Loading...
HomeMy WebLinkAbout2007-128 207 - ', 23 Gifford Community Station Part I Agreement 04103/07 TABLE OF ARTICLES PART 1 AGREEMENT 1 . DESIGN/BUILDER 2. OWNER 3. OWNERSHIP AND USE OF DOCUMENTS AND ELECTRONIC DATA 4. TIME 5. PAYMENTS 6 . DISPUTE RESOLUTION — MEDIATION AND ARBITRATION 7 . MISCELLANEOUS PROVISIONS 8. TERMINATION OF THE AGREEMENT 9. BASIS OF COMPENSATION 10 . OTHER CONDITIONS AND SERVICES i THIS AGREEMENT made on November 17 , 2005 , BETWEEN the Owner Indian River County , a political subdivision of the State of Florida , 1840 25th Street, Vero Beach , Florida 32960 and the Design/Builder Barth Construction , Inc. , 1717 Indian River Blvd. Suite 202A, Vero Beach , Florida 32960 . For the following Project: Design-Build Construction of the Gifford Community Station 3620 49th Street Vero Beach , FL The architectural services described in Article 1 will be provided by the following person or entity who is lawfully licensed to practice architecture : Name and address Registration Relationship to Number Design/Builder Edlund-Dritenbas-Binkley, Architects AR0009308 Contractual & Associates 65 Royal Palm Boulevard , Suite D , Vero Beach , FL 32960 Normal structural , mechanical and electrical engineering services will be provided contractually through the Architect except as indicated below: Name , address and discipline Registration Relationship to Number Design/Builder The Owner and the Design/Builder agree as set forth below. TERMS AND CONDITIONS — PART 1 AGREEMENT ARTICLE 1 DESIGN/BUILDER § 1 . 1 SERVICES § 1 . 1 . 1 Preliminary design , budget, and schedule comprise the services required to accomplish the preparation and submission of the Design/Builder's Proposal as well as the preparation and submission of any modifications to the Proposal prior to execution of the Part 2 Agreement. § 1 . 2 RESPONSIBILITIES § 1 . 2. 1 Design services required by this Part 1 Agreement shall be performed by qualified architects and other design professionals . The contractual obligations of such 2 professional persons or entities are undertaken and performed in the interest of the Design/Builder. § 1 .2 . 2 The agreements between the Design/Builder and the persons or entities identified in this Part 1 Agreement, and any subsequent modifications , shall be in writing . These agreements , including financial arrangements with respect to this Project, shall be promptly and fully disclosed to the Owner upon request. § 1 .2 . 3 Construction budgets shall be prepared by qualified professionals , cost estimators or contractors retained by and acting in the interest of the Design/Builder. § 1 .2 .4 The Design/Builder shall be responsible to the Owner for acts and omissions of the Design/Builder' s employees , subcontractors and their agents and employees , and other persons , ^^' , diRg the Architect and other deSigR pFefe6siG , performing any portion of the Design/Builder's obligations under this Part 1 Agreement. § 1 .2 .5 If the Design/Builder believes or is advised by the Architect or by another design professional retained to provide services on the Project that implementation of any instruction received from the Owner would cause a violation of any applicable law, the Design/Builder shall notify the Owner in writing . Neither the Design/Builder nor the Architect shall be obligated to perform any act which either believes will violate any applicable law. § 1 . 2 .6 Nothing contained in this Part 1 Agreement shall create a contractual relationship between the Owner and any person or entity other than the Design/Builder. § 1 .3 BASIC SERVICES § 1 .3 . 1 The Design/Builder shall provide a preliminary evaluation of the Owner's program and project budget requirements , each in terms of the other. § 1 .3 . 2 The Design/Builder shall visit the site , become familiar with the local conditions , and correlate observable conditions with the requirements of the Owner's program , schedule , and budget. § 1 .3.3 The Design/Builder shall review laws applicable to design and construction of the Project , correlate such laws with the Owner's program requirements , and advise the Owner if any program requirement may cause a violation of such laws . Necessary changes to the Owner's program shall be accomplished by appropriate written modification or disclosed as described in Section 1 . 3 . 5 . § 1 .3.4 The Design/Builder shall review with the Owner alternative approaches to design and construction of the Project. § 1 .3 . 5 The Design/Builder shall submit to the Owner a Proposal , including the completed Preliminary Design Documents , a statement of the proposed contract sum , and a proposed schedule for completion of the Project. Preliminary Design Documents 3 shall consist of preliminary design drawings , outline specifications or other documents sufficient to establish the size , quality and character of the entire Project , its architectural , structural , mechanical and electrical systems , and the materials and such other elements of the Project as may be appropriate . Deviations from the Owner's program shall be disclosed in the Proposal . If the Proposal is accepted by the Owner, the parties shall then execute the Part 2 Agreement. A modification to the Proposal before execution of the Part 2 Agreement shall be recorded in writing as an addendum and shall be identified in the Contract Documents of the Part 2 Agreement. § 1 .4 ADDITIONAL SERVICES § 1 .4. 1 The Additional Services described under this Section 1 .4 shall be provided by the Design/Builder and paid for by the Owner if authorized or confirmed in writing by the Owner. § 1 .4. 2 Making revisions in the Preliminary Design Documents , budget or other documents when such revisions are : . 1 inconsistent with approvals or instructions previously given by the Owner, including revisions made necessary by adjustments in the Owner's program or Project budget; .2 required by the enactment or revision of codes , laws or regulations subsequent to the preparation of such documents ; or .3 due to changes required as a result of the Owner's failure to render decisions in a timely manner. § 1 .4.3 Providing more extensive programmatic criteria than that furnished by the Owner as described in Section 2 . 1 . When authorized , the Design/Builder shall provide professional services to assist the Owner in the preparation of the program . Programming services may consist of: . 1 consulting with the Owner and other persons or entities not designated in this Part 1 Agreement to define the program requirements of the Project and to review the understanding of such requirements with the Owner; . 2 documentation of the applicable requirements necessary for the various Project functions or operations; .3 providing a review and analysis of the functional and organizational relationships , requirements , and objectives for the Project; .4 setting forth a written program of requirements for the Owner's approval which summarizes the Owner's objectives , schedule , constraints , and criteria . § 1 .4.4 Providing financial feasibility or other special studies . § 1 .4. 5 Providing planning surveys , site evaluations or comparative studies of prospective sites . § 1 .4. 6 Providing special surveys , environmental studies , and submissions required for approvals of governmental authorities or others having jurisdiction over the Project. 4 § 1 .4. 7 Providing services relative to future facilities , systems and equipment . § 1 .4.8 Providing services at the Owner's specific request to perform detailed investigations of existing conditions or facilities or to make measured drawings thereof. § 1 .4.9 Providing services at the Owner's specific request to verify the accuracy of drawings or other information furnished by the Owner. § 1 .4. 10 Coordinating services in connection with the work of separate persons or entities retained by the Owner, subsequent to the execution of this Part 1 Agreement . § 1 .4. 11 Providing analyses of owning and operating costs . § 1 .4. 12 Providing interior design and other similar services required for or in connection with the selection , procurement or installation of furniture , furnishings and related equipment. § 1 .4 . 13 Providing services for planning tenant or rental spaces . § 1 .4. 14 Making investigations , inventories of materials or equipment, or valuations and detailed appraisals of existing facilities . ARTICLE 2 OWNER § 2 . 1 RESPONSIBILITIES § 2 . 1 . 1 The Owner shall provide full information in a timely manner regarding requirements for the Project, including a written program which shall set forth the Owner's objectives , schedule , constraints and criteria . § 2 . 1 . 2 The Owner shall establish and update an overall budget for the Project, including reasonable contingencies . This budget shall not constitute the contract sum . § 2 . 1 . 3 The Owner shall designate a representative authorized to act on the Owner's behalf with respect to the Project. The Owner or such authorized representative shall render decisions in a timely manner pertaining to documents submitted by the Design/Builder in order to avoid unreasonable delay in the orderly and sequential progress of the Design/Builder's services . The Owner may obtain independent review of the documents by a separate architect, engineer, contractor, or cost estimator under contract to or employed by the Owner . Such independent review shall be undertaken at the Owner's expense in a timely manner and shall not delay the orderly progress of the Design/Builder's services . § 2. 1 .4 The Design/Builder Owner shall furnish surveys describing physical characteristics , legal limitations and utility locations for the site of the Project, and a written legal description of the site . The surveys and legal information shall include , as applicable , grades and lines of streets , alleys , pavements , and adjoining property and 5 structures ; adjacent drainage ; rights-of-way, restrictions , easements , encroachments , zoning , deed restrictions , boundaries and contours of the site ; locations , dimensions and necessary data pertaining to existing buildings , other improvements and trees ; and information concerning available utility services and lines , both public and private , above and below grade , including inverts and depths . All the information on the survey shall be referenced to a Project benchmark . § 2 . 1 . 5 The Design/Builder Owner shall furnish the services of geotechnical engineers when such services are stipulated in this Part 1 Agreement, or deemed reasonably necessary by the Design/Builder. Such services may include but are not limited to test borings , test pits , determinations of soil bearing values , percolation tests , evaluations of hazardous materials , ground corrosion and resistivity tests , and necessary operations for anticipating subsoil conditions . The services of geotechnical engineer(s) or other consultants shall include preparation and submission of all appropriate reports and professional recommendations . § 2 . 1 . 6 The Owner shall disclose , to the extent known to the Owner, the results and reports of prior tests , inspections or investigations conducted for the Project involving : structural or mechanical systems ; chemical , air and water pollution ; hazardous materials ; or other environmental and subsurface conditions . The Owner shall disclose all information known to the Owner regarding the presence of pollutants at the Project's site . § 2. 1 .7- The Owner shall furnish all legal , aGGGLIRting and iRGUFaRGeGGLIRseliRg sepviGe-s as may beReGessaFy at any time f9F thePFGjeGt , includiRg such auditing services as § 2. 1 .8 The Owner shall promptly obtain easements , zoning variances and legal authorizations regarding site utilization where essential to the execution of the Owner's program . § 2 . 1 . 9 Those services , information , surveys , and reports required by Sections 2 . 1 .4 through 2 . 1 . 8 (except for §2 . 1 . 7 ) which are within the Owner's control shall be furnished at the Owner's expense , and the Design/Builder shall be entitled to rely upon the accuracy and completeness thereof, except to the extent the Owner advises the Design/Builder to the contrary in writing . exGept as atherwise stipulated iR this Part 1 Agreement . § 2 . 1 . 11 The Owner shall communicate with persons or entities employed or retained by the Design/Builder through the Design/Builder, unless otherwise directed by the Design/Builder. 6 ARTICLE 3 OWNERSHIP AND USE OF DOCUMENTS AND ELECTRONIC DATA § 3 . 1 The Owner hopes to use the plans, Drawings , specifications , and ether documents and electronic data furnished by the Design/Builder as a prototype for construction of other fire stations in the future . are mRS4 FneRts of service . The Design/Builder's Architect and other providers of professional services shall retain all common law , statutory and other reserved rights , including copyright in those instruments of service furnished by them , except the owner shall have the right to reuse the instruments for construction of additional fire stations . Dra iRg6 spe^ ;f" Gat,,, .,6 and Part 1 Agreerne .,f . The Owner shall be permitted to retain copies , including reproducible copies , of the drawings , specifications , and other documents and electronic data furnished by the Design/Builder for information and reference in connection with the Project except as provided in Sections 3 . 2 and 3 . 3 . The Owner intends that the documents drawings plans , specifications and electronic data are intended to be reused at some future time . Pursuant to FS 287 . 055 ( l 0) , the documents and plans shall contain notice to the public that the plans are subject to reuse . § 3 .2 If the Part 2 Agreement is not executed , the Owner shall not use the drawings , specifications , and other documents and electronic data furnished by the Design/Builder without the written permission of the Design/Builder. Drawings , specifications , and other documents and electronic data shall not be used by the Owner or others on other projects , for additions to this Project or for completion of this Project by others , except by agreement in writing and with appropriate compensation to the Design/Builder, unless the Design/ Builder is adjudged to be in default under this Part 1 Agreement or under any other subsequently executed agreement, or by agreement in writing . § 3 .3 If the Design/Builder defaults in the Design/Builder's obligations to the Owner, the Architect shall grant a license to the Owner to use the drawings , specifications, and other documents and electronic data furnished by the Architect to the Design/Builder for the completion of the Project, conditioned upon the Owner's execution of an agreement to cure the Design/Builder's default in payment to the Architect for services previously performed and to the extent allowed by law, indemnify the Architect with regard to claims arising from such reuse without the Architect' s professional involvement. § 3 .4 Submission or distribution of the Design/Builder's documents to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the rights reserved in Section 3 . 1 . ARTICLE 4 TIME § 4. 1 Upon the request of the Owner, the Design/Builder shall prepare a schedule for the performance of the Basic and Additional Services which shall not exceed the time limits contained in Section 10 . 1 and shall include allowances for periods of time required for the Owner's review and for approval of submissions by authorities having jurisdiction over the Project. § 4. 2 If the Design/Builder is delayed in the performance of services under this Part 1 Agreement through no fault of the Design/Builder, any applicable schedule shall be equitably adjusted . ARTICLE 5 PAYMENTS § 5 . 1 The initial payment provided in Article 9 shall be made upon execution of this Part 1 Agreement and credited to the Owner's account as provided in Section 9 . 1 .2 . § 5 .2 Subsequent payments for Basic Services , Additional Services , and Reimbursable Expenses provided for in this Part 1 Agreement shall be made in accordance with the Florida Prompt Payment Act FS 218 . 70 et seq . rRenthly on the hef. is set forth , n Article 9. § 5. 3 Upon Within ten ( 10) rt ^. ,^ of the Owner's receipt of a properly submitted and correct Application for Payment, the Owner shall make payment to the Design/Builder in accordance with the Florida Prompt Payment Act. § 5 .4 Payments due the Design/Builder under this Part 1 Agreement which are not paid when due shall bear interest in accordance with the Florida Prompt Payment Act#re+44 the date d at " .+} 'f' rl C t'en 9 . 55 G n the abseRGe of a specified ro#e of r the legal Fate pFevailing where the PFejeGt is 10Gated-. ARTICLE 6 DISPUTE RESOLUTION — MEDIATION AND ARBITRATION § 6 . 1 Claims , disputes or other matters in question between the parties to this Part 1 Agreement arising out of or relating to this Part 1 Agreement or breach thereof shall be subject to the following procedure : the dispute shall first be addressed by a meeting between the Owner Design/Builder Architect and Owner's Representative . If the dispute is not remedied the parties shall submit the dispute to the County Administrator or his assign who shall make the final decision on the matter. The resolution of the dispute shall be reduced to writing and attached to this agreement. and deGided bymediatiGRar arbitrat' OR . C ^h mediatic OF arbitration shall R - 11pq Pf thPAFR8FiGan D h't et' Assnrigtim ^ irrently in effe^t § 6 .2 In A- d-d- ition Wand PFiGF tG aFbitFat'en , the parties shall eRdeaver te settle disputes by R; edmatiG)R . Dernand foF mediatiGR shall be filed iR wFitiRg with the GtheF party to t Part 1 Agreement and with the ArneFiGan ArbitpatiGR A669Giation . A demand fe matter t' ha I event shell the demand far mediation he made ..fFe 7 Ar At.her FAa#pr iR question would be barred by the appliGable statute of Fepese 9 nnsvci 1 ' mrr�'taF rrrcorru: • zwr.%3 - - - - ■ - - m MAW - - mm ■ - - - - -OMP - - - ARTICLE 8 TERMINATION OF THE AGREEMENT § 8. 1 This Part 1 Agreement may be terminated by either party upon seven (7 ) days' written notice should the other party fail to perform substantially in accordance with its terms through no fault of the party initiating the termination . § 8.2 This Part 1 Agreement may be terminated by the Owner without cause upon at least seven (7) days' written notice to the Design/Builder. § 8.3 In the event of termination not the fault of the Design/Builder, the Design/Builder shall be compensated for services performed to the termination date , together with Reimbursable Expenses then due and Termination Expenses. Termination Expenses are expenses directly attributable to termination, including a reasonable amount for overhead and profit, for which the Design/Builder is not otherwise compensated under this Part 1 Agreement. ARTICLE 9 BASIS OF COMPENSATION The Owner shall compensate the Design/Builder in accordance with Article 5, Payments, and the other provisions of this Part 1 Agreement as described below. § 9. 1 COMPENSATION FOR BASIC SERVICES § 9. 1 . 1 FOR BASIC SERVICES, compensation shall be as follows : Fifty One Thousand Six Hundred Ninety Nine Dollars and XX/100 $51 ,699. 00 See Attachment "B": for Detail of Costs § 9. 1 .2 AN INITIAL PAYMENT of Twelve Thousand Nine Hundred Twenty Four Dollars and 75/100 ($ 12,924. 75 ) shall be made upon execution of this Part 1 Agreement and credited to the Owner's account as follows: § 9. 1 .3 SUBSEQUENT PAYMENTS shall be as follows: $12, 924.75 at the completion of the Schematic Design of building $12, 924.75 at the 50% completion of the Preliminary Design Documents $12, 924.75 at the completion of the Preliminary Design Documents, statement of the proposed contract sum and proposed project schedule 10 § 9 . 2 COMPENSATION FOR ADDITIONAL SERVICES § 9 .2 . 1 FOR ADDITIONAL SERVICES , compensation shall be as follows : Per the fee schedule attached to the Master Agreement dated April 19 , 2005 § 9 .3 REIMBURSABLE EXPENSES § 9 . 3. 1 Reimbursable Expenses are in addition to Compensation for Basic and Additional Services , and include actual expenditures made by the Design/Builder and the Design/Builder's employees and contractors in the interest of the Project, as follows : NONE . DESIGN/BUILDER SHALL ASSUME ALL EXPENSES 2 FOR RF ! MB RSAQI E EXPENSFS peRsatienshall be a multiple of-4 v. v . c m wcvvv c.n,i o � � 000 , ccni�n \ tomes the amo . n+c a enrd e.J § 9 .4 DIRECT PERSONNEL EXPENSE is defined as the direct salaries of personnel engaged on the Project, and the portion of the cost of their mandatory and customary contributions and benefits related thereto , such as employment taxes and other statutory employee benefits , insurance , sick leave , holidays , vacations , pensions and similar contributions and benefits . § 9 .5 INTEREST PAYMENTS § 9 .5. 1 The rate of interest for past due payments shall be in accordance with the Florida Prompt Payment Act as (allows: 0 (Usury laws and requirements under- the FedeFal Truth iP / eRGnn A f SiMiIaF tat ..l /er•al n nn. .mer re& la . and tithe , ./adeno at the Q . .neF� d D /Q 7.J vafidit)r of this pFoWsion. Spec-ifiG legal adviGe should be obtained ts4th FespeGt tG § 9. 6 IF THE SCOPE of the Project is changed materially, the amount of compensation shall be equitably adjusted . § 9 .7 The compensation set forth in this Part 1 Agreement shall be equitably adjusted if through no fault of the Design/Builder the services have not been completed within ( 6 ) months of the date of this Part 1 Agreement. ARTICLE 10 OTHER CONDITIONS AND SERVICES § 10 . 1 The Basic Services to be performed shall be commenced on Upon written notice to proceed from Owner and , subject to authorized adjustments and to delays not caused by the Design/Builder, shall be completed in One Hundred Sixty ( 160 ) 11 calendar days . The Design/Builder's Basic Services consist of those described in Section 1 . 3 as part of Basic Services , and include normal professional engineering and preliminary design services , unless otherwise indicated . § 10 . 2 Services beyond those described in Section 1 .4 are as follows : (Insert descriptions of other services, identify Additional Services included within Basic Compensation and modifications to the payment and compensation terms included in this Agreement.) None § 10.3 The Owner's preliminary program , budget and other documents , if any, are enumerated as follows : Title Date Attachment "A" — Project Program April 10 , 2007 This Agreement'On) eyed into as of the day and year first written above . OWN EEO :;�' z � t : ` ; ; �_ DESI NIBUI ER m 25 t (Signat (Si naturIII Gary eeJer,'`ChairmM of BCC Phil Barth , President (Printed name a—Wi titl ) (Printed name and title) APPROVED AS TO FORM AND LEGAL SUFFICI Y APPROVED sY ILLIAM RAAL ASSISTANT COUNTY ATTORNEY young' dmjnlstrA ( Or Attest : J . K . Barton , Clerk Deputy Clerk 12 ATTACHMENT "A" Project Program Indian River County Emergency Services Gifford Community Station - Two Bay Prototype Repeat Station This will be a 2 bay, approximately 8,000 square feet prototype station based on the Miami Dade County floor plan and specifications provided by Indian River County. The structure will be concrete block, fully sprinkled and designed to the current building codes. The exterior finishes will be determined at a later date The following item will be included in the design of this station. Two bays 75 feet in length with two 12 ' x 14' roll up doors Split dorm with a total of 10 beds and lockers for three shifts Unisex ADA restroom off of lobby Secure access from lobby to rest of station- lobby is only public access area Men ' s and Women ' s ADA restrooms with two showers each Conditioned room for Gear with floor drains and incandescent lighting Conditioned room for EMS Storage Work Room with tub sink, washing machine, icemaker and safety shower Exercise room approximately 20 ' x 24 ' Kitchen is contain, 3 pantries, 3 refrigerators, gas range/oven with hood, dishwasher stainless counter tops Office/dispatch area with storage closet Day room/ dining area Covered Patio Lawn equipment storage with roll up door 1 OOKW backup generator with transfer switch, powered by LP gas Fire sprinklers through out building Shore power outlets in apparatus bays 6" concrete aprons in front of each bay door Standing seam metal roof Impact windows with shutters Owner Date 13 / 1 BARTH Construction, Inc. PROGRAMMING & PRECONSTRUCTIONS SERVICES Project: Gifford Community Station months Date: 4.03.07 0 wks Ester months and square I"outage above, all items on the spreadsheet in yellow will automatically change. Labor Mat TOTAL CODE DESCRIPTION i QTY 1UNITIi Unit I LABOR Unit MATERIALS SUB Imdudn Cost I Cast No Tax BID Iaz Q°61 Deis n Builder Desi Build Executive Phil Barth 4 Hrs 150 600 0 0 0 600 Estimator/Project manager Jason F 150 Hrs 100 159000 0 0 0 15000 Su erintendent 1 8 1 Hrs 1 75 1 600 1 0 1 0 1 0 600 Clerical 1 16 1 Hrs 1 45 1 720 1 0 1 0 1 0 720 Architectural Services 1 I LS I I 1 0 1 0 1 -87-70-1 8770 D Strutural Engineer 1 LS 0 0 0 0 ,-r MEP Engineering 1 LS 0 0 0 0 y Civil Desi & Permitin 1 LS 0 0 22500 22500 O Landscape & Irrigation Desi I I 'S - 0 0 7500 7500 R m Surve s I 1 fS 1 0 0 3200 3200 Soil Borings/Foundation Report I I LS 1 0 1 01 3500 1 3500 LS 1 0 1 01 0 1 00 Forensic Demolition 1 I LS 01 01 0 1 0 Document Reproduction/Printing Reproduction/Printing250 ca 0 1 1 1 250 1 0 1 268 IShipping I Is I 1 0 1 1 0 1 0 1 0 Miscellaneous Office Overhead 0 I 'S 0 1 0 0 0 Total 1 16,9201 2501 45,47015 62 658.00 Contingency @ 10% $ 69265.80 Less Amount of Work Order Dated 3.10.06 $ (17,225.00) Total $ 51,698.80