HomeMy WebLinkAbout2022-042ASECTION 00530 — EJCDC STANDARD FORM OF AGREEMENT
BETWEEN OWNER AND CONTRACTOR ON THE BASIS OF A STIPULATED PRICE
North County RO SCADA Improvements
THIS AGREEMENT ("Agreement" or "Contract"), dated the 1st day of March in the year 2022
by and between Indian River County, a political subdivision of the State of Florida (hereinafter called
OWNER) and Paragon Electric of Vero, Inc. .(hereinafter called CONTRACTOR).
OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as
follows:
ARTICLE 1 WORK
CONTRACTOR as an independent contractor and not as an employee shall furnish and
complete all of the necessary labor, material, and equipment to perform the work as specified
or indicated in the Contract Documents and per Indian County Department of Utility Services
(IRCDUS) standards. The work is generally described as follows:
Construct electrical and SCADA system improvements at the North County RO Plant.
ARTICLE 2 ENGINEER
The North County RO SCADA Improvements project has been designed by Kimley-Horn and
Associates, Inc., hereinafter called ENGINEER, and who is to act as OWNER'S representative, assume
all duties and responsibilities and have the rights and authority assigned to ENGINEER in the Contract
Documents in connection with completion of the work in accordance with the Contract Documents.
t12 1[0I1111111�910► C_O091 & 12
3.1 The CONTRACTOR shall be substantially completed with the following timeframe
(a) Within 30 calendar days from effective date of Notice to Proceed, Contractor shall
complete the following tasks:
1. Obtain all necessary permits.
2. Submit shop drawings for all materials and equipment to be utilized on the job.
3. Perform all photographic recording and documentation of conditions prior to
construction.
4. Locate all existing utilities in the area of work.
5. Secure approval of shop drawings.
6. Mobilize all labor, equipment, and materials and prepare the site.
7. Notify all utilities and other affected parties prior to initiating construction.
(b) From 31 calendar days to 250 calendar days from the effective date of Notice to
Proceed, the CONTRACTOR shall complete the following tasks:
1. Install all mechanical, electrical, and control system
hardware/equipment and appurtenant items.
2. Perform all equipment start-ups and field testing.
3. Restore all disturbed areas to their pre -construction condition.
4. Correct all deficiencies noted by Engineer.
Completion of all tasks outlined above (i.e., Subparagraphs a) and b) constitutes Substantial
00530-1
Completion.
(c) From 251 calendar days to 280 calendar days from the effective date of Notice
to Proceed, the CONTRACTOR shall complete the following tasks:
1. Clean up project area.
2. Remove all equipment and material from project site.
3. Perform contract closeout procedures.
4. Demobilize.
3.2 Completion of all tasks outlined above (i.e., Subparagraphs a, b, and c) constitute
Final Completion.
3.3 Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence
of this Agreement and that OWNER will suffer financial loss if the work is not completed within
the times specified in Paragraph 3.1 above, plus any extensions thereof allowed in accordance
with Article 12 of the General Conditions. They also recognize the delays, expense and
difficulties involved in proving in a legal proceeding the actual loss suffered by OWNER if the
work is not completed on time. Accordingly, instead of requiring any such proof, OWNER and
CONTRACTOR agree that as liquidated damages for delay (but not as a penalty)
CONTRACTOR shall pay OWNER four -hundred and fifty dollars ($450.00) for each day that
expires after the time specified in Paragraph 3.1 for Substantial Completion, if CONTRACTOR
shall neglect, refuse or fail to complete the remaining work within the Contract Time or any
proper extension thereof granted by OWNER, CONTRACTOR shall pay OWNER four -hundred
and fifty dollars ($450.00) for each day that expires after the time specified in Paragraphs 3.1
and 3.2 for completion and readiness for final payment.
3.3.1 The CONTRACTOR and OWNER agree that OWNER is authorized to deduct
all or any portion of the above -stated liquidated damages due to the Owner from
payments due to the Contractor; or, in the alternative, all or any portion of the
above -stated liquidated damages may be collected from the Contractor or its
Surety or Sureties. These provisions for liquidated damages shall not prevent
the OWNER, in case of the CONTRACTOR's default, from terminating the
Contractor's right to proceed as provided in this AGREEMENT.
3.3.2 In addition to the above -stated liquidated damages, the CONTRACTOR shall be
responsible for reimbursing OWNER to third party consultants in administering
the Project beyond the Final Completion date specified in this Agreement, or
beyond an approved extension of time granted to CONTRACTOR, whichever
date is later.
ARTICLE 4 CONTRACT PRICE
4.1 OWNER shall pay CONTRACTOR for completion of the work in accordance with the Contract
Documents in current funds in the amount of $ 958,434.00
ARTICLE 5 PAYMENT PROCEDURES
00530-2
CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General
Conditions. Applications for Payment will be processed by ENGINEER as provided in the General
Conditions and the Contract Documents.
5.1 The OWNER shall make progress payments to the CONTRACTOR on the basis of the
approved partial payment request as recommended by ENGINEER in accordance with the
provisions of the Local Government Prompt Payment Act, Florida Statutes section 218.70 et.
seq. The OWNER shall retain five percent (5%) of the payment amount due to CONTRACTOR
until final completion and acceptance of all work to be performed by CONTRACTOR under the
Contract Documents.
5.2 Each request for a progress payment shall contain the CONTRACTOR'S certification. All
progress payments will be on the basis of progress of the work measured by the schedule of
values established, or in the case of unit price work based on the number of units completed.
5.3 Paragraphs 5.1 and 5.2 do not apply to construction services work purchased by the County as
OWNER which are paid for, in whole or in part, with federal funds and are subject to federal
grantor laws and regulations or requirements that are contrary to any provision of the Local
Government Prompt Payment Act. In such event, payment and retainage provisions shall be
governed by the applicable grant requirements and guidelines.
5.4 ACCEPTANCE AND FINAL PAYMENT: Upon receipt of written notice that the work is ready
for final inspection and acceptance, the ENGINEER will promptly make such inspection and
when the ENGINEER finds the work acceptable under the terms of the Contract and the
Contract fully performed, the ENGINEER will promptly issue a final completion certificate
stating that the work provided for in this Contract has been completed, and acceptance by
the OWNER under the terms and the conditions thereof is recommended and the entire
balance found to be due the CONTRACTOR, will be paid to the CONTRACTOR by the
OWNER following County Commission approval of the final Contract payment.
5.5 Acceptance of Final Payment as Release. The acceptance by the CONTRACTOR of final
payment shall be and shall operate as a release to the OWNER from all claims and all liability
to the CONTRACTOR other than claims in stated amounts as may be specifically excepted
by the CONTRACTOR for all things done or furnished in connection with the work under this
Contract and for every act and neglect of the OWNER and others relating to or arising out of
the work. Any payment, however, final or otherwise, shall not release the CONTRACTOR or
its sureties from any obligations under the Contract Documents or the Payment and
Performance Bonds.
ARTICLE 6 INTEREST
Not Applicable.
ARTICLE 7 CONTRACTOR'S REPRESENTATIONS
In order to induce OWNER to enter into this Agreement, CONTRACTOR makes the following
representations:
7.1 CONTRACTOR has familiarized itself with the nature and extent of the Contract Documents,
work, site, locality, and all local conditions and laws and regulations that in any manner may
affect cost, progress, performance or furnishing of the work.
00530-3
7.2 CONTRACTOR has studied carefully all reports of explorations and tests of subsurface
conditions and drawings of physical conditions which are identified in the Supplementary
Conditions as provided in Paragraph 4.02 of the General Conditions, and accepts the
determination set forth in Paragraph SC -4.02 of the Supplementary Conditions of the extent of
the technical data contained in such reports and drawings upon which CONTRACTOR is
entitled to rely.
7.3 CONTRACTOR has obtained and carefully studied (or assumes responsibility for obtaining and
carefully studying) all such examinations, investigations, explorations, tests, reports and studies
(in addition to or to supplement those referred to in Paragraph 7.2 above) which pertain to the
subsurface or physical conditions at or contiguous to the site or otherwise may affect the cost,
progress, performance or furnishing of the work as CONTRACTOR considers necessary for the
performance of furnishing of the work at the Contract Price, within the Contract Time and in
accordance with the other terms and conditions of the Contract Documents, including
specifically the provisions of Paragraph 4.02 of the General Conditions; and no additional
examinations, investigations, explorations, tests, reports, studies or similar information or data
are or will be required by CONTRACTOR for such purposes.
7.4 CONTRACTOR has reviewed and checked all information and data shown or indicated on the
Contract Documents with respect to existing underground facilities at or contiguous to the site
and assumes responsibility for the accurate location of said underground facilities. No additional
examinations, investigations, explorations, tests, reports, studies or similar information or data
in respect of said underground facilities are or will be required by CONTRACTOR in order to
perform and furnish the work at the Contract Price, within the Contract Time and in accordance
with the other terms and conditions of the Contract Documents, including specifically the
provisions of Paragraph 4.04 of the General Conditions.
7.5 CONTRACTOR has correlated the results of all such observations, examinations,
investigations, explorations, tests, reports and studies with the terms and conditions of the
Contract Documents.
7.6 CONTRACTOR has given ENGINEER written notice of all conflicts, errors or discrepancies that
he has discovered in the Contract Documents and the written resolution thereof by ENGINEER
is acceptable to CONTRACTOR.
7.7 Contractor is registered with and will use the Department of Homeland Security's E -Verify
system (www.e-verify.gov) to confirm the employment eligibility of all newly hired employees for
the duration of this agreement, as required by Section 448.095, F.S. Contractor is also
responsible for obtaining proof of E -Verify registration and utilization for all subcontractors.
ARTICLE 8 CONTRACT DOCUMENTS.
The Contract Documents which comprise the entire agreement between OWNER and CONTRACTOR
concerning the work consist of the following:
8.1 This Agreement (Section 00530)
8.2 General Conditions (Section 00700).
8.3 Supplementary Conditions (Section 00800).
8.4 Notice to Proceed (Sample Provided in Section 00800)
8.5 Public Construction Bond (Section 00600)
8.6 Certificate(s) of Liability Insurance (Section 00620)
00530-4
8.7 Contractor's Application for Payment (Sample Provided in Section 00800)
8.8 Certificate of Substantial Completion (Sample Provided in Section 00800)
8.9 Final Release of Lien (Sample Provided in Section 00800)
8.10 Technical Specifications bearing the title "Hobart WTP SCADA System Improvements"
8.11 Drawings Titled "Hobart WTP SCADA System Improvements"
8.12 Addenda numbers to inclusive.
8.13 CONTRACTOR'S Bid (Section 00310).
8.14 Bid Bond (Section 00410)
8.15 Schedule of Subcontractors (Section 00431).
8.16 Certification Regarding Prohibition Against Contracting with Scrutinized Companies (Section
00432).
8.17 Disclosure of Relationships (Section 00452).
8.18 Sworn Statement under the Florida Trench Safety Act (Section 00454).
8.19 General Information Required of Bidders (Section 00456).
8.20 The following, which may be delivered or issued after the effective date of the Agreement and
are not attached hereto: All written amendments and other documents amending, modifying, or
supplementing the Contract Documents pursuant to Paragraphs 3.04 of the General Conditions
(Samples provided in Section 00800).
There are no Contract Documents other than those listed above in this Article 8. The Contract
Documents may only be amended, modified or supplemented as provided in Paragraphs 3.04 of the
General Conditions.
ARTICLE 9 MISCELLANEOUS
9.1 Terms used in this Agreement which are defined in Article 1 of the General Conditions, as
supplemented by the Supplementary Conditions, will have the meanings indicated in the
General Conditions.
9.2 It is agreed that the CONTRACTOR shall not assign, transfer, convey, or otherwise dispose of
the contract or its right, title, or interest in or to the same or any part thereof, or allow legal action
to be brought in its name for the benefit of others, without previous consent of the OWNER and
concurred to by the sureties. Any attempted assignment shall be void and may, at the option of
the OWNER be deemed an event of default hereunder. Nothing herein shall be construed as
creating any personal liability on the part of any officer or agent of the OWNER who may be a
party hereto.
9.3 OWNER and CONTRACTOR each binds itself, its partners, successors, assigns and legal
representatives to the other party hereto, its partners, successors, assigns and legal
representatives in respect of all covenants, agreements and obligations contained in the
Contract Documents.
9.4 The CONTRACTOR shall be properly licensed to practice its trade or trades which are involved
in the completion of this Agreement and the work thereunder.
9.5 This Agreement shall be governed by the laws of the State of Florida. Venue for any lawsuit
brought by either party against the other party or otherwise arising out of this agreement shall
be in Indian River County, Florida, or, in the event of federal jurisdiction, in the United States
District Court for the Southern District of Florida.
9.6 The CONTRACTOR shall indemnify and hold harmless the County, and its officers and
employees, from liabilities, damages, losses and costs, including, but not limited to,
00530-5
reasonable attorney's fees, to the extent caused by the negligence, recklessness, or
intentional wrongful misconduct of the CONTRACTOR and persons employed or utilized by
the CONTRACTOR in the performance of the construction contract.
9.7 Pledge of Credit. The CONTRACTOR shall not pledge the OWNER'S credit or make it a
guarantor of payment or surety for any Agreement, debt, obligation, judgment, lien or any
form of indebtedness. The CONTRACTOR further warrants and represents that it has no
obligation of indebtedness that would impair its ability to fulfill the terms of this Agreement.
9.8. Counterparts. This Agreement may be executed in one or more counterparts, but all such
counterparts, when duly executed, shall constitute one and the same Agreement.
9.9. Public Records. Indian River County is a public agency subject to Chapter 119, Florida
Statutes. The Contractor shall comply with Florida's Public Records Law. Specifically, the
Contractor shall.-
A.
hall:
A. Keep and maintain public records required by the County to perform the service.
B. Upon request from the County's Custodian of Public Records, provide the
County with a copy of the requested records or allow the records to be inspected or
copied within a reasonable time at a cost that does not exceed the cost provided in
Chapter 119 or as otherwise provided by law.
C. Ensure that public records that are exempt or confidential and exempt from public
records disclosure requirements are not disclosed except as authorized by law for
the duration of the contract term and following completion of the contract if the
contractor does not transfer the records to the County.
D. Upon completion of the contract, transfer, at no cost, to the County all public records
in possession of the Contractor or keep and maintain public records required by the
County to perform the service. If the Contractor transfers all public records to the
County upon completion of the contract, the Contractor shall destroy any duplicate
public records that are exempt or confidential and exempt from public records
disclosure requirements. If the contractor keeps and maintains public records upon
completion of the contract, the Contractor shall meet all applicable requirements for
retaining public records. All records stored electronically must be provided to the
County, upon request from the Custodian of Public Records, in a format that is
compatible with the information technology systems of the County.
E. IF THE CONTRACTOR HAS QUESTIONS REGARDING THE
APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO
THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS
RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN
OF PUBLIC RECORDS AT:
(772) 226-1424
publicrecords(d)-ircgov.com
Indian River County Office of the County Attorney
1801 27th Street
Vero Beach, FL 32960
F. Failure of the Contractor to comply with these requirements shall be a material breach
of this Agreement.
00530-6
This Agreement will be effective on March 1, 2022 , (the date the Contract is approved by the Indian
River County Board of County Commissioners, which is the Effective Date of the Agreement).
OWNER:
NTY
f
111
By:
�J
Petep5-Q'Bryan,
By: i - v r
Jason . Bdown, County Administrato
CONTRACTOR:
Cp�SMI$S�0
APPROVED AS TO FORM AND LEGAL
SUFFICIENCY:
By:
Dylan Reingold, County Attorney
Jeffrey R. Smith, Clerk of Court and Comptroller
Attest:
Clerk of Court and Comptroller
(SEAL)
Designated Representative:
Name: Terry Southard
Title: Utility Operations Manager
Contact Info: (772) 226-3404
terrysouthard@ircgov.com
00530-7
i (Contractor)
i
•' ='Iyjs S_Al est/V�->
orivaw, T)JInS
Address for giving notices:
,t.
7 PIA
neo 60AU4,/ S;LC144
License No. �''C adOZ•7 3I
(Where applicable)
Agent for service of process:
Designated Representative:
Name:
Title:
Address:
Phone:
Facsimile:
(If CONTRACTOR is a corporation or a
partnership, attach evidence of authority to sign.)
PUBLIC CONSTRUCTION BOND
Bond No. FLC 82923
(enter bond number)
BY THIS BOND, We Paragon Electric of Vero, Inc. , as Principal and Merchants Bonding Cornpany (Mutual)
a corporation, as Surety, are bound to Indian River County , herein called Owner, in
the sum of $958,434.00, for payment of which we bind ourselves, our heirs, personal
representatives, successors, and assigns, jointly and severally.
THE CONDITION OF THIS BOND is that if Principal:
1. Performs the contract dated March 1 , 2022 , between Principal and Owner for
construction of North County RO SCADA Improvements , the contract being made
a part of this bond by reference, at the times and in the manner prescribed in the
contract; and
2. Promptly makes payments to all claimants, as defined in Section 255.05(1), Florida
Statutes, supplying Principal with labor, materials, or supplies, used directly or indirectly
by Principal in the prosecution of the work provided for in the contract; and
3. Pays Owner all losses, damages, expenses, costs, and attorney's fees, including
appellate proceedings, that Owner sustains because of a default by Principal under the
contract; and
4. Performs the guarantee of all work and materials furnished under the contract for the
time specified in the contract, then this bond is void; otherwise it remains in full force.
Any action instituted by a claimant under this bond for payment must be in accordance
with the notice and time limitation provisions in Section 255.05(2), Florida Statutes.
Any changes in or under the contract documents and compliance or noncompliance
with any formalities connected with the contract or the changes does not affect Surety's
obligation under this bond.
DATED ON March 7, 2022 S
(Name of Principal) Thomas cranims
B
y a
(As Aftorney in Fact) Timothy Fields
Merchants Bonding Company (Mutual)
(Name of Surety)
.-ERCHA.NT�.
BONDING COMP.A_NY.
POWER OF ATTORNEY
Know All Persons By These Presents, that MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.,
both being corporations of the State of Iowa (herein collectively called the "Companies") do hereby make, constitute and appoint, individually,
J Wayne Edens; Selma D Barker; Timothy P Fields
their true and lawful Attorneys) -in -Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings,
contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity
of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any
actions or proceedings allowed by law.
This Power -of -Attorney is granted and is signed and sealed by facsimile under and by authority of the following By -Laws adopted by the Board
of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors
of Merchants National Bonding, Inc., on October 16, 2015.
"The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority
to appoint Attorneys -in -Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and
undertakings, recognizances, contracts of indemnity and other writings obligatory in the nature thereof."
"The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney
or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the
Company, and such signature and seal when so used shall have the same force and effect as though manually fixed."
In connection with obligations in favor of the Florida Department of Transportation only, it is agreed that the power and aut hority hereby given to the
Attorney -in -Fact includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction
contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department
of Transportation making payment of the final estimate to the Contractor and/or its assignee, shall not relieve this surety company of any of
its obligations under its bond.
In connection with obligations in favor of the Kentucky Department of Highways only, it is agreed that the power and authority hereby given
to the Attorney -in -Fact cannot be modified or revoked unless prior written personal notice of such intent has been given to the Commissioner -
Department of Highways of the Commonwealth of Kentucky at least thirty (30) days prior to the modification or revocation.
In Witness Whereof, the Companies have caused this instrument to be signed and sealed this 11th day of February 2020
' 10N G
R R'
pQ , *-. 01,�• MERCHANTS BONDING COMPANY (MUTUAL)
hy;'40q 2 ^ �; V�� 9�js .�; MERCHANTS NATIONAL BONDING, INC.
:Z.2 _o -.rte :=
v 2003 �� : : y 1933 c; By
�• �•., ,.:� '�; •�,�... .••�.�•• President
STATE OF IOWA •••�•`""'``��'' • • • • • • • •
COUNTY OF DALLAS ss.
On this 11th day of February 2020 before me appeared Larry Taylor, to me personally known, who being by me duly sworn
did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the
seals affixed to the foregoing instrument are the Corporate Seals of the Companies; and that the said instrument was signed and sealed in behalf
of the Companies by authority of their respective Boards of Directors.
�PRtAZ s POLLY MASON
o y Commission Number 750576 �A
Z ° ° ° My Commission Expires
,oWP * January 07, 2023 Notary Public
(Expiration of notary's commission
does not invalidate this instrument)
I, William Warner, Jr., Secretary of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., do hereby
certify that the above and foregoing is a true and correct copy of the POWER-OF-ATTORNEY executed by said Companies, which is still in full
force and effect and has not been amended or revoked.
In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 7th day of March , 2022
�•'? RpOR.�o• ; •off RPQ,g'
Z.' 6'•� 1933 v: C' Secretary
L) : 2003 :.�: : s�. Wil►;
POA 0018 (1/20) ••�'""""`���'
PARAELE-03 5MGNEtLY
CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DDNYYY)
1/26/2022
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on
this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
PRODUCER CONT CT Shari McNeely
NAM
J.W. Edens and Company Inc. (A/CC,,"N , Ext : (321) 383-4554 ac, No):
4650 S Hopkins Ave E-MAIL smcneely@jwedens.com
Titusville, FL 32780 Ess: 1
INSURED
Paragon Electric Of Vero, Inc.
9120 16th Place
Vero Beach, FL 32966
INSURER F:
ers
m
DC\/ICIAhI IVIIMRCL?•
038
tluvCKAVCa %+crtr rr,v�THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
TYPE OF INSURANCE
ADDL
SUBR
POLICY NUMBER
POLICY EFF
POLICY EXP
LIMITS
LTR
A
X COMMERCIAL GENERAL LIABILITY
CLAIMS -MADE FX OCCUR
Vero Beach, FL 32960
72862532
1/1/2022
1/1/2023
EACH OCCURRENCE $ 1,000'000
DAMAGE TO RENTED 300,000
SES( $
MED EXP (Any oneperson) $ 10,000
PERSONAL BADV INJURY $ 1,000,000
N'LAGGREGATE LIMIT APPLIES PER:
POLICY a jE& � LOC
Rx"
GENERALAGGREGATE $ 2,000,000
2'000,000
PRODUCTS - COMP/OP AGG $
COMBINED SINGLE LIMIT 1,000,000
ccid $
B
OTHER: Limited Contractual Liab$
AUTOMOBILE LIABILITY
BODILY INJURY Perperson)_ $
X ANY AUTO
4786253202
1/1/2022
1/1/2023
BODILY INJURY Per accident $
OWNEDSCHEDULED
AUTOS ONLY AUTOS
yyryE
X AUTOS ONLY X AUOTOJ ONLY
PROPERTY DAMAGE
Per accident $
A
X
UMBRELLA LIAB
EXCESS LIAB
X
OCCUR
CLAIMS -MADE
47-862-532-03
1/1/2022
1/1/2023
EACH OCCURRENCE $ 2,000,000
AGGREGATE $ 2,000,000
DED I X I RETENTION$ 10,000
Follow Form $
rm=
FoER
C
WORKERS COMPENSATION
EMPLOYERS' LIABILITY
ANY PROPRIETOR/PARTNER/EXECUTIVE Y/ N
OFFICER/MEMBER EXCLUDED?
(Mandatory in NH)
If yes, describe under
DESCRIPTION OF OPERATIONS below
N / A
WC840-0032156-2022A
1/1/2022
1/1/2023
ER
�( PST
1,000,000
E.L. EACH ACCIDENT $
1,000,000
E.L. DISEASE - EA EMPLOYE $
1,000,000
E.L. DISEASE -POLICY LIMIT $
DESCRIPTION OF OPERATIONS I LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, mai be attached if more space is required)
Bid 2022023- North County RO SCADA Improvements.
The General Liability policy includes a Blanket Additional Insured status only when there is a written contract that requires such status. This insurance is
primary for the Additional Insured, but only with respect to liability arising out of "your work" for that Additional Insured by or for you and BLANKET WAIVER
OF SUBROGATION When you have agreed to waive your right of subrogation in a written contract. Workers Comp policy includes a Blanket Waiver of
Subrogation endorsement. Auto Policy includes DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE BLANKET COVERAGE and WAIVER
OF OUR RIGHT TO RECOVER PAYMENTS (WAIVER OF SUBROGATION) - BLANKET
ACORD 25 (2016/03) v IyOO-w10 M%,UMU I.vr%r-1jr\M11i iv. rii iiyiiw 1GOC1��u.
The ACORD name and logo are registered marks of ACORD
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
Indian River County
ACCORDANCE WITH THE POLICY PROVISIONS.
1800 27th Street
Building "B"
Vero Beach, FL 32960
AUTHORIZED REPRESENTATIVE
ACORD 25 (2016/03) v IyOO-w10 M%,UMU I.vr%r-1jr\M11i iv. rii iiyiiw 1GOC1��u.
The ACORD name and logo are registered marks of ACORD