1 TABLE OF CONTENTS Title Em - ARTICLE 1 - DEFINITIONS AND TERMINOLOGY., ...... I..", .......... 6 ...... 11.11,011.111, .... be.* ....... all ............ I ................ 0 ........ 5 1.01 Defined Terms...................................................................................................................................5 1.02 Terminology. ........ I I I . . 6 . . I I I I I . . . I . 0 0 . . 6*9'..00 . . a a a 0 . . . . 6 0 . . . . . . . . . . . . . . . . . . . I I . I . I . I . . . 1 17 ARTICLE2 - PRELIMINARY MATTERS..................... ......................................a..........................................................8 2.01 Delivery of Bonds..............................................................................................................................8 2.02 Copies of Documents........................................................................................................................8 2.03 Commencement of Contract rimes, Notice to Proceed.....,.,.. .... boo..@ .... ......... 8 2.04 Starting the Work. .... 10.111, a,* 0 oleo,, pg. sea 11 1.1...008 2.05 Before Starting Construcfion.............................................................................................................8 2.06 Preconstruction Conference.,,..","..,,,. lose .... 6 0006.9b..0 110,066. 0* ... 1111.1119 2.07 Initial Acceptance of Schedules........................................................................................................9 ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE... 11.9 3.01 Intent... ..... ........ Deep*,.* a& Pa." 1&.0 be best 0 as**@....9 3.02 Reference Standards........................................................................................................................10 3.03 Reporting and Resolving Discrepancies...........................................................................................10 3.04 Amending and Supplementing Contract Documents.......................................................................10 3.05 Reuse of Documents., I I I I I I I I I I . I I I I I I I I I I I . I . I I I I . a 0 0 a w w . . . 0 0 0 0 0 b I I I I . . I I I I I . 0 1 a a w 0 . p w . o & . . 0 t a I . I I I I I . . . . I I I I 1 1 4 . I . I I I . . . 0.10 ARTICLE 4 - AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS....................................................................................................................................................11 . 4.01 Availability of Lands.....,..."..",.. boo** ..a* a Poo #N06,81D, 1.111PI1.1.11 ... Israeli 4.02 Subsurface and Physical Conditions................................................................................................11 4.03 Differing Subsurface or Physical Conditions. ......... .............. -stereos,, ... a .........1111. "allow.11 4.04 Underground Facilities......................................................................................................................12 4.05 Reference Points..............................................................................a................................................13 4.06 Hazardous Environmental Condition at Site.....................................................................................13 ARTICLE 5 - BONDS AND INSURANCE,, I 1.. 0 ",a* 11 1 of go a@* P.*S111114 I I I IV I'll Messrs. re.*8690 ...... 1.11, 1#.b.botol 4 5.01 Performance, Payment, and Other Bonds'..., 1... 10 1,, 0 be Beer, I 1 0 "1** ... 11,11".."111014 5.02 Licensed Sureties and Insurers........................................................................................................15 5.03 Certificates of Insurance...................................................................................................................15 5.04 CONTRACTOR'S Liability Insurance................................................................................................15 s Liability Insurance. 5.05 OWNER' 5.06 Property Insurance...*.,',,,, I*",*, a Bobo BOB*%.@**, @***$Dome go,.* Does, 0.6.06 0 pass%,*, I 5.07 Waiver of Rights................................................................................................................................17 5.08 Receipt and Application of Insurance Proceeds.,,,. we ... ....... 1118 5.09 Acceptance of Bonds and Insurance, Option to Replace.". 101.11,11. age&., see a t000..0.18 5.10 Partial Utilization, Acknowledgment of Property Insurer,.",. a a or. be 0 . . . . 2 . . . . . . . . . . D a . . . . . . . 18 ARTICLE 6 be CONTRACTOR'S RESPONSIBILITIES.................................................................................................18 6.01 Supervision and Superintendence....................................................................................................18 6.02 Labor, Working Hours.......................................................................................................................18 6.03 Services, Materials, and Equipment..................a..............................................................................19 6.04 Progress Schedule............................................................................................................................19 6.05 Substitutes and "Or-Equals"..............................................................................................................19 6.07 Patent Fees and Royalties................................................................................................................21 00700 we General Conditions 00700-2 FAEngM6 ecr ctition Paving\0522 ist Rd from 32nd Ave. to 35th Ave\Bid Documents\00700 . General Condidons.doc 6.08 Permits ..... .... .......... ........... .................. ....... ........................................................................................22 6.09 Laws and Regulations.......................................................................................................................22 6.10 Taxes.................................................................................................................................................22 6.11 Use of Site and Other Areas.............................................................................................................22 6.13 Safety and Protection........................................................................................................................23 6.14 Safety Representative.......................................................................................................................23 6.15 Hazard Communication Programs....................................................................................................24 6.16 Emergencies.., ....... 0111.1 ..... ....... 1.1111.0.1 ............... oo..g.6 ............ ...... ................. *0000.6..V.024 6.17 Shop Drawings and Samples............................................................................................................24 6.18 Continuing the Work..........................................................................................................................25 6.19 CONTRACTOR'S General Warranty and Guarantee, ... a.. a.. a ....... 10,11.1 ... .... 0.1101'..25 6.20 Indemnification..................................................................................................................................25 ARTICLE7 - OTHER WORK........................................................................................................................................26 7.01 Related Work at Site.........................................................................................................................26 7.02 Coordination......................................................................................................................................27 ARTICLE 8 - OWNER'S RESPONSIBILITIES... ............ I'll ........... ................ .... 0 a a ....... , ..... 27 8.01 Communications to Contractor,,.,.,.. ... "I'll" ....... "..1.1 ...... I ................................................................ 127 8.02 Replacement of ENGINEER.............................................................................................................27 8.03 Fumish Data......................................................................................................................................27 8.04 Pay Promptly When Due...................................................................................................................27 8.05 Lands and Easements, Reports and Tests......................................................................................27 8.06 Insurance...........................................................................................................................................27 8.07 Change Orders,,,.,,... ... 'ease 0 . . . . a 0 0 0 0 0 4 0 . . . . . . . . . 04 . . . . . . . . . . . . . . . . . . . . . . 0 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . & a 0 b . a a a 6 427 8.08 Inspections, Tests, and Approvals....................................................................................................27 8.09 Limitations on OWNER'S Responsibilities........................................................................................27 8.10 Undisclosed Hazardous Environmental Condition...........................................................................28 8.11 Evidence of Financial Arrangements................................................................................................28 ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION.............................................................................28 9.01 OWNER'S Representative................................................................................................................28 9.02 Visits to Site.......................................................................................................................................28 9.03 Project Representative......................................................................................................................28 9.04 Clarifications and/nte►pretations.......................................................................................................28 9.05 Authorized Variations in Work,,..,", ..... I ................ ............... ........................... 0 .... 28 9.06 Rejecting Defective Work..................................................................................................................29 9.07 Shop Drawings, Change Orders and Payments..............................................................................29 9.09 Decisions on Requirements of Contract Documents and Acceptability of Work. 9.10 Limitations on ENGINEER's Authority and Responsibilities" ARTICLE 10, -CHANGES IN THE WORK; CLAIMS..,, I I . . I ... I .... W a 0 6 a . 1 6 . a 0 & # 0 1 1 . I I I . I I . . . 4 0 0 0 6 a a 0 0 . 0 . 2 0 . I I I I I 1 0 . 0 1 1 . 9 0 % 6 a 6 & 0 6 0 0 a 0 0 0 1 1 1 1 1 . I . 130 10.01 Authorized Changes in the Work....................................................................................................30 10.02 Unauthorized Changes in the Work................................................................................................30 10.03 Execution of Change Orders.. ... I 1 1. 1 1 1 1 ... logo 0 0 0 . & 9 . I . . . . I I I I . . I I 1 6 6 . . a & 0 a 6 . . I . I 1 0 a a 0 6 6 a a a a a I . . . . . . . . . . . . . . . 30 10.04 Notification to Surety.,,, ........... ............ ......30 .................... 10.05 Claims and Disputes.......................................................................................................................31 ARTICLE 11 - COST OF THE WORK; CASH ALLOWANCES; UNIT PRICE WORK..,, ..... 11111..*1131 11.01 Cost of the Work..............................................................................................................................31 11.02 Cash Allowances.............................................................................................................................33 11.03 Unit Price Work,..,..,,,,, .... ............... ................................................................... 33 ARTICLE 12 - CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES..............................................34 00700 - General Conditions 00700-3 FAEngineeting\Petition Paving\0522 1 st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 12.01 Change of Contract Price................................................................................................................34 12.02 Change of Contract Times..............................................................................................................35 12.03 Delays Beyond CONTRACTOR's Control......................................................................................35 12.04 Delays Within CONTRACTOR's Control... I I I . . . a., . . . . .35 12.06 Delay Damages... I b Is.. I I . . . . . . 0*0 . 0.00.609.1 1,.", mass am a.. 6.1 . . . . . . . . . . . . 9 . 1 0 a . a . 0 1 1 . . . . . I I 1 0 . . . . I am". . .1.190.35 ARTICLE 13 - TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVEWORK..................................................................................................................................35 13.01 Notice of Defects.."..... I'll, 6 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . so . . . 0 6 . . . & .0 0 . . . . . . . 6 . . . . . . . . . . 35 13.02 Access to Work...............................................................................................................................35 13.03 Tests and Inspections.....................................................................................................................35 13.04 Uncovering Work. ............................................................................................................................36 13.05 OWNER May Stop the Works., . I I I I 1 0 1 1 1 . I . 6 . I I I I . I . I p I I ................ ........... I'll ..... 1111199.36 13.06 Correction or Removal of Defective Work......................................................................................37 13.07 Correction Period............................................................................................................................37 13.08 Acceptance of Defective Work........................................................................................................37 13.09 OWNER May Correct Defective Work............................................................................................37 ARTICLE 14 - PAYMENTS TO CONTRACTOR AND COMPLETION.......................................................................38 14.01 Schedule of Values.........................................................................................................................38 14.02 Progress Payments.,'.......".. ... Soo& 0 ,'so 090.1 &be., &@boo 11.0.038 14.03 CONTRACTOR's Wan'anty of Trt1e................................................................................................40 14.04 Substantial Completion...................................................................................................................41 14.05 Partial Utilization..............................................................................................................................41 14.06 Final Inspection...............................................................................................................................42 14.07 Final Payment.................................................................................................................................42 14.09 Waiver of Claims.............................................................................................................................43 ARTICLE 15 - SUSPENSION OF WORK AND TERMINATION.................................................................................43 15.01 OWNER May Suspend Work..................................................................................:......................43 15.02 OWNER May Terminate for Cause................................................................................................43 15.03 OWNER May Terminate For Convenience....................................................................................43 15.04 CONTRACTOR May Stop Work or Terminate...............................................................................44 ARTICLE16 - DISPUTE RESOLUTION......................................................................................................................44 16.01 Methods and Procedures,.........., ... be &*&a lease. a a ..................... 44 ARTICLE17 - MISCELLANEOUS................................................................................................................................44 17.01 Giving Notice.,,,',, &bases go% asses, & a 6 , a 0 4 a 0 6 N a 0 . . . . I I I I I . I I I,,.*$1111.116.1111.0 .... 0044 Times................................................................................................................... 44 17.02 Computation of ve Remedies.....................................................................................................................44 17.03 Cumulati........................................................................................................45 17.04 Survival of Obligations...,...,..... 17.05 Controlling Law. ...............................................................................................................................45 00700 - General Conditions 00700-4 F;\Enginerning\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid DOcun=U\00700 - General Conftons.doc GENERAL CONDITIONS ARTICLE 1 - DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms A. Wherever used in the Contract Documents and printed with initial or all capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. 1. Addenda --Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the Contract Documents. 2. Agreement—The written instrument which is evidence of the agreement between OWNER and CONTRACTOR covering the Work. 3. Application for Payment --The form acceptable to ENGINEER which is to be used by CONTRACTOR during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4. Asbestos --Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupa- tional Safety and Health Administration, 5. Bid—The offer or proposal of a bidder submitted on the prescribed form setting forth the prices for the Work to be performed. 6. Bidding Documents --The Bidding Requirements and the proposed Contract Documents (including all Addenda issued prior to receipt of Bids). 7. Bidding Requirements --The Advertisement or Invitation to Bid, Instructions to Bidders, Bid security form, if any, and the Bid form with any supplements. 8. Bonds --Performance and payment bonds and other instruments of security. 9. Change Order --A document recommend- ed by ENGINEER which is signed by CONTRACTOR and OWNER and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement. 10. Claim—A demand or assertion by OWNER or CONTRACTOR seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11. Contract—The entire and integrated written agreement between the OWNER and CONTRACTOR concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. 12. Contract Documents --The Contract Documents establish the rights and obligations of the parties and include the Agreement, Addenda (which pertain to the Contract Documents), CONTRACTOR's Bid (including documentation accompanying the Bid and any post Bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Agreement, the Notice to Proceed, the Bonds, these General Conditions, the Supplementary Conditions, the Specifications and the Drawings as the same are more specifically identified in the Agreement, together with all Written Amendments, Change Orders, Work Change Directives, Field Orders, and ENGINEER's written interpretations and clarifications issued on or after the Effective Date of the Agreement. Approved Shop Drawings and the reports and drawings of subsurface and physical conditions are not Contract Documents. Only printed or hard copies of the items listed in this paragraph are Contract Documents. Files in electronic media format of text, data, graphics, and the like that may be furnished by OWNER to CONTRACTOR are not Contract Documents. 13, Contract Price -The moneys payable by OWNER to CONTRACTOR for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of paragraph 11.03 in the case of Unit Price Work), 14. Contract Times --The number of days or the dates stated in the Agreement to: (i) achieve Substantial Completion; and (ii) complete the Work so that it is ready for final payment as evidenced by ENGINEER's written recommendation of final pay- ment. 15. CONTRACTOR --The individual or entity with whom OWNER has entered into the Agreement. 16. Cost of the Work—See paragraph 11.01.A for definition. 00700 - General Conditions 00700-5 FAEoginceringTetition Pavingt0522 lst Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 17. Drawings—That part of the Contract Documents prepared or approved by ENGINEER which graphically shows the scope, extent, and character of the Work to be performed by CONTRACTOR. Shop Drawings and other CONTRACTOR submittals are not Drawings as so defined. 18. Effective Date of the Agreement --The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 19. ENGINEER --The individual or entity named as such in the Agreement. 21, Field Order --A written order issued by ENGINEER which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 22. General Requirements—Sections of Division 1 of the Specifications. The General Requirements pertain to all sections of the Specifica- tions. 23, Hazardous Environmental Condition The presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto in connection with the Work. 24, Hazardous Waste—The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 25. Laws and Regulations; Laws or Regulat ions— Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all govem- mental bodies, agencies, authorities, and courts having jurisdiction. 26. Liens—Charges, security interests, or encumbrances upon Project funds, real property, or personal property. 27. Milestone—A principal event specified in the Contract Documents relating to an intermediate completion date or time prior to Substantial Comple- tion of all the Work. 28. Notice of Award --The written notice by OWNER to the apparent successful bidder stating that upon timely compliance by the apparent successful bidder with the conditions precedent listed therein, OWNER will sign and deliver the Agreement. 29. Notice to Proceed—A written notice given by OWNER to CONTRACTOR fixing the date on which the Contract Times will commence to run and on which CONTRACTOR shall start to perform the Work under the Contract Documents, 30. OWNER --The individual, entity, public body, or authority with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be performed. 31. Partial Utilization --Use by OWNER of a substantially completed part of the Work for the pur- pose for which it is intended (or a related purpose) prior to Substantial Completion of all the Work. 32. PCBs --Polychlorinated biphenyls. 33. Petroleum --Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non -Hazardous Waste and crude oils. 34. Project—The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part as may be indicated elsewhere in the Contract Documents, 35, Project Manual --The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 36. Radioactive Matedal--Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 37. Resident Project Representative --The authorized representative of ENGINEER who may be assigned to the Site or any part thereof. 38. Samples --Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which 00700-6 FAEngineeringTetitlon Paving\0522 Iat Rd. from 32nd Ave. to 35th Ave\Bld Document"0700 - General Conditions.dDc 00700 - General Condibons t W�A M-1 r'q". n2T�.AJJJJV�Qgr S, a a a 21, Field Order --A written order issued by ENGINEER which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 22. General Requirements—Sections of Division 1 of the Specifications. The General Requirements pertain to all sections of the Specifica- tions. 23, Hazardous Environmental Condition The presence at the Site of Asbestos, PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto in connection with the Work. 24, Hazardous Waste—The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 25. Laws and Regulations; Laws or Regulat ions— Any and all applicable laws, rules, regulations, ordinances, codes, and orders of any and all govem- mental bodies, agencies, authorities, and courts having jurisdiction. 26. Liens—Charges, security interests, or encumbrances upon Project funds, real property, or personal property. 27. Milestone—A principal event specified in the Contract Documents relating to an intermediate completion date or time prior to Substantial Comple- tion of all the Work. 28. Notice of Award --The written notice by OWNER to the apparent successful bidder stating that upon timely compliance by the apparent successful bidder with the conditions precedent listed therein, OWNER will sign and deliver the Agreement. 29. Notice to Proceed—A written notice given by OWNER to CONTRACTOR fixing the date on which the Contract Times will commence to run and on which CONTRACTOR shall start to perform the Work under the Contract Documents, 30. OWNER --The individual, entity, public body, or authority with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be performed. 31. Partial Utilization --Use by OWNER of a substantially completed part of the Work for the pur- pose for which it is intended (or a related purpose) prior to Substantial Completion of all the Work. 32. PCBs --Polychlorinated biphenyls. 33. Petroleum --Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and pressure (60 degrees Fahrenheit and 14.7 pounds per square inch absolute), such as oil, petroleum, fuel oil, oil sludge, oil refuse, gasoline, kerosene, and oil mixed with other non -Hazardous Waste and crude oils. 34. Project—The total construction of which the Work to be performed under the Contract Documents may be the whole, or a part as may be indicated elsewhere in the Contract Documents, 35, Project Manual --The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 36. Radioactive Matedal--Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. 37. Resident Project Representative --The authorized representative of ENGINEER who may be assigned to the Site or any part thereof. 38. Samples --Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which 00700-6 FAEngineeringTetitlon Paving\0522 Iat Rd. from 32nd Ave. to 35th Ave\Bld Document"0700 - General Conditions.dDc 00700 - General Condibons establish the standards by which such portion of the Work will be judged. 39. Shop Drawings- All drawings, diagrams, illustrations, schedules, and other data or information which are specifically prepared or assembled by or for CONTRACTOR and submitted by CONTRACTOR to illustrate some portion of the Work. 40. Site --Lands or areas indicated in the Contract Documents as being furnished by OWNER upon which the Work is to be performed, including rights-of-way and easements for access thereto, and such other lands furnished by OWNER which are designated for the use of CONTRACTOR. 41. Specifications --That part of the Contract Documents consisting of written technical descriptions of materials, equipment, systems, standards, and workmanship as applied to the Work and certain administrative details applicable thereto. 42. Subcontractor --An individual or entity having a direct contract with CONTRACTOR or with any other Subcontractor for the performance of a part of the Work at the Site. 43. Substantial Completion --The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of ENGINEER, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion thereof. 44. Supplementary Conditions --That part of the Contract Documents which amends or supplements these General Conditions, 45. Supplier --A manufacturer, fabricator, supplier, distributor, materialman, or vendor having a direct contract with CONTRACTOR or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by CONTRACTOR or any Subcontractor. 46. Underground Facilities All underground pipelines, conduits, ducts, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, including those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 47. Unit Price Work --Work to be paid for on the basis of unit prices. 48. Work --The entire completed construction or the various separately identifiable parts thereof re- quired to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 49. Work Change Directive—A written statement to CONTRACTOR issued on or after the Effective Date of the Agreement and signed by OWNER and recommended by ENGINEER ordering an addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the change ordered or documented by a Work Change Directive will be incorporated in a subse- quently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times, 50. Written Amendment A written statement modifying the Contract Documents, signed by OWNER and CONTRACTOR on or after the Effective Date of the Agreement and normally dealing with the nonengineering or nontechnical rather than strictly construction -related aspects of the Contract Docu- ments. 1.02 Terminology A. Intent of Certain Terms or Adjectives 1. Whenever in the Contract Documents the terms "as allowed," "as approved," or terms of like effect or import are used, or the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of ENGINEER as to the Work, it is intended that such action or determination will be solely to evaluate, in general, the completed Work for compliance with the requirements of and information in the Contract Documents and conformance with the design concept of the completed Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective shall not be effective to assign to- ENGk 00700-7 00700 - General Conditions FAEngineering\Petition Paving\05221st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc NEER any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of paragraph 90 or any other provisi .1on of the Contract Documents. B. Day 1. The word "day' shall constitute a calendar day of 24 hours measured from midnight to the next midnight. C. Defective 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it does not conform to the Contract Documents or does not meet the requirements of any inspection, reference standard, test, or approval referred to in the Contract Documents, or has been damaged prior to ENGINEER's recom- mendation of final payment (unless responsi- bility for the protection thereof has been assumed by OWNER at Substantial Completion in accordance with paragraph 14.04 or 14.05). D. Furnish, Install, Perform, Provide M. A. AAAAAAAAMAAAAAAM �KWAAAA`A RNA' AA Me t am a 9:::: - - _win! ,-, AAA A, AMA M. A. AAAAAAAAMAAAAAAM �KWAAAA`A RNA' AA 4. When "furnish," "install," "perform," or "provide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of CONTRACTOR, "provide" is implied. E. Unless stated otherwise in the Contract Docu- ments, words or phrases which have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 - PRELIMINARY MATTERS 2.01 Delivery of Bonds A. When CONTRACTOR delivers the executed Agreements to OWNER, CONTRACTOR shall also deliver to OWNER such Bonds as CONTRACTOR may be required to furnish. 2.02 Copies of Documents A. OWNER shall furnish to CONTRACTOR up to ten copies of the Contract Documents. Additional copies will be furnished upon request at the cost of reproduction. 2.03 Commencement of Contract Times; Notice to Proceed A. The Contract Times will commence to run on the thirtieth day after the Effective Date of the Agree- ment or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Pro- ceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event will the Contract Times commence to run later than the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. 2.04 Starting the Work A. CONTRACTOR shall start to perform the Work on the date when the Contract Times com- mence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.05 Before Starting Construction A. CONTRACTOR's Review of Contract Docu- ments: Before undertaking each part of the Work, CONTRACTOR shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. CONTRACTOR shall promptly report in writing to ENGINEER any conflict, error, ambiguity, or discrepancy which CONTRACTOR may discover and shall obtain a written interpretation or clarification from ENGINEER before proceeding with any Work affected 00700 - General Conditions 00700-8 FAEngineeringTelition Paving%0522 tst Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Condltions.doc Me t am a 9:::: - - _win! ,-, 4. When "furnish," "install," "perform," or "provide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of CONTRACTOR, "provide" is implied. E. Unless stated otherwise in the Contract Docu- ments, words or phrases which have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning. ARTICLE 2 - PRELIMINARY MATTERS 2.01 Delivery of Bonds A. When CONTRACTOR delivers the executed Agreements to OWNER, CONTRACTOR shall also deliver to OWNER such Bonds as CONTRACTOR may be required to furnish. 2.02 Copies of Documents A. OWNER shall furnish to CONTRACTOR up to ten copies of the Contract Documents. Additional copies will be furnished upon request at the cost of reproduction. 2.03 Commencement of Contract Times; Notice to Proceed A. The Contract Times will commence to run on the thirtieth day after the Effective Date of the Agree- ment or, if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Pro- ceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event will the Contract Times commence to run later than the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. 2.04 Starting the Work A. CONTRACTOR shall start to perform the Work on the date when the Contract Times com- mence to run. No Work shall be done at the Site prior to the date on which the Contract Times commence to run. 2.05 Before Starting Construction A. CONTRACTOR's Review of Contract Docu- ments: Before undertaking each part of the Work, CONTRACTOR shall carefully study and compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. CONTRACTOR shall promptly report in writing to ENGINEER any conflict, error, ambiguity, or discrepancy which CONTRACTOR may discover and shall obtain a written interpretation or clarification from ENGINEER before proceeding with any Work affected 00700 - General Conditions 00700-8 FAEngineeringTelition Paving%0522 tst Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Condltions.doc thereby, however, CONTRACTOR shall not be liable to OWNER or ENGINEER for failure to report any conflict, error, ambiguity, or discrepancy in the Contract Documents unless CONTRACTOR knew or reasonably should have known thereof. B. Preliminary Schedules. Within ten days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), CONTRAC- TOR shall submit to ENGINEER for its timely review: 1. a preliminary progress schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2, a preliminary schedule of Shop Drawing and Sample submittals which will list each required submittal and the times for sub- mitting, reviewing, and processing such submittal; and 3. a preliminary schedule of values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. 2.06 Preconstruction Conference 2.07 Initial Acceptance of Schedules A. Unless otherwise provided in the Contract Documents, at least ten days before submission of the first Application for Payment a conference attended by CONTRACTOR, ENGINEER, and others as appropri- ate will be held to review for acceptability to ENGI- NEER as provided below the schedules submitted in accordance with paragraph 2.05.13. CONTRACTOR shall have an additional ten days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shall be made to CONTRACTOR until acceptable schedules are submitted to ENGINEER. 1. The progress schedule will be acceptable to ENGINEER if it provides an orderly progression of the Work to completion within any specified Milestones and the Contract Times. Such acceptance will not impose on ENGINEER responsibility for the progress schedule, for sequencing, scheduling, or progress of the Work nor interfere with or relieve CONTRACTOR from CONTRACTOR's full responsibility therefor. 2. CONTRACTOR's schedule of Shop Drawing and Sample submittals will be acceptable to ENGINEER if it provides a workable arrangement for reviewing and processing the required submittals. 3. CONTRACTOR's schedule of values will be acceptable to ENGINEER as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.01 Intent A. The Contract Documents are comple- mentary; what is called for by one is as binding as if called for by all. B. It is the intent of the Contract Documents to describe a functionally complete Project (or part there- of) to be constructed in accordance with the Contract Documents. Any labor, documentation, services, materials, or equipment that may reasonably be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the intended result will be provided whether or not specifically called for at no additional cost to OWNER. 00700 - General Conditions 00700-9 FAEngineering\Petition Paving\0522 list Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Condilions.doc -A - - &I N 1101 .- 2.07 Initial Acceptance of Schedules A. Unless otherwise provided in the Contract Documents, at least ten days before submission of the first Application for Payment a conference attended by CONTRACTOR, ENGINEER, and others as appropri- ate will be held to review for acceptability to ENGI- NEER as provided below the schedules submitted in accordance with paragraph 2.05.13. CONTRACTOR shall have an additional ten days to make corrections and adjustments and to complete and resubmit the schedules. No progress payment shall be made to CONTRACTOR until acceptable schedules are submitted to ENGINEER. 1. The progress schedule will be acceptable to ENGINEER if it provides an orderly progression of the Work to completion within any specified Milestones and the Contract Times. Such acceptance will not impose on ENGINEER responsibility for the progress schedule, for sequencing, scheduling, or progress of the Work nor interfere with or relieve CONTRACTOR from CONTRACTOR's full responsibility therefor. 2. CONTRACTOR's schedule of Shop Drawing and Sample submittals will be acceptable to ENGINEER if it provides a workable arrangement for reviewing and processing the required submittals. 3. CONTRACTOR's schedule of values will be acceptable to ENGINEER as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.01 Intent A. The Contract Documents are comple- mentary; what is called for by one is as binding as if called for by all. B. It is the intent of the Contract Documents to describe a functionally complete Project (or part there- of) to be constructed in accordance with the Contract Documents. Any labor, documentation, services, materials, or equipment that may reasonably be inferred from the Contract Documents or from prevailing custom or trade usage as being required to produce the intended result will be provided whether or not specifically called for at no additional cost to OWNER. 00700 - General Conditions 00700-9 FAEngineering\Petition Paving\0522 list Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Condilions.doc C. Clarifications and interpretations of the Contract Documents shall be issued by ENGINEER as provided in Article 9. 3.02 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 1. Reference to standards, specifica- tions, manuals, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, shall mean the stan- dard, specification, manual, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the Contract Documents. 2. No provision of any such standard, specification, manual or code, or any instruction of a Supplier shall be effective to change the duties or responsibilities of OWNER, CONTRACTOR, or ENGINEER, or any of their subcontractors, consultants, agents, or employ- ees from those set forth in the Contract Documents, nor shall any such provision or instruction be effective to assign to OWNER, ENGINEER, or any of ENGINEER's Consultants, agents, or employees any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies 1. If, during the performance of the Work, CONTRACTOR discovers any conflict, error, ambiguity, or discrepancy within the Con- tract Documents or between the Contract Documents and any provision of any Law or Regulation applicable to the performance of the Work or of any standard, specification, manual. or code, or of any instruction of any Supplier, CONTRACTOR shall report it to ENGINEER in writing at once. CONTRACTOR shall not proceed with the Work affected thereby (except in an emergency as required by paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in paragraph 3.04; provided, however, that CONTRACTOR shall not be liable to OWNER or ENGINEER for failure to report any such conflict, error, ambiguity, or discrepancy unless CON- TRACTOR knew or reasonably should have known thereof. B. Resolving Discrepancies 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, code, or instruction (whether or not specifically incorporated by reference in the Contract Documents); or b. the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Law or Regulation). 3.04 Amending and Supplementing Contract Documents A. The Contract Documents may be amended to provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof in one or more of the following ways: (i) a Written Amendment; (ii) a Change Order; or (iii) a Work Change Directive. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: (i) a Field Order; (ii) ENGINEER's approval of a Shop Drawing or Sample; or (iii) ENGINEER's written interpretation or clarifi- cation. 3.05 Reuse of Documents A. CONTRACTOR and any Subcontractor or Supplier or other individual or entity performing or furnishing any of the Work under a direct or indirect contract with OWNER: (i) shall not have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of ENGINEER or ENGINEER's Consultant, including electronic media editions; and (ii) shall not reuse any of such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of OWNER and 00700 - General Conditions 00700-10 F:\Engineering\Petition Paving\0522 Ist Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc ENGINEER and specific written verification or adaption by ENGINEER. This prohibition will survive final payment, completion, and acceptance of the Work, or termination or completion of the Contract. Nothing herein shall preclude CONTRACTOR from retaining copies of the Contract Documents for record purposes. ARTICLE 4 - AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS 4.01 Availability of Lands A. OWNER shall furnish the Site. OWNER shall notify CONTRACTOR of any encumbrances or restrictions not of general application but specifically related to use of the Site with which CONTRACTOR must comply in performing the Work. OWNER will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If CONTRACTOR and OWNER are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, as a result of any delay in OWNER's furnishing the Site, CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. B. Upon reasonable written request, OWNER shall furnish CONTRACTOR with a current statement of record legal title and legal description of the lands upon which the Work is to be performed and OWNER's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. C. CONTRACTOR shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 4.02 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: 1. those reports of explorations and tests of subsurface conditions at or contiguous to the Site that ENGINEER has used in preparing the Contract Documents; and Site (except Underground Facilities) that ENGI- NEER has used in preparing the Contract Documents, B. Limited Reliance by CONTRACTOR on Technical Data Authorized: CONTRACTOR may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementa- ry Conditions. Except for such reliance on such "technical data," CONTRACTOR may not rely upon or make any Claim against OWNER, ENGINEER, or any of ENGINEER's Consultants with respect to: 1. the completeness of such reports and drawings for CONTRACTOR's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by CONTRACTOR, and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings; or 3. any CONTRACTOR interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions, or information. 4.03 Differing Subsurface or Physical Conditions A. Notice: If CONTRACTOR believes that any subsurface or physical condition at or contiguous to the Site that is uncovered or revealed either: 1. is of such a nature as to establish that any "technical data" on which CONTRAC- TOR is entitled to rely as provided in paragraph 4.02 is materially inaccurate; or 2. is of such a nature as to require a change in the Contract Documents; or 3, differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inher- ent in work of the character provided for in the Contract Documents; 2, those drawings of physical then CONTRACTOR shall, promptly after becoming conditions in or relating to existing surface or aware thereof and before further disturbing the subsurface structures at or contiguous to the subsurface or physical conditions or performing any 00700 - General Conditions 00700-11 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc Work in connection therewith (except in an emergency as required by paragraph 6.16.A), notify OWNER and ENGINEER in writing about such condition. CONTRACTOR shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B. ENGINEER's Review: After receipt of written notice as required by paragraph 4.03.A, ENGINEER will promptly review the pertinent condition, determine the necessity of OWNER's obtaining additional exploration or tests with respect thereto, and advise OWNER in writing (with a copy to CONTRACTOR) of ENGINEER's findings and conclusions. C. Possible Price and Times Adjustments 1, The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an in- crease or decrease in CONTRACTOR's cost of, or time required for, performance of the Work; subject, however, to the following: a. such condition must meet any one or more of the categories described in para- graph 4.03.A; and b, with respect to Work that is paid for on a Unit Price Basis, any adjustment in Contract Price will be subject to the provisions of paragraphs 9.08 and 11.03. 2. CONTRACTOR shall not be entitled to any adjustment in the Contract Price or Contract Times if: a. CONTRACTOR knew of the existence of such conditions at the time CONTRACTOR made a final commitment to OWNER in respect of Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for CON- TRACTOR prior to CONTRACTOR's making such final commitment; or c. CONTRACTOR failed to give the written notice within the time and as re- quired by paragraph 4.03.A. 3. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in paragraph 10.05. However, OWNER, ENGINEER, and ENGINEER's Consultants shall not be liable to CONTRACTOR for. any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by CONTRACTOR on or in connection with any other project or anticipated project. 4.04 Underground Facilities A. Shown or Indicated: The information and data shown or indicated in the Contract Documents with respect to existing Underground Facilities at or contiguous to the Site is based on information and data furnished to OWNER or ENGINEER by the owners of such Underground Facilities, including OWNER, or by others. Unless it is otherwise expressly provided in the Supplementary Conditions: 1. OWNER and ENGINEER shall not be responsible for the accuracy or com- pleteness of any such information or data; and 2, the cost of all of the following will be included in the Contract Price, and CONTRAC- TOR shall have full responsibility for: a. reviewing and checking all such information and data, b. locating all Underground Facilities shown or indicated in the Contract Documents, c. coordination of the Work with the owners of such Underground Facilities, including OWNER, during construction, and d. the safety and protection of all such Underground Facilities and repairing any damage thereto resulting from the Work. B. Not Shown or Indicated 1. If an Underground Facility is uncovered or revealed at or contiguous to the 00700 - General Conditions 00700-12 FAEngineering\Petition Paving\05221st Rd. from 32nd Ave. to 35th Ave\Bid DocumentsW0700 - General Conditions.doc Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, CONTRACTOR shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by paragraph 6.16.A), identify the owner of such Underground Facility and give written notice to that owner and to OWNER and ENGI- NEER. ENGINEER will promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the consequences of the existence or location of the Underground Facility. During such time, CONTRACTOR shall be responsible for the safety and protection of such Underground Facility, 2, If ENGINEER concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflect and document such consequences. An equitable adjustment shall be made in the Contract Price or Contract Times, or both, to the extent that they are attributable to the existence or location of any Underground Facility that was not shown or indicated or not shown or indicated with reasonable accuracy in the Contract Documents and that CONTRACTOR did not know of and could not reasonably have been expected to be aware of or to have anticipated. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment in Contract Price or Contract Times, OWNER or CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. 4.05 Reference Points A. OWNER shall provide engineering surveys to establish reference points for construction which in ENGINEER's judgment are necessary to enable CONTRACTOR to proceed with the Work. COW TRACTOR shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of OWNER. CONTRACTOR shall report to ENGINEER whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.06 Hazardous Environmental Condition at Site A. Reports and Drawings: Reference is made to the Supplementary Conditions for the identification of those reports and drawings relating to a Hazardous Environmental Condition identified at the Site, if any, that have been utilized by the ENGINEER in the preparation of the Contract Documents. B. Limited Reliance by CONTRACTOR on Technical Data Authorized: CONTRACTOR may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," CONTRACTOR may not rely upon or make any Claim against OWNER, ENGINEER or any of ENGINEER's Consultants with respect to: 1. the completeness of such reports and drawings for CONTRACTOR's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences and procedures of construction to be employed by CONTRACTOR and safety precautions and programs incident thereto; or 2, other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings; or 3. any CONTRACTOR interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions or information. C. CONTRACTOR shall not be responsible for any Hazardous Environmental Condition uncovered or revealed at the Site which was not shown or indicated in Drawings or Specifications or identified in the Contract Documents to be within the scope of the Work. CONTRACTOR shall be responsible for a Hazardous Environmental Condition created with any materials brought to the Site by CONTRACTOR, Subcontractors, Suppliers, or anyone else for whom CONTRACTOR is responsible. D. If CONTRACTOR encounters a Hazardous Environmental Condition or if CONTRACTOR or anyone for whom CONTRACTOR is responsible creates a Hazardous Environmental Condition, CONTRACTOR shall immediately: (i) secure or otherwise isolate such condition; (ii) stop all Work in 00700 - General Conditions 00700-13 F:\Engineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc connection with such condition and in any area affected thereby (except in an emergency as required by paragraph 6.16); and (iii) notify OWNER and ENGI- NEER (and promptly thereafter confirm such notice in writing). OWNER shall promptly consult with ENGINEER concerning the necessity for OWNER to retain a qualified expert to evaluate such condition or take corrective action, if any. E. CONTRACTOR shall not be required to resume Work in connection with such condition or in any affected area until after OWNER has obtained any required permits related thereto and delivered to CONTRACTOR written notice: (i) specifying that such condition and any affected area is or has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If OWNER and CONTRACTOR cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stoppage or such special conditions under which Work is agreed to be resumed by CONTRACTOR, either party may make a Claim therefor as provided in paragraph 10.05. F. If after receipt of such written notice CONTRACTOR does not agree to resume such Work based on a reasonable belief it is unsafe, or does not agree to resume such Work under such special condi- tions, then OWNER may order the portion of the Work that is in the area affected by such condition to be deleted from the Work. If OWNER and CON- TRACTOR cannot agree as to entitlement to or on the amount or extent, if any, of an adjustment in Contract Price or Contract Times as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in paragraph 10.05. OWNER may have such deleted portion of the Work performed by OWNER's own forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, OWNER shall indemnify and hold harmless CONTRACTOR, Subcontractors, ENGI- NEER, ENGINEER's Consultants and the officers, directors, partners, employees, agents, other consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hazardous Environmental Condition: (i) was not shown or indicated in the Drawings or Specifications or identified in the Contract Documents to be included within the scope of the Work, and (ii) was not created by CONTRACTOR or by anyone for whom CONTRACTOR is responsible. Nothing in this para- graph 4.06.E shall obligate OWNER to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. H. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, ENGINEER's Consultants, and the officers, directors, partners, employees, agents, other consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by CONTRACTOR or by anyone for whom CONTRACTOR is responsible. Nothing in this paragraph 4.06.F shall obligate CONTRACTOR to indemnify any individual or entity from and against the consequences of that individual's or entity's own negli- gence. I. The provisions of paragraphs 4.02, 4.03, and 4.04 are not intended to apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 IN BONDS AND INSURANCE 5.01 Performance, Payment, and Other Bonds B. All Bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the current list of "Com- panies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All Bonds signed by an agent must be 00700 - General Conditions 00700-14 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Donuments\00700 - General Conditions.doc .. -. .- .. 14 .. . ,le If..- . . - B. All Bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the current list of "Com- panies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All Bonds signed by an agent must be 00700 - General Conditions 00700-14 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Donuments\00700 - General Conditions.doc accompanied by a certified copy of such agent's authority to act. C. If the surety on any Bond furnished by CON- TRACTOR is declared bankrupt or becomes insolvent or its right to do business is terminated in any state where any part of the Project is located or it ceases to meet the requirements of paragraph 5.01.8, CONTRACTOR shall within 20 days thereafter substitute another Bond and surety, both of which shall comply with the requirements of paragraphs 5.01.8 and 5.02. 5.02 Licensed Sureties and Insurers A. All Bonds and insurance required by the Contract Documents to be purchased and maintained by OWNER or CONTRACTOR shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue Bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided in the Supplementary Conditions. 5.03 Certificates of Insurance OEM= wN �. -. 5.04 CONTRACTOR's Liability Insurance A. CONTRACTOR shall purchase and maintain such liability and other insurance as is appropriate for the Work being performed and as will provide protection from claims set forth below which may arise out of or result from CONTRACTOR's performance of the Work and CONTRACTOR's other obligations under the Contract Documents, whether it is to be per- formed by CONTRACTOR, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of CONTRACTOR's employees; 3, claims for damages because of bodily injury, sickness or disease, or death of any person other than CONTRACTOR's employees; 4* claims for damages insured by reasonably available personal injury liability coverage which are sustained: (i) by any person as a result of an offense directly or indirectly related to the employment of such person by CONTRACTOR, or (ii) by any other person for any other reason; 5, claims for damages, other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 6, claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, mainte- nance or use of any motor vehicle. B. The policies of insurance so required by this paragraph 5.04 to be purchased and maintained shall: 1. with respect to insurance required by paragraphs 5.04.A.3 through 5.04.A.6 inclusive, include as additional insureds (subject to any customary exclusion in respect of professional liability) OWNER, ENGINEER, ENGINEER's Consultants, and any other individuals or entities identified in the Supplementary Condi- tions, all of whom shall be listed as additional insureds, and include coverage for the respec- tive officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby, 2, include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or required by Laws or Regulations, whichever is greater; 3. include insurance; 00700-15 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc completed operations 00700 - General Conditions 5.08 Receipt and Application of Insurance Proceeds 5.09 Acceptance of Bonds and Insurance; Option to Replace .. elm ._ -L MALI A I IIALAAAWAMMOM AM A.M. a ... AL - IJMMMAII .., - I' .,Ad AL ad AL .. .. - .. AM 0 F19 . _ - . . . - Ir AL I AL MAI I ., ., - I .. POW 5.09 Acceptance of Bonds and Insurance; Option to Replace elm WI -L MALI A I IIALAAAWAMMOM AM A.M. a AL IJMMMAII AL MAINE "I'LAMAMN I' .,Ad AL ad .. .. - .. AM 0 F19 MAI I ., ., - .. ._ AM 5.09 Acceptance of Bonds and Insurance; Option to Replace 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If OWNER finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in paragraph 14.05, no such use or occupancy shall commence before the insurers providing the property insurance pursuant to paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in cover- age necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. CONTRACTOR shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. CON- TRACTOR shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction, but CONTRACTOR shall not be responsible for the negligence of OWNER or ENGINEER in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. CON- TRACTOR shall be responsible to see that the completed Work complies accurately with the Contract Documents. B. At all times during the progress of the Work, CONTRACTOR shall assign a competent resident superintendent thereto who shall not be replaced without written notice to OWNER and ENGINEER except under extraordinary circumstances. The superintendent will be CONTRACTOR's representative at the Site and shall have authority to act on behalf of CONTRACTOR. All communications given to or received from the superintendent shall be binding on CONTRACTOR. 6.02 Labor; Working Hours A. CONTRACTOR shall provide competent, suitably qualified personnel to survey, lay out, and construct the Work as required by the Contract Docu- 00700 - General Conditions 00700 - 18 FAEngineering\Petltion Paving\05221st Rd. from 32nd Ave. to 35th Ave\Bld Documents\00700 - General Conditions.doc WI ad .. .. AM 0 F19 MAI I ., .. ._ AM 14 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If OWNER finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in paragraph 14.05, no such use or occupancy shall commence before the insurers providing the property insurance pursuant to paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in cover- age necessitated thereby. The insurers providing the property insurance shall consent by endorsement on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. CONTRACTOR shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents. CON- TRACTOR shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction, but CONTRACTOR shall not be responsible for the negligence of OWNER or ENGINEER in the design or specification of a specific means, method, technique, sequence, or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. CON- TRACTOR shall be responsible to see that the completed Work complies accurately with the Contract Documents. B. At all times during the progress of the Work, CONTRACTOR shall assign a competent resident superintendent thereto who shall not be replaced without written notice to OWNER and ENGINEER except under extraordinary circumstances. The superintendent will be CONTRACTOR's representative at the Site and shall have authority to act on behalf of CONTRACTOR. All communications given to or received from the superintendent shall be binding on CONTRACTOR. 6.02 Labor; Working Hours A. CONTRACTOR shall provide competent, suitably qualified personnel to survey, lay out, and construct the Work as required by the Contract Docu- 00700 - General Conditions 00700 - 18 FAEngineering\Petltion Paving\05221st Rd. from 32nd Ave. to 35th Ave\Bld Documents\00700 - General Conditions.doc ments. CONTRACTOR shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours, and CONTRACTOR will not permit overtime work or the performance of Work on Saturday, Sunday, or any legal holiday without OWNER's written consent (which will not be unreasonably withheld) given after prior written notice to ENGINEER. 6.03 Services, Materials, and Equipment A. Unless otherwise specified in the General Re- quirements, CONTRACTOR shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start-up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All warranties and guarantees specifically called for by the Specifica- tions shall expressly run to the benefit of OWNER. If required by ENGINEER, CONTRACTOR shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents. 6.04 Progress Schedule A. CONTRACTOR shall adhere to the progress schedule established in accordance with paragraph 2.07 as it may be adjusted from time to time as provided below. 1. CONTRACTOR shall submit to ENGINEER for acceptance (to the extent indi- cated in paragraph 2.07) proposed adjustments in the progress schedule that will not result in changing the Contract Times (or Milestones). Such adjustments will conform generally to the progress schedule then in effect and additional- ly will comply with any provisions of the General Requirements applicable thereto. 2. Proposed adjustments in the progress schedule that will change the Contract Times (or Milestones) shall be submitted in accordance with the requirements of Article 12. Such adjustments may only be made by a Change Order or Written Amendment in accor- dance with Article 12, 6.05 Substitutes and "Or -Equals" A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or -equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to ENGINEER for review under the circumstances described below. 1. "Or -Equal" Items: If in ENGINEER's sole discretion an item of material or equipment proposed by CONTRACTOR is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by ENGINEER as an "or -equal" item, in which case review and approval of the proposed item may, in ENGINEER's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substk tute items. For the purposes of this paragraph 6.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if: a. in the exercise of reasonable judgment ENGINEER determines that: (i) it is at least equal in quality, durability, appearance, strength, and design characteristics; (ii) it will reliably perform at least equally well the function imposed by the design concept of the completed Project as a functioning whole, and; b. CONTRACTOR certifies that: (i) there is no increase in cost to the OWNER; and (ii) it will conform substantially, even with deviations, to the detailed requirements of the item named in the Contract Documents. 00700 - General Conditions 00700-19 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 2. Substitute Items a. If in ENGINEER's sole discretion an item of material or equipment proposed by CONTRACTOR does not qualify as an "or -equal" item under paragraph 6.05.A.I I it will be considered a proposed substitute item. b. CONTRACTOR shall submit suffi- cient information as provided below to allow ENGINEER to determine that the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by ENGINEER from anyone other than CONTRACTOR. c. The procedure for review by ENGI- NEER will be as set forth in paragraph 6.05.A.2.d, as supplemented in the General Requirements and as ENGINEER may decide is appropriate under the circumstances. d. CONTRACTOR shall first make written application to ENGINEER for review of a proposed substitute item of material or equipment that CONTRACTOR seeks to furnish or use. The application shall certify that the proposed substitute item will perform adequately the functions and achieve the results called for by the general design, be similar in substance to that specified, and be suited to the same use as that specified. The application will state the extent, if any, to which the use of the pro- posed substitute item will prejudice CONTRACTOR's achievement of Substan- tial Completion on time, whether or not use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) to adapt the design to the proposed substitute item and whether or not incorporation or use of the proposed substi- tute item in connection with the Work is sub- ject to payment of any license fee or royalty. All variations of the proposed substitute item from that specified will be identified in the application, and available engineering, sales, maintenance, repair, and replacement services will be indicated. The application will also contain an itemized estk mate of all costs or credits that will result directly or indirectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change, all of which will be considered by ENGINEER in evaluating the proposed substitute item. ENGINEER may require CONTRACTOR to furnish additional data about the proposed substitute item. B. Substitute Construction Methods or Proce- dures: If a specific means, method, technique, se- quence, or procedure of construction is shown or indicated in and expressly required by the Contract Documents, CONTRACTOR may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by ENGINEER. CONTRACTOR shall submit sufficient information to allow ENGINEER, in ENGINEER's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The procedure for review by ENGINEER will be similar to that provided in subparagraph 6.05.A.2. C. Engineer's Evaluation: ENGINEER will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to para- graphs 6.05.A and 6.05.13. ENGINEER will be the sole judge of acceptability. No "or -equal" or substitute will be ordered, installed or utilized until ENGINEER's review is complete, which will be evidenced by either a Change Order for a substitute or an approved Shop Drawing for an "or equal" ENGINEER will advise CONTRACTOR in writing of any negative determination. D. Special Guarantee: OWNER may require CONTRACTOR to furnish at CONTRACTOR's ex- pense a special performance guarantee or other surety with respect to any substitute. E. ENGINEER's Cost Reimbursement: ENGINEER will record time required by ENGINEER and ENGINEER's Consultants in evaluating substitute proposed or submitted by CONTRACTOR pursuant to paragraphs 6.05.A.2 and 6.05.13 and in making changes in the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) occasioned thereby. Whether or not ENGINEER approves a substitute item so pro- posed or submitted by CONTRACTOR, CON- TRACTOR shall reimburse OWNER for the charges of ENGINEER and ENGINEER's Consultants for evaluating each such proposed substitute. F. CONTRACTOR's Expense: CONTRACTOR shall provide all data in support of any proposed substitute or "or -equal" at CONTRACTOR's expense. 00700 - General Conditions 00700-20 F:AEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 6.06 Concerning Subcontractors, Suppliers, and Others A. CONTRACTOR shall not employ any Subcontractor, Supplier, or other individual or entity (including those acceptable to OWNER as indicated in paragraph 6.06.13), whether initially or as a replacement, against whom OWNER may have reasonable objection. CONTRACTOR shall not be required to employ any Subcontractor, Supplier, or other individual or entity to furnish or perform any of the Work against whom CONTRACTOR has reason- able objection. B. If the Supplementary Conditions require the identity of certain Subcontractors, Suppliers, or other individuals or entities to be submitted to OWNER in advance for acceptance by OWNER by a specified date prior to the Effective Date of the Agreement, and if CONTRACTOR has submitted a list thereof in accordance with the Supplementary Conditions, OWNER's acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection in the Bidding Documents or the Contract Documents) of any such Subcon- tractor, Supplier, or other individual or entity so identified may be revoked on the basis of reasonable objection after due investigation. CONTRACTOR shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the difference in the cost occasioned by such replacement, and an appropriate Change Order will be issued or Written Amendment signed. No acceptance by OWNER of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall constitute a waiver of any right of OWNER or ENGINEER to reject defective Work. C. CONTRACTOR shall be fully responsible to OWNER and ENGINEER for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as CONTRACTOR is responsible for CONTRACTOR's own acts and omissions. Nothing in the Contract Documents shall create for the benefit of any such Subcontractor, Supplier, or other individual or entity any contractual relationship between OWNER or ENGINEER and any such Subcontractor, Supplier or other individual or entity, nor shall it create any obligation on the part of OWNER or ENGINEER to pay or to see to the payment of any moneys due any such Subcontractor, Supplier, or other individual or entity except as may otherwise be required by Laws and Regulations. D. CONTRACTOR shall be solely responsible for scheduling and coordinating the Work of Subcon- tractors, Suppliers, and other individuals or entities performing or furnishing any of the Work under a direct or indirect contract with CONTRACTOR. E. CONTRACTOR shall require all Subcontrac- tors, Suppliers, and such other individuals or entities performing or furnishing any of the Work to commu- nicate with ENGINEER through CONTRACTOR. F. The divisions and sections of the Specifica- tions and the identifications of any Drawings shall not control CONTRACTOR in dividing the Work among Subcontractors or Suppliers or delineating the Work to be performed by any specific trade. G. All Work performed for CONTRACTOR by a Subcontractor or Supplier will be pursuant to an appropriate agreement between CONTRACTOR and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of OWNER and ENGINEER. Whenever any such agreement is with a Subcontractor or Supplier who is listed as an additional insured on the property insurance provided in paragraph 5.06, the agreement between the CONTRACTOR and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against OWNER, CONTRACTOR, ENGINEER, ENGINEER's Consultants, and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, CONTRACTOR will obtain the same. 6.07 Patent Fees and Royalties A. CONTRACTOR shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if to the actual knowledge of OWNER or ENGINEER its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by OWNER in the Contract Documents. To the fullest extent permitted by Laws and Regulations, 00700 - General Conditlons 00700-21 FAEngineeringTetition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, ENGINEER's Consultants, and the officers, directors, partners, employees or agents, and other consultants of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents, 6.08 Permits A. Unless otherwise provided in the Supple- mentary Conditions, CONTRACTOR shall obtain and pay for all construction permits and licenses. OWNER shall assist CONTRACTOR, when necessary, in obtaining such permits and licenses. CONTRACTOR shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. CONTRACTOR shall pay all charges of utility owners for connections to the Work, and OWNER shall pay all charges of such utility owners for capital costs related thereto, such as plant investment fees. 6.09 Laws and Regulations A. CONTRACTOR shall give all notices and comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither OWNER nor ENGINEER shall be responsible for monitoring CONTRACTOR's compli- ance with any Laws or Regulations. B. If CONTRACTOR performs any Work know- ing or having reason to know that it is contrary to Laws or Regulations, CONTRACTOR shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work; however, it shall not be CONTRACTOR's primary responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve CONTRACTOR of CONTRACTOR's obligations under paragraph 3.03. C. Changes in Laws or Regulations not known at the time of opening of Bids (or, on the Effective Date of the Agreement if there were no Bids) having an effect on the cost or time of performance of the Work may be the subject of an adjustment in Contract Price or Contract Times. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any such adjustment, a Claim may be made therefor as provided in paragraph 10.05. 6.10 Taxes B. OWNER qualifies for state and local sales tax exemption in the purchase of all material and equipment. 6.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas 1. CONTRACTOR shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. CONTRACTOR shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, CONTRACTOR shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, , and the officers, directors, partners, employees, agents, and other consultants of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or 00700 - General Conditions 00700-22 FAEngineering\Petition Paving%0522 1 st Rd. from 32nd Ave. to 35th AveXBid Documents\00700 - General Conditions.doc IL B. OWNER qualifies for state and local sales tax exemption in the purchase of all material and equipment. 6.11 Use of Site and Other Areas A. Limitation on Use of Site and Other Areas 1. CONTRACTOR shall confine construction equipment, the storage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. CONTRACTOR shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, CONTRACTOR shall promptly settle with such other party by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, , and the officers, directors, partners, employees, agents, and other consultants of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or 00700 - General Conditions 00700-22 FAEngineering\Petition Paving%0522 1 st Rd. from 32nd Ave. to 35th AveXBid Documents\00700 - General Conditions.doc arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against OWNER, ENGINEER, or any other party indemnified hereunder to the extent caused by or based upon CONTRACTOR's performance of the Work. B. Removal of Debris During Performance of the Work. During the progress of the Work CONTRAC- TOR shall keep the Site and other areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materi- als, rubbish, and other debris shall conform to applica- ble Laws and Regulations. C. Cleaning: Prior to Substantial Completion of the Work CONTRACTOR shall clean the Site and make it ready for utilization by OWNER. At the com- pletion of the Work CONTRACTOR shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents, D. Loading Structures: CONTRACTOR shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall CONTRACTOR subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.12 Record Documents A. CONTRACTOR shall maintain in a safe place at the Site one record copy of all Drawings, Specifica- tions, Addenda, Written Amendments, Change Orders, Work Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of all approved Shop Drawings will be available to ENGI- NEER for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to ENGINEER for OWNER. 6.13 Safety and Protection A. CONTRACTOR shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. CONTRACTOR shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equip- ment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. CONTRACTOR shall comply with all applica- ble Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. CONTRACTOR shall notify owners of adjacent property and of Underground Facilities and other utility owners when prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property. All damage, injury, or loss to any property referred to in paragraph 6.13.A.2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by CONTRACTOR, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by CONTRACTOR (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of OWNER or ENGINEER or ENGINEER's Consultant, or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of CONTRACTOR or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them). CONTRACTOR's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and ENGINEER has issued a notice to OWNER and CONTRACTOR in accordance with paragraph 14.07.13 that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14 Safety Representative A. CONTRACTOR shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and supervising of safety precautions and programs. 00700 - General Conditions 00700-23 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Dowments\00700 - General Conditions.doc 6.15 Hazard Communication Programs A. CONTRACTOR shall be responsible for coordinating any exchange of material safety data sheets or other hazard communication information required to be made available to or exchanged be- tween or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protec- tion of persons or the Work or property at the Site or adjacent thereto, CONTRACTOR is obligated to act to prevent threatened damage, injury, or loss. CONTRACTOR shall give ENGINEER prompt written notice if CONTRACTOR believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If ENGINEER determines that a change in the Contract Documents is required be- cause of the action taken by CONTRACTOR in response to such an emergency, a Work Change Directive or Change Order will be issued. 6.17 Shop Drawings and Samples A. CONTRACTOR shall submit Shop Drawings to ENGINEER for review and approval in accordance with the acceptable schedule of Shop Drawings and Sample submittals. All submittals will be identified as ENGINEER may require and in the number of copies specified in the General Requirements. The data shown on the Shop Drawings will be complete with respect to quantities, dimensions, specified perfor- mance and design criteria, materials, and similar data to show ENGINEER the services, materials, and equipment CONTRACTOR proposes to provide and to enable ENGINEER to review the information for the limited purposes required by paragraph 6.17.E. B. CONTRACTOR shall also submit Samples to ENGINEER for review and approval in accordance with the acceptable schedule of Shop Drawings and Sample submittals. Each Sample will be identified clearly as to material, Supplier, pertinent data such as catalog numbers, and the use for which intended and otherwise as ENGINEER may require to enable ENGI- NEER to review the submittal for the limited purposes required by paragraph 6.17.E. The numbers of each Sample to be submitted will be as specified in the Specifications. C. Where a Shop Drawing or Sample is required by the Contract Documents or the schedule of Shop Drawings and Sample submittals acceptable to ENGk NEER as required by paragraph 2.07, any related Work performed prior to ENGINEER's review and approval of the pertinent submittal will be at the sole expense and responsibility of CONTRACTOR. D. Submittal Procedures 1. Before submitting each Shop Drawing or Sample, CONTRACTOR shall have determined and verified: a. all field measurements, quantities, dimensions, specified performance criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; b. all materials with respect to intended use, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; c, all information relative to means, methods, techniques, sequences, and procedures of construction and safety precautions and programs incident thereto; and d. CONTRACTOR shall also have reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents. 2. Each submittal shall bear a stamp or specific written indication that CONTRACTOR has satisfied CONTRACTOR's obligations under the Contract Documents with respect to CONTRACTOR's review and approval of that submittal. 3. At the time of each submittal, CON- TRACTOR shall give ENGINEER specific written notice of such variations, if any, that the Shop Drawing or Sample submitted may have from the requirements of the Contract Documents, such notice to be in a written com- munication separate from the submittal; and, in addition, shall cause a specific notation to be made on each Shop Drawing and Sample sub- mitted to ENGINEER for review and approval of each such variation. E. ENG/NEER's Review 1. ENGINEER will timely review and approve Shop Drawings and Samples in accordance with the schedule of Shop Drawings and Sample submittals acceptable to 00700 - General Conditions 00700-24 FAEngineeringTetition Pavin05221st Rd. from 32nd Ave. to 35th Ave\Bid Oocuments%00700 . General Conditions.doc ENGINEER. ENGINEER's review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2. ENGINEER's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of con- struction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. ENGINEER's review and approval of Shop Drawings or Samples shall not relieve CONTRACTOR from responsibility for any variation from the requirements of the Contract Documents unless CONTRACTOR has in writing called ENGINEER's attention to each such variation at the time of each submittal as required by paragraph 6.17.D.3 and ENGI- NEER has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample approval; nor will any approval by ENGINEER relieve CON- TRACTOR from responsibility for complying with the requirements of paragraph 6.17.D.1 I F. Resubmittal Procedures 1. CONTRACTOR shall make correc- tions required by ENGINEER and shall return the required number of corrected copies of Shop Drawings and submit as required new Samples for review and approval. CON- TRACTOR shall direct specific attention in writing to revisions other than the corrections called for by ENGINEER on previous submittals. 6.18 Continuing the Work A. CONTRACTOR shall carry on the Work and adhere to the progress schedule during all disputes or disagreements with OWNER. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by paragraph 15.04 or as OWNER and CONTRACTOR may otherwise agree in writing. 6.19 CONTRACTOR's General Warranty and Guarantee A. CONTRACTOR warrants and guarantees to OWNER, ENGINEER, and ENGINEER's Consultants that all Work will be in accordance with the Contract Documents and will not be defective. CONTRACTOR's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than CONTRACTOR, Subcontractors, Suppliers, or any other individual or entity for whom CONTRACTOR is responsible; or 2. normal wear and tear under normal usage. B. CONTRACTOR's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of CONTRACTOR's obligation to perform the Work in accordance with the Contract Documents: 1. observations by ENGINEER; 2, recommendation by ENGINEER or payment by OWNER of any progress or final payment; 3, the issuance of a certificate of Sub- stantial Completion by ENGINEER or any payment related thereto by OWNER; 4. use or occupancy of the Work or any part thereof by OWNER; 5, any acceptance by OWNER or any failure to do so; 6, any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptability by ENGINEER; 7. any inspection, test, or approval by others; or 8, any correction of defective Work by OWNER. 6.20 Indemnification A. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold 00700 . General Conditions 00700-25 FAEngineering\Petition Paving\0522 1 st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc harmless OWNER, ENGINEER, RNIQ1 1291PIRI GIRtS, and the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage: 1. is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction of tangible property (other than the Work itself), including the loss of use resulting therefrom; and 2* is caused in whole or in part by any negligent act or omission of CONTRACTOR, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work or anyone for whose acts any of them may be liable, regardless of whether or not caused in part by any negligence or omission of an individual or entity indemnified hereunder or whether liability is imposed upon such indemni- fied party by Laws and Regulations regardless of the negligence of any such individual or entity. B. In any and all claims against OWNER or ENGINEER or any of their respective consultants, agents, officers, directors, partners, or employees by any employee (or the survivor or personal representative of such employee) of CONTRACTOR, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for CONTRACTOR or any such Subcontractor, Supplier, or other individual or entity under workers' compen- sation acts, disability benefit acts, or other employee benefit acts. C. The indemnification obligations of COW TRACTOR under paragraph 6.20.A shall not extend to the liability of ENGINEER aaa —€AIGIN€ER's Gem altants or to the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them arising out of: 1. the preparation or approval of, or the failure to prepare or approve, maps, Drawings, opinions, reports, surveys, Change Orders, designs, or Specifications; or 2, giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage. ARTICLE 7 - OTHER WORK 7.01 Related Work at Site A. OWNER may perform other work related to the Project at the Site by OWNER's employees, or let other direct contracts therefore, or have other work performed by utility owners. If such other work is not noted in the Contract Documents, then: 1. written notice thereof will be given to CONTRACTOR prior to starting any such other work; and 2. if OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in paragraph 10.05. B. CONTRACTOR shall afford each other contractor who is a party to such a direct contract and each utility owner (and OWNER, if OWNER is per- forming the other work with OWNER's employees) proper and safe access to the Site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work and shall properly coordinate the Work with theirs. Unless otherwise provided in the Contract Documents, CONTRACTOR shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and property integrate with such other work. CONTRACTOR shall not endanger any work of others by cutting, excavating, or otherwise altering their work and will only cut or alter their work with the written consent of ENGINEER and the others whose work will be affected. The duties and responsibilities of CONTRACTOR under this paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of CONTRACTOR in said direct contracts between OWNER and such utility owners and other contractors. 00700 - General Conditions 00700-26 FAEngineeringTetition Paving\0522 Ist Rd. from 32nd Ave. to 35th Ave\Bld Documentst00700 - General Conditions.doc C. If the proper execution or results of any part of CONTRACTOR's Work depends upon work per- formed by others under this Article 7, CONTRACTOR shall inspect such other work and promptly report to ENGINEER in writing any delays, defects, or deficien- cies in such other work that render it unavailable or unsuitable for the proper execution and results of CONTRACTOR's Work. CONTRACTOR's failure to so report will constitute an acceptance of such other work as fit and proper for integration with CONTRACTOR's Work except for latent defects and deficiencies in such other work. 7.02 Coordination A. If OWNER intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Conditions: 1. the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3, the extent of such authority and responsibilities will be provided. B. Unless otherwise provided in the Supplementary Conditions, OWNER shall have sole authority and responsibility for such coordination. ARTICLE 8 - OWNER'S RESPONSIBILITIES 8.01 Communications to Contractor A. Except as otherwise provided in these General Conditions, OWNER shall issue all communi- cations to CONTRACTOR through ENGINEER. 8.02 Replacement of ENGINEER A. In case of termination of the employment of ENGINEER, OWNER shall appoint an engineer to whom CONTRACTOR makes no reasonable objection, whose status under the Contract Documents shall be that of the former ENGINEER. 8.03 Furnish Data A. OWNER shall promptly furnish the data required of OWNER under the Contract Documents, 8.04 Pay Promptly When Due A. OWNER shall make payments to CONTRAC- TOR promptly when they are due as provided in paragraphs 14.02.0 and 14.07.C. 8.05 Lands and Easements; Reports and Tests A. OWNER's duties in respect of providing lands and easements and providing engineering surveys to establish reference points are set forth in paragraphs 4.01 and 4.05. Paragraph 4.02 refers to OWNER's identifying and making available to CONTRACTOR copies of reports of explorations and tests of subsurface conditions and drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site that have been utilized by ENGINEER in preparing the Contract Documents. 8.06 Insurance A. OWNER's responsibilities, if any, in respect to purchasing and maintaining liability and property insur- ance are set forth in Article 5. 8.07 Change Orders A. OWNER is obligated to execute Change Orders as indicated in paragraph 10.03. 8.08 Inspections, Tests, and Approvals A. OWNER's responsibility in respect to certain inspections, tests, and approvals is set forth in paragraph 13.03.13. 8.09 Limitations on O WNER's Responsibilities A. The OWNER shall not supervise, direct, or have control or authority over, nor be responsible for, CONTRACTOR's means, methods, techniques, se- quences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of the Work. OWNER will not be responsible for CONTRACTOR's failure to perform the Work in accordance with the Contract Documents. 00700 - General Conditions 00700-27 FAEngineeringTetition Paving\0522 Ist Rd. from 32nd Ave. to 35th Ave\Bld Documents=700 - General Conditions.doc 8.10 Undisclosed Hazardous Environmental Condition A. OWNER's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in paragraph 4.06. 8.11 Evidence of Financial Arrangements A. If and to the extent OWNER has agreed to furnish CONTRACTOR reasonable evidence that financial arrangements have been made to satisfy OWNER's obligations under the Contract Documents, OWNER's responsibility in respect thereof will be as set forth in the Supplementary Conditions. ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION 9.01 OWNER'S Representative A. ENGINEER will be OWNER's representative during the construction period. The duties and responsibilities and the limitations of authority of ENGINEER as OWNER Is representative during construction are set forth in the Contract Documents and will not be changed without written consent of OWNER and ENGINEER. 9.02 Visits to Site A. ENGINEER will make visits to the Site at intervals appropriate to the various stages of construc- tion as ENGINEER deems necessary in order to observe as an experienced and qualified design professional the progress that has been made and the quality of the various aspects of CONTRACTOR's executed Work. Based on information obtained during such visits and observations, ENGINEER, for the benefit of OWNER, will determine, in general, if the Work is proceeding in accordance with the Con- tract Documents. ENGINEER will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. ENGINEER's efforts will be directed toward providing for OWNER a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, ENGINEER will keep OWNER informed of the progress of the Work and will endeavor to guard OWNER against defective Work. B. ENGINEER's visits and observations are subject to all the limitations on ENGINEER's authority and responsibility set forth in paragraph 9.10, and particularly, but without limitation, during or as a result of ENGINEER's visits or observations of CONTRACTOR's Work ENGINEER will not supervise, direct, control, or have authority over or be responsible for CONTRACTOR's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of the Work. 9.03 Project Representative A. If OWNER and ENGINEER agree, ENGI- NEER will furnish a Resident Project Representative to assist ENGINEER in providing more extensive observation of the Work. The responsibilities and authority and limitations thereon of any such Resident Project Representative and assistants will be as provided in paragraph 9.10 and in the Supplementary Conditions, If OWNER designates another represen- tative or agent to represent OWNER at the Site who is not ENGINEER's Consultant, agent or employee, the responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supplementary Conditions, 9.04 Clarifications and Interpretations A. ENGINEER will issue with reasonable promptness such written clarifications or interpreta- tions of the requirements of the Contract Documents as ENGINEER may determine necessary, which shall be consistent with the intent of and reasonably inferable from the Contract Documents. Such written clarifications and interpretations will be binding on OWNER and CONTRACTOR. If OWNER and COW TRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a written clarification or interpretation, a Claim may be made therefor as provided in paragraph 10.05. 9.05 Authorized Variations in Work A. ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compati- ble with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on OWNER and also on CONTRACTOR, who shall perform the Work involved promptly. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, as a result of a Field Order, 00700 - General Conditions 00700-28 FAEngineering\Petition Paving\0522 Iat Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Condilions.doe a Claim may be made therefore as provided in paragraph 10.05. 9.06 Rejecting Defective Work A. ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, or that ENGINEER believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. ENGINEER will also have authority to require special inspection or testing of the Work as provided in paragraph 13.04, whether or not the Work is fabricated, installed, or completed. 9.07 Shop Drawings, Change Orders and Payments A. In connection with ENGINEER's authority as to Shop Drawings and Samples, see paragraph 6.17. B. In connection with ENGINEER's authority as to Change Orders, see Articles 101 11, and 12. C. In connection with ENGINEER's authority as to Applications for Payment, see Article 14. 9.08 Determinations for Unit Price Work A. ENGINEER will determine the actual quantk ties and classifications of Unit Price Work performed by CONTRACTOR. ENGINEER will review with CONTRACTOR the ENGINEER's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). ENGINEER's written decision thereon will be final and binding (except as modified by ENGINEER to reflect changed factual conditions or more accurate data) upon OWNER and CONTRACTOR, subject to the provisions of paragraph 10.05. 9.09 Decisions on Requirements of Contract Documents and Acceptability of Work A. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. Claims, disputes and other matters relating to the acceptability of the Work, the quantities and classifications of Unit Price Work, the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, and Claims seeking changes in the Contract Price or Contract Times will be referred initially to ENGINEER in writing, in accordance with the provisions of paragraph 10.05, with a request for a formal decision. B. When functioning as interpreter and judge under this paragraph 9.09, ENGINEER will not show partiality to OWNER or CONTRACTOR and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to this paragraph 9.09 with respect to any such Claim, dispute, or other matter (except any which have been waived by the making or acceptance of final payment as provided in paragraph 14.07) will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any such Claim, dispute, or other matter. 9.10 Limitations on ENGINEER's Authority and Responsibilities A. Neither ENGINEER's authority or respon- sibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by ENGINEER in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by ENGINEER shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by ENGINEER to CONTRACTOR, any Subcon- tractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. B. ENGINEER will not supervise, direct, control, or have authority over or be responsible for CONTRACTOR's means, methods, techniques, se- quences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of the Work. ENGINEER will not be responsible for CONTRACTOR's failure to perform the Work in accordance with the Contract Documents. C. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. ENGINEER's review of the final Application for Payment and accompanying documentation and all maintenance and operating instructions, schedules, guarantees, Bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by paragraph 14.07.A will only be to determine generally that their content complies with the requirements of, and in the case of certificates of 00700 - General Conditions 00700-29 FAEngineeringTetilion Paving\0522 Ist Rd. from 32nd Ave. to 35th Ave\Bid Documents\D0700 - General Conditions.doc inspections, tests, and approvals that the results certified indicate compliance with, the Contract Documents, E. The limitations upon authority and responsibil- ity set forth in this paragraph 9.10 shall also apply to ENGINEER's Consultants, Resident Project Repre- sentative, and assistants. ARTICLE 10 - CHANGES IN THE WORK; CLAIMS 10.01 Authorized Changes in the Work A. Without invalidating the Agreement and without notice to any surety, OWNER may, at any time or from time to time, order additions, deletions, or revisions in the Work by a Written Amendment, a Change Order, or a Work Change Directive. Upon receipt of any such document, CONTRACTOR shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). B. If OWNER and CONTRACTOR are unable to agree on entitlement to, or on the amount or extent, if any, of an adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided in paragraph 10.05. 10.02 Unauthorized Changes in the Work A. CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in paragraph 3.04, except in the case of an emergency as provided in paragraph 6.16 or in the case of uncovering Work as provided in paragraph 13.04.13. 10.03 Execution of Change Orders A. OWNER and CONTRACTOR shall execute appropriate Change Orders recommended by ENGI- NEER (or Written Amendments) covering: 1. changes in the Work which are: (i) ordered by OWNER pursuant to paragraph 10.01.A, (ii) required because of acceptance of defective Work under paragraph 13.08.A or OWNER's correction of defective Work under paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by ENGINEER pursuant to paragraph 10.05; provided that, in lieu of executing any such Change Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract Documents and applicable Laws and Regula- tions, but during any such appeal, CONTRACTOR shall cant' on the Work and adhere to the progress schedule as provided in paragraph 6.18.A. 10.04 Notification to Surety A. If notice of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times) is required by the provisions of any Bond to be given to a surety, the giving of any such notice will be CONTRACTOR's responsibility. The amount of each applicable Bond will be adjusted to reflect the effect of any such change. 00700 - General Conditions 00700-30 FAEngineering\Petition PwAng\05221st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 10.05 Claims and Disputes A. Notice: Written notice stating the general nature of each Claim, dispute, or other matter shall be delivered by the claimant to ENGINEER and the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. Notice of the amount or extent of the Claim, dispute, or other matter with supporting data shall be delivered to the ENGINEER and the other party to the Contract within 60 days after the start of such event (unless ENGINEER allows additional time for claimant to submit additional or more accurate data in support of such Claim, dispute, or other matter). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of paragraph 12.01.B. A Claim for an adjustment in Contract Time shall be prepared in accordance with the provisions of paragraph 12.02.B. Each Claim shall be accom- panied by claimant's written statement that the adjust- ment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The opposing party shall submit any response to ENGINEER and the claimant within 30 days after receipt of the claimant's last submittal (unless ENGINEER allows additional time). B. ENGINEER's Decision: ENGINEER will render a formal decision in writing within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any. ENGINEER's written decision on such Claim, dispute, or other matter will be final and binding upon OWNER and CONTRACTOR unless: 1. an appeal from ENGINEER's decision is taken within the time limits and in accordance with the dispute resolution procedures set forth in Article 16; or 2, if no such dispute resolution procedures have been set forth in Article 16, a written notice of intention to appeal from ENGINEER's written decision is delivered by OWNER or CONTRACTOR to the other and to ENGINEER within 30 days after the date of such decision, and a formal proceeding is instituted by the appealing party in a forum of competent jurisdiction within 60 days after the date of such decision or within 60 days after Substantial Completion, whichever is later (unless otherwise agreed in writing by OWNER and CONTRACTOR), to exercise such rights or remedies as the appealing party may have with respect to such Claim, dispute, or other matter in accordance with applicable Laws and Regulations. C. If ENGINEER does not render a formal decision in writing within the time stated in paragraph 10.05.13, a decision denying the Claim in its entirety shall be deemed to have been issued 31 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any. D. No Claim for an adjustment in Contract Price or Contract Times (or Milestones) will be valid if not submitted in accordance with this paragraph 10.05. ARTICLE 11 - COST OF THE WORK; CASH ALLOWANCES; UNIT PRICE WORK 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sum of all costs necessarily incurred and paid by CONTRACTOR in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to CONTRACTOR will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by OWNER, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall include only the following items, and shall not include any of the costs itemized in para- graph 11.01.13. 1. Payroll costs for employees in the direct employ of CONTRACTOR in the perfor- mance of the Work under schedules of job classifications agreed upon by OWNER and CONTRACTOR. Such employees shall include without limitation superintendents, foremen, and other personnel employed full time at the Site. Payroll costs for employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits, which shall include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by OWNER. 00700 - General Conditions 00700-31 F:\EngineeringTetition Paving\0522 1sl Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 2. Cost of all materials and equipment furnished and incorporated in the Work, includ- ing costs of transportation and storage thereof, and Suppliers' field services . required in connection therewith. All cash discounts shall accrue to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with which to make payments, in which case the cash discounts shall accrue to OWNER. All trade discounts, rebates and refunds and returns from sale of surplus materials and equipment shall accrue to OWNER, and CONTRACTOR shall make provisions so that they may be obtained. 3. Payments made by CONTRACTOR to Subcontractors for Work performed by Subcontractors. If required by OWNER, COW TRACTOR shall obtain competitive bids from subcontractors acceptable to OWNER and CONTRACTOR and shall deliver such bids to OWNER, who will then determine, with the advice of ENGINEER, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same manner as CONTRACTOR's Cost of the Work and fee as provided in this para- graph 11.01. 4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the Work. 5. Supplemental costs including the following: a. The proportion of necessary trans- portation, travel, and subsistence expenses of CONTRACTOR's employees incurred in dis- charge of duties connected with the Work. b. Cost, including transportation and maintenance, of all materials, supplies, equip- ment, machinery, appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are consumed in the performance of the Work, and cost, less market value, of such items used but not con- sumed which remain the property of COW TRACTOR. C, Rentals of all construction equip- ment and machinery, and the parts thereof whether rented from CONTRACTOR or others in accordance with rental agreements approved by OWNER with the advice of ENGINEER, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs shall be in accordance with the terms of said rental agreements. The rental of any such equipment, machinery, or parts shall cease when the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work, and for which CONTRACTOR is liable, imposed by Laws and Regulations. e . Deposits lost for causes other than negligence of CONTRACTOR, any Sub- contractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. f. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sus- tained by CONTRACTOR in connection with the performance of the Work (except losses and damages within the deductible amounts of property insurance established in accordance with paragraph 5.06.D), provided such losses and damages have resulted from causes other than the negligence of CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include settlements made with the written consent and approval of OWNER. No such losses, damages, and expenses shall be included in the Cost of the Work for the purpose of determining CONTRACTOR's fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, expressage, and similar petty cash items in connection with the Work. i. When the Cost of the Work is used to determine the value of a Change Order or of a Claim, the cost of premiums for additional Bonds and insurance required because of the changes in the Work or caused by the event giving rise to the Claim. j. When all the Work is performed on the basis of cost-plus, the costs of premiums for all 00700 - General Conditions 00700-32 FAEngineeringTatifion Paving\0522 Ist Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditlons.doc Bonds and insurance CONTRACTOR is required by the Contract Documents to purchase and maintain. B. Costs Excluded. The term Cost of the Work shall not include any of the following items: 1. Payroll costs and other compensation of CONTRACTOR's officers, executives, princi- pals (of partnerships and sole proprietorships), general managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by CONTRACTOR, whether at the Site or in CONTRACTOR's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in paragraph 11.01.A.1 or specifically covered by paragraph 11.01.A.4, all of which are to be considered administrative costs covered by the CONTRACTOR's fee. 2. Expenses of CONTRACTOR's princi- pal and branch offices other than CONTRACTOR's office at the Site. 3. Any part of CONTRACTOR's capital expenses, including interest on CONTRACTOR's capital employed for the Work and charges against CONTRACTOR for delinquent payments. 4. Costs due to the negligence of CON- TRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 5. Other overhead or general expense costs of, any kind and the costs of any item not specifically and expressly included in paragraphs 11.01.A and 11.01.13. C. CONTRACTOR's Fee: When all the Work is performed on the basis of cost-plus, CONTRACTOR's fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, CONTRACTOR's fee shall be determined as set forth in paragraph 12.01.C. D. Documentation: Whenever the Cost of the Work for any purpose is to be determined pursuant to paragraphs 11.01.A and 11.01.6, CONTRACTOR will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to ENGINEER an itemized cost breakdown together with supporting data. 11.02 Cash Allowances A. It is understood that CONTRACTOR has in- cluded in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums as may be acceptable to OWNER and ENGINEER. CONTRACTOR agrees that: 1. the allowances include the cost to CONTRACTOR (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and 2. CONTRACTOR's costs for unloading and handling on the Site, labor, installation costs, overhead, profit, and other expenses contemplated for the allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. B. Prior to final payment, an appropriate Change Order will be issued as recommended by ENGINEER to reflect actual amounts due CONTRACTOR on account of Work covered by allowances, and the Con- tract Price shall be correspondingly adjusted. 11.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. The estimated quantities of items of Unit Price Work are not guaran- teed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Deter- minations of the actual quantities and classifications of Unit Price Work performed by CONTRACTOR will be made by ENGINEER subject to the provisions of paragraph 9.08. B. Each unit price will be deemed to include an amount considered by CONTRACTOR to be ade- 00700 - General Conditions 00700-33 FAEngineering\Petition Paving\0522 Ist Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc quate to cover CONTRACTOR's overhead and profit for each separately identified item. C. OWNER or CONTRACTOR may make a Claim for an adjustment in the Contract Price in accor- dance with paragraph 10.05 if: 1. the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and significantly from the estimated quantity of such item indicated in the Agreement; and 2, there is no corresponding adjustment with respect any other item of Work; and 3. if CONTRACTOR believes that CONTRACTOR is entitled to an increase in Contract Price as a result of having incurred additional expense or OWNER believes that OWNER is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 - CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES 12.01 Change of Contract Price A. The Contract Price may only be changed by a Change Order or by a Written Amendment. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the ENGINEER and the other party to the Contract in accordance with the provisions of para- graph 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: 1. where the Work involved is covered by unit prices contained in the Contract Documents, by application of such unit prices to the quantities of the items involved (subject to the provisions of paragraph 11.03 ); or 2. where the Work involved is not cov- ered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with paragraph 12.01.C.2); or 3. where the Work involved is not cov- ered by unit prices contained in the Contract Documents and agreement to a lump sum is not reached under paragraph 12.01.13.2, on the basis of the Cost of the Work (determined as provided in paragraph 11.01) plus a CONTRACTOR's fee for overhead and profit (determined as provided in paragraph 12.01.C). C. CONTRACTOR's Fee: The CONTRACTOR's fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. for costs incurred under para- graphs 11.01 A.1 and 11.01.A.2, the CONTRACTOR's fee shall be 15 percent; b. for costs incurred under paragraph 11.01.A.3, the CONTRACTOR's fee shall be five percent; c. where one or more tiers of subcon- tracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of paragraph 12.01.C.2.a is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under paragraphs 11.01.A.1 and 11.01.A.2 and that any higher tier Subcontractor. and CONTRACTOR will each be paid a fee of five percent of the amount paid to the next lower tier Subcon- tractor; d. no fee shall be payable on the basis of costs itemized under paragraphs 11.01.A.4, 11.01.A.5, and 11.01.13; e, the amount of credit to be allowed by CONTRACTOR to OWNER for any change which results in a net decrease in cost will be the amount of the actual net decrease in cost plus a deduction in CONTRACTOR's fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are involved in any one change, the adjustment in CONTRACTOR's fee shall be computed on the basis of the net change in accordance with paragraphs 12.01.C.2.a through 12.01.C.2.e, inclusive. 00700 - General Conditions 00700-34 FAEngineering\Petition Paving\05221st Rd. from 32nd Ave. to 35th Ave\ id Dowments\00700 - General Conditions.doc 12.02 Change of Contract Times A. The Contract Times (or Milestones) may only be changed by a Change Order or by a Written Amendment, Any Claim for an adjustment in the Contract Times (or Milestones) shall be based on written notice submitted by the party making the claim to the ENGINEER and the other party to the Contract in accordance with the provisions of paragraph 10.05. B. Any adjustment of the Contract Times (or Milestones) covered by a Change Order or of any Claim for an adjustment in the Contract Times (or Milestones) will be determined in accordance with the provisions of this Article 12. 12.03 Delays Beyond CONTRACTOR's Control A. Where CONTRACTOR is prevented from completing any part of the Work within the Contract Times (or Milestones) due to delay beyond the control of CONTRACTOR, the Contract Times (or Milestones) will be extended in an amount equal to the time lost due to such delay if a Claim is made therefor as provided in paragraph 12.02.A. Delays beyond the control of CONTRACTOR shall include, but not be limited to, acts or neglect by OWNER, acts or neglect of utility owners or other contractors performing other work as contemplated by Article 7, fires, floods, epidemics, abnormal weather conditions, or acts of God. 12.04 Delays Within CONTRACTOR's Control A. The Contract Times (or Milestones) will not be extended due to delays within the control of CONTRACTOR. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of CONTRAC- TOR. 12.05 Delays Beyond OWNER's and CONTRACTOR's Control A. Where CONTRACTOR is prevented from completing any part of the Work within the Contract Times (or Milestones) due to delay beyond the control of both OWNER and CONTRACTOR, an extension of the Contract Times (or Milestones) in an amount equal to the time lost due to such delay shall be CONTRACTOR's sole and exclusive remedy for such delay. 12.06 Delay Damages A. In no event shall OWNER or ENGINEER be liable to CONTRACTOR, any Subcontractor, any Supplier, or any other person or organization, or to any surety for or employee or agent of any of them, for damages arising out of or resulting from: 1. delays caused by or within the control of CONTRACTOR; or 2, delays beyond the control of both OWNER and CONTRACTOR including but not limited to fires, floods, epidemics, abnormal weather conditions, acts of God, or acts or neglect by utility owners or other contractors performing other work as contemplated by Article 7. B. Nothing in this paragraph 12.06 bars a change in Contract Price pursuant to this Article 12 to compensate CONTRACTOR due to delay, interference, or disruption directly attributable to actions or inactions of OWNER or anyone for whom OWNER is responsible. ARTICLE 13 - TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.01 Notice of Defects A. Prompt notice of all defective Work of which OWNER or ENGINEER has actual knowledge will be given to CONTRACTOR. All defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to Work A. OWNER, ENGINEER, ENGINEER's Con- sultants, other representatives and personnel of OWNER, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspecting, and testing. CONTRACTOR shall provide them proper and safe conditions for such access and advise them of CONTRACTOR's Site safety procedures and programs so that they may comply therewith as applicable. 13.03 Tests and Inspections A. CONTRACTOR shall give ENGINEER timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. 00700 - General Conditions 00700-35 FAEngineeringTetition Paving\05221st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc - .. - .. 101 Aw" C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, CONTRACTOR shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish ENGINEER the required certificates of inspec- tion or approval. D. CONTRACTOR shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for OWNER's and ENGINEER's acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to CONTRACTOR's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to OWNER and ENGINEER. E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by COW TRACTOR without written concurrence of ENGI- NEER, it must, if requested by ENGINEER, be uncov- ered for observation. F. Uncovering Work as provided in paragraph 13.03.E shall be at CONTRACTOR's expense unless CONTRACTOR has given ENGINEER timely notice of CONTRACTOR's intention to cover the same and ENGINEER has not acted with reasonable prompt- ness in response to such notice. 13.04 Uncovering Work A. If any Work is covered contrary to the written request of ENGINEER, it must, if requested by ENGI- NEER, be uncovered for ENGINEER's observation and replaced at CONTRACTOR's expense. B. If ENGINEER considers it necessary or advisable that covered Work be observed by ENGI- NEER or inspected or tested by others, CONTRAC- TOR, at ENGINEER's request, shall uncover, expose, or otherwise make available for observation, inspec- tion, or testing as ENGINEER may require, that portion of the Work in question, furnishing all neces- sary labor, material, and equipment. If it is found that such Work is defective, CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observa- tion, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and OWNER shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, OWNER may make a Claim therefor as provided in paragraph 10.05. If, however, such Work is not found to be defective, CONTRACTOR shall be allowed an increase in the Contract Price or an extension of the Contract Times (or Milestones), or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. 13.05 OWNER May Stop the Work 101 Aw" C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, CONTRACTOR shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish ENGINEER the required certificates of inspec- tion or approval. D. CONTRACTOR shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for OWNER's and ENGINEER's acceptance of materials or equipment to be incorporated in the Work; or acceptance of materials, mix designs, or equipment submitted for approval prior to CONTRACTOR's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to OWNER and ENGINEER. E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by COW TRACTOR without written concurrence of ENGI- NEER, it must, if requested by ENGINEER, be uncov- ered for observation. F. Uncovering Work as provided in paragraph 13.03.E shall be at CONTRACTOR's expense unless CONTRACTOR has given ENGINEER timely notice of CONTRACTOR's intention to cover the same and ENGINEER has not acted with reasonable prompt- ness in response to such notice. 13.04 Uncovering Work A. If any Work is covered contrary to the written request of ENGINEER, it must, if requested by ENGI- NEER, be uncovered for ENGINEER's observation and replaced at CONTRACTOR's expense. B. If ENGINEER considers it necessary or advisable that covered Work be observed by ENGI- NEER or inspected or tested by others, CONTRAC- TOR, at ENGINEER's request, shall uncover, expose, or otherwise make available for observation, inspec- tion, or testing as ENGINEER may require, that portion of the Work in question, furnishing all neces- sary labor, material, and equipment. If it is found that such Work is defective, CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observa- tion, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and OWNER shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount thereof, OWNER may make a Claim therefor as provided in paragraph 10.05. If, however, such Work is not found to be defective, CONTRACTOR shall be allowed an increase in the Contract Price or an extension of the Contract Times (or Milestones), or both, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. 13.05 OWNER May Stop the Work 00700 • General Conditions 00700-36 FAEngineering\Petitlon Paving\0522 1st Rd. from 32nd Ave. to 35th Avid DocumentsX00700 - General Conditions.doc ..=Trwr.. - .. .. .. -• .- 00700 • General Conditions 00700-36 FAEngineering\Petitlon Paving\0522 1st Rd. from 32nd Ave. to 35th Avid DocumentsX00700 - General Conditions.doc 13.06 Correction or Removal of Defective Work A. CONTRACTOR shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by ENGI- NEER, remove it from the Project and replace it with Work that is not defective. CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or removal (including but not limited to all costs of repair or replacement of work of others). 13.07 Correction Period A. If within one year after the date of Substantial Completion or such longer period of time as may be prescribed by Laws or Regulations or by the terms of any applicable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made: available for CONTRACTOR's use by OWNER or permitted by Laws and Regulations as contemplated in paragraph 6.11.A is found to be defective, CONTRACTOR shall promptly, without cost to OWNER and in accordance with OWNER's written instructions: (i) repair such defective land or areas, or (ii) correct such defective Work or, if the defective Work has been rejected by OWNER, remove it from the Project and replace it with Work that is not defective, and (iii) satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others or other land or areas resulting there- from. If CONTRACTOR does not promptly comply with the terms of such instructions, or in an emergency where delay would cause serious risk of loss or damage, OWNER may have the defective Work corrected or repaired or may have the rejected Work removed and replaced, and all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others) will be paid by CONTRACTOR. B. In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications or by Written Amendment. C. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. D. CONTRACTOR's obligations under this paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this paragraph 13.07 shall not be construed as a substitute for or a waiver of the provisions of any applicable statute of limitation or repose. 13.08 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, OWNER (and, prior to ENGINEER's recommendation of final pay- ment, ENGINEER) prefers to accept it, OWNER may do so. CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to OWNER's evaluation of and determination to accept such defective Work (such costs to be approved by ENGINEER as to reasonableness) and the diminished value of the Work to the extent not otherwise paid by CONTRACTOR pursuant to this sentence. If any such acceptance occurs prior to ENGINEER's recom- mendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work, and OWNER shall be entitled to an appropriate decrease in the Contract Price, reflecting the diminished value of Work so accepted. If the parties are unable to agree as to the amount thereof, OWNER may make a Claim therefor as provided in paragraph 10.05. If the acceptance occurs after such recommendation, an appropriate amount will be paid by CONTRACTOR to OWNER. 13.09 OWNER May Correct Defective Work A. If CONTRACTOR fails within a reasonable time after written notice from ENGINEER to correct defective Work or to remove and replace rejected Work as required by ENGINEER in accordance with paragraph 13.06.A, or if CONTRACTOR fails to perform the Work in accordance with the Contract Documents, or if CONTRACTOR fails to comply with any other provision of the Contract Documents, OWNER may, after seven days written notice to CONTRACTOR, correct and remedy any such deficiency. 00700 - General Conditions 00700-37 FAEngineeringWetition Paving\0522 1st Rd. from 32nd Ave. to 35th AveWBid Documents\00700 - General Conditions.doc B. In exercising the rights and remedies under this paragraph, OWNER shall proceed expeditiously. In connection with such corrective and remedial action, OWNER may exclude CONTRACTOR from all or part of the Site, take possession of all or part of the Work and suspend CONTRACTOR's services related thereto, take possession of CONTRACTOR's tools, appliances, construction equipment and machinery at the Site, and incorporate in the Work all materials and equipment stored at the Site or for which OWNER has paid CONTRACTOR but which are stored elsewhere. CONTRACTOR shall allow OWNER, OWNER's representatives, agents and employees, OWNER's other contractors, and ENGINEER and ENGINEER's Consultants access to the Site to enable OWNER to exercise the rights and remedies under this paragraph. C. All Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by OWNER in exercising the rights and remedies under this paragraph,; 13.09 will be charged against CON- TRACTOR, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and OWNER shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, OWNER may make a Claim therefor as provided in paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of CONTRACTOR's defective Work. D. CONTRACTOR shall not be allowed an extension of the Contract Times (or Milestones) because of any delay in the performance of the Work attributable to the exercise by OWNER of OWNER's rights and remedies under this paragraph 13.09. ARTICLE 14 - PAYMENTS TO CONTRACTOR AND COMPLETION 14.01 Schedule of Values A. The schedule of values established as provid- ed in paragraph 2.07.A will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to ENGk NEER. Progress payments on account of Unit Price Work will be based on the number of units completed. 14.02 Progress Payments A. Applications for Payments 1. At least 20 days before the date established for each progress payment (but not more often than once a month), CONTRACTOR shall submit to ENGINEER for review an Application for Payment filled out and signed by CONTRACTOR covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other documentation warranting that OWNER has received the materials and equip- ment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect OWNER's interest therein, all of which must be satisfactory to OWNER. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of CONTRACTOR stating that all previous progress payments received on account of the Work have been applied on account to discharge CONTRACTOR's legitimate obligations associated with prior Applications for Payment. 3. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. B. Review of Applications 1. ENGINEER will, within 10 days after receipt of each Application for Payment, either indicate in writing a recommendation of payment and present the Application to OWNER or return the Application to CONTRACTOR indicating in writing ENGINEER's reasons for refusing to recommend payment. In the latter case, CON- TRACTOR may make the necessary corrections and resubmit the Application. 2. ENGINEER's recommendation of any payment requested in an Application for Payment will constitute a representation by ENGINEER to OWNER, based on 00700 - General Conditions 00700-38 FAEngineeringTatition Paving\0522 1st Rd. from 32nd Ave. to 35th Av"Id DOcuments\007D0 - General Conditions.doc ENGINEER's observations on the Site of the executed Work as an experienced and qualified design professional and on ENGINEER's review of the Application for Payment and the accompanying data and schedules, that to the best of ENGINEER's knowledge, information and belief: a. the Work has progressed to the point indicated; b. the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contract Documents, to a final determination of quantities and classifications for Unit Price Work under paragraph 9.08, and to any other qualifications stated in the recommendation); and c. The conditions precedent to CONTRACTOR's being entitled to such payment appear to have been fulfilled in so far as it is ENGINEER Is responsibility to observe the Work. 3. By recommending any such payment ENGINEER will not thereby be deemed to have represented that: (1) inspec- tions made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsi- bilities specifically assigned to ENGINEER in the Contract Documents; or (ii) that there may not be other matters or issues between the parties that might entitle CONTRACTOR to be paid additionally by OWNER or entitle OWNER to withhold payment to CONTRACTOR. 4. Neither ENGINEER's review of CONTRACTOR's Work for the purposes of recommending payments nor ENGINEER's recommendation of any payment, including final payment, will impose responsibility on ENGINEER to supervise, direct, or control the Work or for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for CONTRACTOR's failure to comply with Laws and Regulations applicable to CONTRACTOR's performance of the Work. Additionally, said review or recommendation will not impose responsibility on ENGINEER to make any examination to ascertain how or for what purposes CONTRACTOR has used the moneys paid on account of the Contract Price, or to determine that title to any of the Work, materials, or equipment has passed to OWNER free and clear of any Liens. 5. ENGINEER may refuse to recom- mend the whole or any part of any payment if, in ENGINEER's opinion, it would be incorrect to make the representations to OWNER referred to in paragraph 14.02.13.2. ENGINEER may also refuse to recommend any such payment or, because of subsequently discovered evidence or the results of subsequent inspections or tests, revise or revoke any such payment recommendation previously made, to such extent as may be necessary in ENGINEER's opinion to protect OWNER from loss because: a. the Work is defective, or completed Work has been damaged, requiring correction or replacement; b. the Contract Price has been reduced by Written Amendment or Change Orders; c. OWNER has been required to correct defective Work or complete Work in accor- dance with paragraph 13.09; or C. Payment Becomes Due D. Reduction in Payment 1. OWNER may refuse to make payment of the full amount recommended by ENGINEER because: a. claims have been made against OWNER on account of CONTRACTOR's performance or furnishing of the Work; b. Liens have been filed in connection with the Work, except where CONTRACTOR has delivered a specific 00700 _ General Conditions 00700-39 F:\Engineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc .. - .. ,in ronplgr - - - ._ In I -WILT Tollin... - .. . in D. Reduction in Payment 1. OWNER may refuse to make payment of the full amount recommended by ENGINEER because: a. claims have been made against OWNER on account of CONTRACTOR's performance or furnishing of the Work; b. Liens have been filed in connection with the Work, except where CONTRACTOR has delivered a specific 00700 _ General Conditions 00700-39 F:\Engineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc Bond satisfactory to OWNER to secure the satisfaction and discharge of such Liens; c. there are other items entitling OWN- ER to a set-off against the amount recommended; or d. OWNER has actual knowledge of the occurrence of any of the events enumerated in paragraphs 14.02.B.5.a through 14.02.B.5.c or paragraph 15.02.A. 2, If OWNER refuses to make payment of the full amount recommended by ENGINEER, OWNER must give CONTRACTOR immediate written notice (with a copy to ENGINEER) stating the reasons for such action and promptly pay CONTRACTOR any amount remaining after deduction of the amount so withheld. OWNER shall promptly pay CONTRACTOR the amount so withheld, or any adjustment thereto agreed to by OWNER and CONTRACTOR, when CONTRACTOR corrects to OWNER's satisfaction the reasons for such laction, 3. If it is subsequently determined that OWNER's refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by paragraph 14.02.C.1. 14.03 CONTRACTOR's Warranty of Title A. CONTRACTOR warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to OWNER no later than the time of payment free and clear of all Liens. 00700 - General Conditions 00700-40 FAEnginseringTatition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 14.04 Substantial Completion • •- •- - - • •MIT• • - . .-- ITT Rio • 1 1 rim - ` IMI 1 .. ■,ITT NII A AM a ramp as A MI a ■ - ■. ■_ ■TI 1IIIIITTAMTM I—"'. AMA—A�Alft ATI M I n1i sDJWrM WdhTal. ■- rMAITATA N 144 - ■. -. �-- APIA a 1111P ■ -a AN■ki IN 111 AII CIS AT An .. . B. OWNER shall have the right to exclude CONTRACTOR from the Site after the date of Substantial Completion, but OWNER shall allow CON- TRACTOR reasonable access to complete or correct items on the tentative list. 14.05 Partial Utilization A. Use by OWNER at OWNER's option of any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which OWNER, ENGINEER, and CONTRACTOR agree constitutes a separately functioning and usable part of the Work that can be used by OWNER for its intended purpose without significant interference with CONTRACTOR's performance of the remainder of the Work, may be accomplished prior to Substantial Completion of all the Work subject to the following conditions. 1. OWNER at any time may request CONTRACTOR in writing to permit OWNER to use any such part of the Work which OWNER believes to be ready for its intended use and substantially complete. If CONTRACTOR agrees that such part of the Work is substantially complete, CONTRACTOR will certify to OWNER and ENGINEER that such part of the Work is substantially complete and request ENGINEER to issue a certificate of Substantial Completion for that part of the Work. CONTRACTOR at any time may notify OWNER and ENGINEER in writing that CONTRACTOR considers any such part of the Work ready for its intended use and substan- tially complete and request ENGINEER to issue a certificate of Substantial Completion for that part of the Work. Within a reasonable time after either such request, OWNER, CONTRACTOR, and ENGINEER shall make an inspection of that part of the Work to determine its status of completion. If ENGINEER does not consider that part of the Work to be substantially complete, ENGINEER will notify OWNER and CONTRACTOR in writing giving the reasons therefor. If ENGINEER considers that part of the Work to be substantially complete, the provisions of paragraph 14.04 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 2. No occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of paragraph 5.10 regarding property insurance. 00700 - General Conditions 00700 - 41 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bld Doaments\00700 IT General Conditions.doc 14.06 Final Inspection A. Upon written notice from CONTRACTOR that the entire Work or an agreed portion thereof is complete, ENGINEER will promptly make a final inspection with OWNER and CONTRACTOR and will notify CONTRACTOR in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. CONTRACTOR shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 14.07 Final Payment A. Application for Payment 1. After CONTRACTOR has, in the opinion of ENGINEER, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guaran- tees, Bonds, certificates or other evidence of insurance certificates of inspection, marked -up record documents (as provided in paragraph 6.12), and other documents, CONTRACTOR may make application for final payment follow- ing the procedure for progress payments. 2. The final Application for Payment shall be accompanied (except as previously delivered) by: (i) all documentation called for in the Contract Documents, including but not limited to the evidence of insurance required by subparagraph 5.04.13.7; (ii) consent of the surety, if any, to final payment; and (iii) complete and legally effective releases or waivers (satisfactory to OWNER) of all Lien rights arising out of or Liens filed in connection with the Work. 3. In lieu of the releases or waivers of Liens specified in paragraph 14.07.A.2 and as approved by OWNER, CONTRACTOR may furnish receipts or releases in full and an affidavit of CONTRACTOR that: (i) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (ii) all' payrolls, material and equipment bills, and other indebtedness connected with the Work for which OWNER or OWNER's property might in any way be responsible have been paid or otherwise satis- fied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, COW TRACTOR may furnish a Bond or other collateral satisfactory to OWNER to indemnify OWNER against any Lien. B. Review of Application and Acceptance 1. If, on the basis of ENGINEER's observation of the Work during construction and final inspection, and ENGINEER's review of the final Application for Payment and accompanying documentation as required by the Contract Documents, ENGINEER is satisfied that the Work has been completed and CONTRACTOR's other obligations under the Contract Documents have been fulfilled, ENGINEER will, within ten days after receipt of the final Application for Payment, indicate in writing ENGINEER's recommendation of payment and present the Application for Payment to OWNER for payment. At the same time ENGINEER will also give written notice to OWNER and CONTRACTOR that the Work is acceptable subject to the provisions of paragraph 14.09. Otherwise, ENGINEER will return the Application for Payment to CONTRACTOR, indicating in writing the reasons for refusing to recommend final payment, in which case CONTRACTOR shall make the necessary corrections and resubmit the Application for Payment. C. Payment Becomes Due 14.08 Final Completion Delayed A. If, through no fault of CONTRACTOR, final completion of the Work is significantly delayed, and if ENGINEER so confirms, OWNER shall, upon receipt of CONTRACTOR's final Application for Payment and recommendation of ENGINEER, and without terminat- ing the Agreement, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by OWNER for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if Bonds have been furnished as required in paragraph 5.019 the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by CONTRACTOR to ENGINEER with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. 00700 - General Conditions 00700-42 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc - . • 1N• _ M MWAIT&T - .TF -IMMMIT. 14.08 Final Completion Delayed A. If, through no fault of CONTRACTOR, final completion of the Work is significantly delayed, and if ENGINEER so confirms, OWNER shall, upon receipt of CONTRACTOR's final Application for Payment and recommendation of ENGINEER, and without terminat- ing the Agreement, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by OWNER for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if Bonds have been furnished as required in paragraph 5.019 the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by CONTRACTOR to ENGINEER with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. 00700 - General Conditions 00700-42 FAEngineering\Petition Paving\0522 1st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc 14.09 Waiver of Claims A. The making and acceptance of final payment will constitute: 1. a waiver of all Claims by OWNER against CONTRACTOR, except Claims arising from unsettled Liens, from defective Work appearing after final inspection pursuant to paragraph 14.06, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or from CONTRACTOR's continuing obligations under the Contract Documents; and 2, a waiver of all Claims by CONTRAC- TOR against OWNER other than those previously made in writing which are still unsettled. ARTICLE 15 - SUSPENSION OF WORK AND TERMINATION 15.01 OWNER May Suspend Work RENOIR 2 - - - -•- MIR NINO - . 14 111 d �� .� - .. 15.02 OWNER May Terminate for Cause A. The occurrence of any one or more of the following events will justify termination for cause: 1. CONTRACTOR's persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment or failure to adhere to the progress schedule established under paragraph 2.07 as adjusted from time to time pursuant to paragraph 6.04); 2. CONTRACTOR's disregard of Laws or Regulations of any public body having jurisdiction; 3. CONTRACTOR's disregard of the authority of ENGINEER; or 4. CONTRACTOR's violation in any substantial way of any provisions of the Contract Documents. B. If one or more of the events identified in paragraph 15.02.A occur, OWNER may, after giving CONTRACTOR (and the surety, if any) seven days written notice, terminate the services of CONTRACTOR, exclude CONTRACTOR from the Site, and take possession of the Work and of all CONTRACTOR's tools, appliances, construction equipment, and machinery at the Site, and use the same to the full extent they could be used by CONTRACTOR (without liability to CONTRACTOR for trespass or conversion), incorporate in the Work all materials and equipment stored at the Site or for which OWNER has paid CONTRACTOR but which are stored elsewhere, and finish the Work as OWNER may deem expedient. In such case, CONTRACTOR shall not be entitled to receive any further payment until the Work is finished. If the unpaid balance of the Contract Price exceeds all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by OWNER arising out of or relating to completing the Work, such excess will be paid to CONTRACTOR. If such claims, costs, losses, and damages exceed such unpaid balance, CONTRACTOR shall pay the difference to OWNER. Such claims, costs, losses, and damages incurred by OWNER will be reviewed by ENGINEER as to their reasonableness and, when so approved by ENGINEER, incorporated in a Change Order. When exercising any rights or remedies under this paragraph OWNER shall not be required to obtain the lowest price for the Work performed. C. Where CONTRACTOR's services have been so terminated by OWNER, the termination will not affect any rights or remedies of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys due CONTRACTOR by OWNER will not release CON- TRACTOR from liability. 15.03 OWNER May Terminate For Convenience A. Upon seven days written notice to CON- TRACTOR and ENGINEER, OWNER may, without cause and without prejudice to any other right or remedy of OWNER, elect to terminate the Contract. In such case, CONTRACTOR shall be paid (without duplication of any items): 00700-43 00700 - General Conditions FAEngineering\Petition Paving\0522 1 st Rd. from 32nd Ave. to 35th Ave\Bid Documents100700 - General Conditions.doc 1. for completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums for overhead and profit on such Work; 2, for expenses sustained prior to the effective date of termination in performing services and furnishing labor, materials, or equipment as required by the Contract Documents in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 3, for all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) in- curred in settlement of terminated contracts with Subcontractors, Suppliers, and others; and 4, for reasonable expenses directly attributable to termination. B. CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other eco- nomic loss arising out of or resulting from such termination. 15.04 CONTRACTOR May Stop Work or Terminate A. If, through no act or fault of CONTRACTOR, the Work is suspended for more than 90 consecutive days by OWNER or under an order of court or other public authority, or ENGINEER fails to act on any Application for Payment within 30 days after it is submitted, TRACTOR any sum finally datarmORAd to be due, then CONTRACTOR may, upon seven days written notice to OWNER and ENGINEER, and provided OWNER or ENGINEER do not remedy such suspension or failure within that time, terminate the Contract and recover from OWNER payment on the same terms as provided in paragraph 15.03. In lieu of terminating the Contract and without prejudice to any other right or remedy, if ENGINEER has failed to act on an Application for Payment within 30 days after it is submitted, 9F OWNER hals, falle-al far 30 days to pay CONTRACTOR may, seven days after written notice to OWNER and ENGINEER, stop the Work until payment is made of all such amounts due CONTRACTOR, including interest thereon. The provisions of this paragraph 15.04 are not intended to preclude CONTRACTOR from making a Claim under paragraph 10.05 for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to CONTRACTOR's stopping the Work as permitted by this paragraph. ARTICLE 16 - DISPUTE RESOLUTION 16.01 Methods and Procedures A. Dispute resolution methods and procedures, if any, shall be as set forth in the Supplementary Conditions. If no method and procedure has been set forth, and subject to the provisions of paragraphs 9.09 and 10.05, OWNER and CONTRACTOR may exercise such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any dispute. ARTICLE 17 - MISCELLANEOUS 17.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or if delivered at or sent by registered or certified mail, postage prepaid, to the last business address known to the giver of the notice. 17.02 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. 17.03 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies avail- able hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents, and the provisions of this paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each 00700 - General Conditions 00700-44 FAEngineeringTatition Paving\05221st Rd. from 32nd Ave. to 35th AvetBid Documentst00700 - General Condltions.doc particular duty, obligation, right, and remedy to which they apply. 17.04 Survival of Obligations A. All representations, indemnifications, warran- ties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or comple- tion of the Agreement. 17.05 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 00700 - General Conditions 00700-45 FAEngineering\Petition Paving\0522 1 st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00700 - General Conditions.doc SECTION 00800 = SUPPLEMENTARY CONDITIONS TO THE GENERAL CONDITIONS Article Title Introduction Defined Terms Before Starting Construction Preconstruction Conference Coordination of Plans, Specifications, and Special Provisions Subsurface and Physical Conditions Performance, Payment and Other Bonds Certificates of Insurance CONTRACTOR'S Liability Insurance OWNER'S Liability Insurance Property Insurance Waiver of Rights Receipt and Application of Insurance Proceeds Labor; Working Hours Permits Taxes Test and Inspections Progress Payments Mediation Arbitration Liens Article Number SC - 1.00 SC —1.01 SC —2.05 SC — 2.06 SC — 3.06 SC — 4.02 SC — 5.01 SC — 5.03 SC — 5.04 SC — 5.05 SC — 5.06 SC — 5.07 SC — 5.08 SC — 6.02 SC — 6.06 SC — 6.10 SC —13.03 SC —14.02 SC —16.02 SC —16.03 SC —17.06 008004 00800 - Supplementary Conditions IN 11J L �fn�J L..- /- OL1l /�..-\OtJ /� .. ♦-\I\/\OI\n P.. 1 � ♦ .nom -l:♦' J ^^Q^n iG.�r__ tn�<`♦' n�.L�tnGnn CTION 00800 ED GENERAL CONDITIONS SC -1.00 Introduction TO These Supplementary Conditions amend or supplement the Standard General Conditions of the Construction Contract (No. 1910-8, 1996 Edition) and other provisions of the Contract Documents as indicated below. All provisions, which are not so amended or supplemented, remain in full force and effect. The terms used in these Supplementary Conditions will have the meanings indicated in the General Conditions. SC -1.01 Defined Terms SC -1.01.A.20. Delete paragraph GC 1.01.A.20 in its entirety. SC -1.02 Terminology SC -1.02.D.1, 2, and 3 Delete paragraphs GC -1.02.D.1, 2, and 3 in their entirety and insert the following paragraphs in their place: D. Furnish, Install, Perform, Provide 1. The word "furnish" shall mean to supply and deliver services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install' shall mean to put into use or place in final position services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide" shall mean to furnish and install services, materials, or equipment complete and ready for intended use. SC -2.05 Before Starting Construction SC -2.05.C. Delete paragraph GC 2.05.0 in its entirety and insert the following paragraph in its place: C. Evidence of Insurance: CONTRACTOR shall not commence work under this Contract until he has obtained all insurance required under Article 5 and such insurance has been delivered to the OWNER and approved by the OWNER, nor shall the CONTRACTOR allow any Subcontractor to commence work on his subcontract until all similar insurance required of the Subcontractor has been so obtained and approved. All such insurance shall remain in effect until final payment and at all times thereafter when CONTRACTOR may be correcting, removing or replacing defective Work in accordance with Article 13. SC -2.06 Preconstruction Conference SC -2.06 Delete paragraph GC -2.06.A in its entirety and insert the following paragraph in its place: A. Immediately after awarding the contract, but before the CONTRACTOR begins work, the Construction Coordination Manager will call a preconstruction conference at a place the ENGINEER designates to establish an understanding among the parties as to the work and to discuss schedules referred to in oosoo-1 0woo - suppiementary Conditions 00800 1 F.\Engineering\PeUtlon Paving\0522 tat Rd. from 32nd Ave. to 35th Ave\Bld Documents\0081)0 - Supplementary Conditions.doc paragraph 2.05.13, procedures for handling Shop Drawings and other submittals, and maintaining required records. Utility companies and others as appropriate will be requested to attend to discuss and coordinate work. SC -3.06 Coordination of Plans, Specifications, and Special Provisions SC -3.06 Add the following new paragraphs immediately after paragraph GC -3.05: SC -3.06 Coordination of Plans, Specifications, and Special Provisions A. In case of discrepancy, the governing order of the documents shall be as follows: 1. Written Interpretations 2, Addenda 3. Specifications 4, Supplementary Conditions to the General Conditions 5. General Conditions 6, Approved Shop Drawings 7. Drawings 8. Referenced Standards. B. Written/computed dimensions shall govern over scaled dimensions. SC -4.02 Subsurface and Physical Conditions SC -4.02 Add the following new paragraphs immediately after paragraph GC -4.02.8: C. In the preparation of Drawings and Specifications, ENGINEER or ENGINEER's Consultants relied upon the following reports of explorations and tests of subsurface conditions at the Site: 1. Roadway Soil Survey —1St Road from 35th Avenue to 32nd Avenue dated and 10th Court SW from Oslo Road to 7th Street SW dated 11/27/2007 D. Reports and drawings itemized in SC4.02.0 are not included with the Bidding Documents. Copies may be examined at Indian River County Administration Building, Public Works, 1801 27th Street Vero Beach FL 32960 during regular business hours. These reports and drawings are not part of the Contract Documents, SC -5.01 Performance, Payment and Other Bonds SC -5.01.A. Delete paragraph GC -5.01.A in its entirety and insert the following paragraphs in its place: A. Within ten (10) days of receipt of the Contract Documents for execution, the CONTRACTOR shall furnish a Performance Bond in an amount equal to 100% of the Contract Price and a Payment Bond in an amount equal to 100% of the Contract Price. 1. The CONTRACTOR shall provide two separate bonds. A combined Payment and Performance Bond for 125% of the Contract Price is not an acceptable substitute. _ 2. In lieu of the Performance and Payment Bonds, the CONTRACTOR may furnish an alternative form of security in the form of cash, money order, certified check, cashier's check, irrevocable letter of credit or a security as listed in Part II of F.S. Chapter 625. Any such alternative form of security shall be for the same purpose, and be for the same amount and subject 00800-2 to the same conditions as those applicable to the bond otherwise required. The determination of the value of an alternative form of security shall be made by the OWNER. 3, Such Bonds shall continue in effect for one (1) year after acceptance of the Work by the OWNER. 4. The CONTRACTOR shall record, the Payment Bond and the Performance Bond with the Public Record Section of the Indian River County Courthouse located at 2000 16th Avenue, Vero Beach, Florida 32960. The recorded bonds shall be forwarded to the Indian River County Purchasing Division on or before the seventh day after they are recorded. The CONTRACTOR shall pay all costs. SC -5.03 Certificates of Insurance SC -5.03 Delete the second sentence of paragraph GC -5.03 in its entirety. SC -5.04 CONTRACTOR's Liability Insurance SC -5.04 Add the following new paragraphs immediately after paragraph GC -5.04.6: Co The limits of liability for the insurance required by paragraph 5.04 of the General Conditions shall provide coverage for not less than the following amounts or greater where required by Laws and Regulations: 1. Worker's Compensation: To meet statutory limits in compliance with the Worker's Compensation Law of Florida. This policy must include Employer Liability with a limit $100,000 for each accident, $500,000 disease (policy limit) and $100,000 disease (each employee). Such policy shall include a waiver of subrogation as against OWNER -and ENGINEER on account of injury sustained by an employee(s) of the CONTRACTOR. 2. Commercial General Liability: Coverage shall provide minimum limits of liability of $1,000,000 per occurrence Combined Single Limit for Bodily Injury and Property Damage. This shall include coverage for: a. Premises/Operations b. Products/Completed Operations C, Contractual Liability d. Independent Contractors e. Explosion f. Collapse g. Underground. 3. Business Auto Liability: Coverage shall provide minimum limits of liability of $1,000,000 per occurrence Combined Single Limit for Bodily Injury and Property Damage. This shall include coverage for: a. Owner Autos b. Hired Autos c. Non -Owned Autos. 4. CONTRACTOR's "All Risk" Insurance: CONTRACTOR shall secure Builders' Risk "All Risk" insurance at his expense and provide properly completed and executed "Certificates of Insurance and Insurance Endorsement" forms in the exact wording and format presented in these Contract Documents before starting work. 5. Special Requirements: a. Ten (10) days prior to the commencement of any work under this Contract, certificates of insurance and endorsement forms in the exact wording and format as presented in these Contract 00800-3 00800 - Supplementary conditions nnonn 9-.+. __+___--an-ac-- n-.a-.anenn 4-4 MA s.-... OO..A A% j^ 1.. 7FIb e..e\Girl I1nn u.wMa\M1RM1 _ CunnlunwMsn. (`nndllinne fir Documents will be provided to the OWNER's Risk Manager for review and approval. b. "Indian 'River County Florida" will be named as "Additional Insured" on both the General Liability, Auto Liability and Builder's Risk "All Risk" Insurance. C, The OWNER will be given thirty (30) days notice prior to cancellation or modification of any stipulated insurance. Such notification will be in writing by registered mail, return receipt requested and addressed to the OWNER's Risk Manager. d. An appropriate "Indemnification" clause shall be made a provision of the Contract (see paragraph 6.20 of the General Conditions). e. It is the responsibility of the CONTRACTOR to insure that all subcontractors comply with all insurance requirements. f. It should be remembered that these are minimum requirements, which are subject to modification in response to high hazard operation. g. Insured must be authorized to do business and have an agent for service of process in Florida and have an AAA policyholder's rating and financial rating of a least Class XI in accordance with the most current Best's Rating. D. Additional Insureds: 1. In addition to "Indian River County, Florida," the following individuals or entities shall be listed as "additional insureds" on the CONTRACTOR's liability insurance policies: a. NONE b. C, SC -5.05 OWNER's Liability Insurance SC -5.05 Delete paragraph GC -5.05.A in its entirety. SC -5.06 Property Insurance SC -5.06 Delete paragraphs GC -5.06.A, B, and C in their entirety and insert the following paragraphs in their place: A. CONTRACTOR shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof. This insurance shall: 1. include the interests of OWNER, CONTRACTOR, Subcontractors, ENGINEER, ENGINEER's Consultants and any other individuals or entities identified in the Supplementary Conditions, and the officers, directors, partners, employees, agents and other consultants and subcontractors of any of them each of whom is deemed to have an insurable interest and shall be listed as an insured or additional insured; 2. be written on a Builder's Risk "All Risk" or open peril or special causes of loss policy form that shall at least include insurance for physical loss and damage to the Work, temporary buildings, falsework, and materials and equipment in transit and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, 00800-4 00800 - Supplementary conditions 00800 4FAEngineering\Petition Paving\05221st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00800 - Supplementary Conditions.doc water damage, and such other perils or causes of loss as may be specifically required by the Supplementary Conditions. 3, include expenses incurred in the repair or replacement of any insured property (including but not limited to fees and charges of engineers and architects); 4, cover materials and equipment stored at the Site or at another location that was agreed to in writing by OWNER prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by ENGINEER; and 5, allow for partial utilization of the Work by OWNER; 6. include testing and startup; and 7. be maintained in effect until final payment is made unless otherwise agreed to in writing by OWNER, CONTRACTOR and ENGINEER with 30 days written notice to each other additional insured to whom a certificate of insurance has been issued. B. CONTRACTOR shall be responsible for any deductible or self-insured retention. C. The policies of insurance required to be purchased and maintained by CONTRACTOR in accordance with this paragraph SC -5.06 shall comply with the requirements of paragraph 5.06.0 of the General Conditions, SC -5.06.E Delete paragraph GC -5.06.E in its entirety and insert the following in its place: E. Additional Insureds: 1. The following individuals or entities shall be CONTRACTOR's property insurance policies: a. Indian River County, Florida b. NONE C, SC -5.07 Waiver of Rights listed as "additional insureds" on the SC -5.07 Delete GC -5.07 (paragraphs A. B. and C) in its entirety. SC -5.08 Receipt and Application of Insurance Proceeds SC -5.08 Delete GC -5.08 (paragraphs A and B) in its entirety. SCm5.09 Delete (paragraph A) SC -6.02 Labor; Working Hours SC -6.02.13. Add the following paragraphs immediately after paragraph GC -6.02.8: 1. Regular working hours are defined as Monday through Friday, excluding Indian River County Holidays, from 7 a.m. to 5 p.m. 2. Indian River County Holidays are: New Year's Day, Good Friday, Memorial Day, Independence Day, Labor Day, Veterans Day, Thanksgiving Day, Friday after Thanksgiving, Christmas Eve and Christmas Day. Working on these days will not be permitted without prior written permission and approval from the 00800-5 00800 - Supplementary Conditions 1�f DA f m %03 4 Aum Avn\RLI n^n 4 nenfw%AnQnn _ SnnMmmen,an. (.nndMinnc Ar Construction Coordination Manager. 3. The CONTRACTOR shall receive no additional compensation for overtime work, i.e., work in excess of eight hours in any one calendar day or 40 hours in any one calendar week, even though such overtime work may be required under emergency conditions and may be ordered by the ENGINEER in writing. 4. All costs of inspection and testing performed during overtime work by the CONTRACTOR, which is allowed solely for the convenience of the CONTRACTOR, shall be borne by the CONTRACTOR, and a credit given to the OWNER to deduct the costs of all such inspection and testing from any payments otherwise due the CONTRACTOR. 5. All costs of OWNER Is employees and costs of ENGINEER's Consultant resulting from overtime work by the CONTRACTOR, which is allowed solely for the convenience of the CONTRACTOR, shall be borne by the CONTRACTOR, and a credit given to OWNER to deduct all such costs from any payments otherwise due the CONTRACTOR. 6. No work shall commence before 7 a.m. or continue after 7 p.m. except in case of emergency upon specific permission of the ENGINEER. SC4.06 Concerning Subcontractors, Suppliers, and Others SC -6.06.C. Add the following sentence at the end of paragraph GC -6.06. C: OWNER or ENGINEER may furnish to any such Subcontractor, Supplier, or other individual or entity, to the extent practicable, information about amounts paid to CONTRACTOR on account of Work performed for CONTRACTOR by a particular Subcontractor, Supplier, or other individual or entity. SC -6.08 Permits SC -6.08 Add the following paragraphs immediately after paragraph GC -6.08.A: B. The OWNER has obtained the following permits (copies of these permits are contained in Appendix "A"): 1. St. Johns River Water Management District - Permit No's. 42-061- 114887-1 and 400-061-110368-1 2. Indian River Farms Water Control District - Permit No, C. The CONTRACTOR shall obtain and pay for all other required permits and licenses. The CONTRACTOR shall provide copies of the permits to the OWNER and ENGINEER and shall comply with all conditions contained in the permits at no extra cost to the OWNER. D. The CONTRACTOR shall be familiar with all permit requirements during construction and shall be responsible for complying with these requirements. The cost of this effort shall be included in the pay item in which the work is most closely associated with. 00800-6 00800 - Supplementary conditions 00800 6FAEngineering\Petition Paving%0522 1st Rd. from 32nd Ave. to 35th Ave%Bid Documents\00600 - Supplementary Conditions.doc SC -13.03 Test and Inspections SC -13.03.13. Delete the first sentence of paragraph GC -13.03.8 in its entirety, and insert the following sentences in its place: B. OWNER shall employ and pay for the services of an independent testing laboratory to perform all initial inspections, tests, or approvals required by the Contract Documents except those inspections, tests, or approvals listed immediately below. Subsequent inspections, tests, or approvals required after initial failing inspections, tests, or approvals shall be paid for by the CONTRACTOR by back charge to subsequent applications for payment. The CONTRACTOR shall arrange, obtain, and pay for the following inspections, tests, or approvals: 1. inspections, tests, or approvals covered by paragraphs 13.03.0 and 13.03.1) below; 2a costs incurred in connection with tests or inspections conducted pursuant to paragraph 13.04.13 shall be paid as provided in said paragraph 13.04.13; 3.tests otherwise specifically provided in the Contract Documents. 13.05 OWNER May Stop the Work SC -13.05.A. Delete paragraph GC43.05.A in its entirety and insert the following paragraph in its place: A. If the Work is defective, or CONTRACTOR fails to supply sufficient skilled workers or suitable materials or equipment, or fails to comply with permit requirements, or fails to comply with the technical specifications, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, OWNER may order CONTRACTOR to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of OWNER to stop the Work shall not give rise to any duty on the part of OWNER to exercise this right for the benefit of CONTRACTOR, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 14.02 Progress Payments SC -14.02.13.5. Delete paragraph GC-14.02.B.5.d in its entirety and insert the following paragraph in its place: d. ENGINEER has actual knowledge of the occurrence of any of the events enumerated in paragraph 15.02.A; or SC -14.02.13.5. Add the following sentences at the end of paragraph GC -14.02.6.5: e. OWNER has been required to pay ENGINEER additional compensation because of CONTRACTOR delays or rejection of defective Work; or 00800-7 00800 - Supplementary conditions noAnn %F•\FnninoainniPefMnn P0.r7mMnr99 ief RA fmm 049nd Avo M AFfh Av %Rid r1mmmonfe\nmmn . Ai ndm�onfam Cnnriifinne rinn f. OWNER has been required to subsequent inspections, tests, inspections, tests, or approvals. pay an independent testing laboratory for or approvals taken after initial failing SC -14.02.C.1. Delete paragraph GC -14.02.C.1 in its entirety and insert the following paragraph in its place: C. Payment Becomes Due 1. Payment shall be made by OWNER to CONTRACTOR according to the Local Government Prompt Payment Act, SC -14.04A. After the third sentence in paragraph GC -14.04A of the General Conditions, delete the remainder of paragraph 14.04A in its entirety and replace with the following: "If Engineer considers the Work substantially complete, Engineer will prepare and deliver to Owner a tentative certificate of Substantial Completion that shall fix the date of Substantial Completion. In accordance with the provisions of Florida Statutes section 208.735(7)(a)(2005), upon receipt of the tentative certificate of Substantial Completion from Engineer, the Owner, the Engineer, and the Contractor shall conduct a walk-through inspection of the Project to document a list of any items required to render the Work on the Project complete, satisfactory, and acceptable under this Agreement (herein the "Statutory List"). The Statutory List shall be reduced to writing and circulated among the Owner, the Engineer, and the Contractor by the Owner or the Engineer within 30 calendar days after substantial completion. The Owner and Contractor acknowledge and agree that: 1) the failure to include any corrective work, or pending items that are not yet completed, on the Statutory List does not alter the responsibility of the Contractor to complete all of the Work under this Agreement; 2) upon completion of all items on the Statutory List, the Contractor may submit a pay request for all remaining retainage except as otherwise set forth in this Agreement; and 3) any and all items that require correction under this Agreement and that are identified after the preparation of the Statutory List remain the obligation of the Contractor to complete to the Owner's satisfaction under this Agreement. After receipt of the Statutory List by the Contractor, the Contractor acknowledges and agrees that it will diligently proceed to complete all items on the Statutory List and schedule a final walk-through in anticipation of final completion on the Project." SC -14.04B Add the following new paragraph immediately after paragraph GC 14.048: C. At the time of delivery of the tentative certificate of Substantial Completion, Engineer will deliver to Owner and Contractor a written recommendation as to division of responsibilities pending final payment between Owner and Contractor with respect to security, operation, safety, and protection of the Work, maintenance, heat, utilities, insurance, and warranties and guarantees SC -14.07 Final; Payment SC -14.07.C.1. Delete paragraph GC44.07.C.1 in its entirety and insert the following paragraph in its place: C. Payment Becomes Due 00800-8 00800 - Supplementary Conditions 00800 8FAEngineering\Petitlon Paving\0522 tst Rd. from 32nd Ave. to 35th Ave\Bid Documents\00800 - Supplementary Conditions.doc 1. Payment shall be made by OWNER to CONTRACTOR according to the " Local Government Prompt Payment Act" , Florida Statutes section 218.70, et. seq. SC -15.01 OWNER May Suspend Work SC -15.01.A Delete the last sentence in paragraph GC -15.01.A and insert the following in its place: CONTRACTOR shall be allowed an extension of the Contract Times, directly attributable to any such suspension if CONTRACTOR makes a Claim for an extension as provided in paragraph 10.05. CONTRACTOR shall not be allowed an adjustment of the Contract Price and CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other eco- nomic loss arising out of or resulting from such Work suspension. SC -15.02 OWNER May Terminate For Cause SC4 5.02.A.5 and SC -15.02.A.6 Add the following new paragraphs immediately after paragraph GC45.02.A.4: 5. CONTRACTOR's violation of Section 02225 —"Erosion Control and Treatment of Dewatering Water From the Construction Site." 6. CONTRACTOR's failure to make payment to Subcontractors or Suppliers for materials or labor in accordance with the respective agreements between the CONTRACTOR and the Subcontractors or Suppliers. SC -15.04 CONTRACTOR May Stop Work or Terminate SC -15.04 Delete the following text from the first sentence of paragraph GC45.04.A: SC -15.04 Delete the following text from the second sentence of paragraph GC45.04.A: SC -16 DISPUTE RESOLUTION SC -16.02 Mediation SC -16 Add the following new paragraph immediately after paragraph GC46.01. SC -16.02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims, disputes, or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties. The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed. 00800-9 00800 - Supplementary conditions SCA7 Miscellaneous Add the following new paragraphs immediately after paragraph GC 17,05: SC -17.06 Liens A. This project is a "Public Works" under Chapter 255, Florida Statutes. No merchant's liens may be filed against the OWNER. Any claimant may apply to the OWNER for a copy of this Contract. The claimant shall have a right of action against the CONTRACTOR for the amount due him. Such action shall not involve the OWNER in any expense. Claims against the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in Florida Statutes Section 255.05. The CONTRACTOR shall insert the following paragraph in all subcontracts hereunder: "Notice: Claims for labor, materials and supplies are not assessable against Indian River County and are subiect to proper prior notice to (CONTRACTOR'S Name) and to (CONTRACTOR Surety Company Name) pursuant to Chapter 255 of the Florida Statutes. This paragraph shall be inserted in every sub - subcontract hereunder." The payment due under the Contract shall be paid by the OWNER to the CONTRACTOR only after the CONTRACTOR has furnished the OWNER with an affidavit stating that all persons, firms or corporations who are defined in Section 713.01, Florida Statutes, who have furnished labor or materials, employed directly or indirectly in the Work, have been paid in full. The OWNER may rely on said affidavit at face value. The CONTRACTOR does hereby release, remiss and quit -claim any and all rights he may enjoy perfecting any lien or any other type of statutory common law or equitable lien against the job. ++END OF SUPPLEMENTARY CONDITIONS++ 00800-10 00800 - Supplementary Conditions 008001 OFAEngineeringTelition Paving\05221st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00800 - Supplementary Conditions.doc SECTION 00942 - Change Order Form DATE OF ISSUANCE: OWNER: Indian River County CONTRACTOR Bid No: 2008062 Project: 1St Road from 35"' Street SW OWNER's Contract No. ENGINEER Indian River County No, EFFECTIVE DATE: Al ENGINEER's Contract No. N/A You are directed to make the following changes in the Contract Documents: Description: Reason for Change Order: Attachments: (List documents supporting change) CHANGE IN CONTRACT PRICE: Description Amount Original Contract Price $ Net Increase (Decrease) from $ previous Change Orders No. to Contract Price prior to this $ Change Order: Net increase (decrease) of this $ Change Order: Contract Price with all approved $ Change Orders: ACCEPTED: By: CONTRACTOR (Signature) Date: 7th CHANGE IN CONTRACT TIMES Description Time Original Contract Time: (days or dates) Substantial Completion: Final Completion: Net change from previous Change Orders No. to (days) Substantial Completion: Final Completion: Contract Time prior to this Change Order: (days or dates) Substantial Completion: Final Completion: Net increase (decrease) this Change Order: (days or dates) Substantial Completion: Final Completion: Contract Time with all approved Change Orders: (days or dates) Substantial Completion: Final Completion: RECOMMENDED: By: Date: re) APPROVED: By: OWNER (Signature Date: 00942 - Change Order Form 00942-1 FAEngineering\Petition Paving\05221 st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00942 - Change Order Form.doc Rev. 05101 SECTION 00946 - Field Order Form DATE OF ISSUANCE: OWNER: Indian River Countv CONTRACTOR Bid No: 2008062 Project:1 oad from 35`h A Street SW OWNER's Contract No, ENGINEER: Indian River County Field Activity Description: Reason for Change: Recommended Disposition: Field Operations Officer / Engineer (Signature) Disposition: Contractor's Onsite Supervisor (Signature) Field Change No.: EFFECTIVE DATE: ENGINEER's Contract No. Distribution: Field Operations Officer Others as Required: On-site Supervisor Project File Date Date 00946 - Field Order Form FAEngineering\Petition Paving\0522 1 st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00946 - Field Order Form.doc SECTION 00948 = Work Change Directive DATE OF ISSUANCE: OWNER: Indian River County CONTRACTOR: Bid No: 2008062 Project: 1St Road from 35' Avenue to 3 Street SW OWNER's Contract No. ENGINEER: Indian River County No. EFFECTIVE DATE: ENGINEER's Contract No. You are directed to proceed promptly with the following changes: Description: Purpose of Work Change Directive: Attachments: (List documents supporting change) If OWNER or CONTRACTOR believe that the above change has affected Contract Price any Claim for a Change Order based thereon will involve one or more of the following methods as defined in the Contract Documents. Method of determining change in Contract Prices: II Unit Prices 0 Lump Sum II Other: n By Change Order: Estimated increase (decrease) in Contract Price: If the change involves an increase, the estimated amount is not to be exceeded without further authorization. RECOMMENDED: By: EER (Authorized Signature) Date: Method of determining change in Contract Times j] Contractor's Records [� Engineer's Records ❑ Other: F71 By Change Order: Estimated increase (decrease) in Contract Times: Substantial Completion: days; Ready for Final Completion: days. If the change involves an increase, the estimated time is not to be exceeded without further authorization. AUTHORIZED: By: OWNER (Authorized Date: FAEngineering\Petition Paving\05221 st Rd. from 32nd Ave. to 35th Ave\Bid Documents\00948 - Work Change Directive.doc