HomeMy WebLinkAbout2003-340/J l/ •Oy
AGREEMENT
INDIAN RIVER COUNTY, FLORIDA
BAYTREE, MARBRISA, AND SEAGRAPE TRAIL DUNE RESTORATION
PROJECT
THIS AGREEMENT made and entered into on the 1 hth day of nPcPmhPr , 2003, by
and between. Henry Fischer and Sons, Inc. 10729 US Rt. # 1 Sebastian, FL 32958
(Name and Address)
herein after called the CONTRACTOR, and INDIAN RIVER COUNTY, a Political
Subdivision of the State of Florida organized and existing under the Laws of the State of
Florida, hereinafter called the COUNTY, or OWNER.
WITNESSETH:
That the CONTRACTOR and the COUNTY, for the consideration hereinafter named,
agree as follows:
Article 1. SCOPE OF WORK: The CONTRACTOR shall furnish all of the materials
and perform all the work shown on the Drawings and described in the
Specifications entitled:
INDIAN RIVER COUNTY BAYTREE, MARBRISA, AND SEAGRAPE
TRAIL DUNE RESTORATION PROJECT
for Indian River County, Florida and shall do everything required by this
Agreement and Contract Documents. Payment shall be made in accordance
with the Itemized Bid Schedule attached as Exhibit "A" and made a part of
this agreement.
Article 2. COMMENCEMENT AND COMPLETION & LIQUIDATED DAMAGES:
As time is of the essence, the Contractor will be required to commence work
under this contract within ten (10) calendar days after receipt of the notice -to -
proceed and shall complete the project by March 1, 2004 as specified in the
Supplementary Conditions, Paragraph I. The CONTRACTOR agrees to
reimburse Indian River County, Florida for liquidated damages for each
calendar day elapsing between the date herein specified as the day of full
completion and the actual day of such completion of the Contract work the
amount of $2,000.00 per calendar day in accordance with the schedule of
damages listed in Article 840.2 of Florida Department of Transportation
Standard Specifications for Road and Bridge Construction, 2002 edition. Said
damages shall not exceed 20% of total amount of the contract. Liquidated
damages are hereby fixed and agreed upon between the parties, recognizing
the impossibility of precisely ascertaining the amount of damages that will be
sustained by OWNER as a consequence of such delay, and both parties
desiring to obviate any question or dispute concerning the amount of such
0 aj.42 V6
damages and the cost and effect of the failure of CONTRACTOR to complete
the Contract on time. The above -stated liquidated damages shall apply
separately to each portion of the Project for which a time for completion is
given. The CONTRACTOR and OWNER agree that OWNER is authorized to
deduct all or any portion of the above -stated liquidated damages from the
monies due to CONTRACTOR for the Work under this Contract as the
OWNER deems just and reasonable. In addition to the above -stated
liquidated damages, the CONTRACTOR shall be responsible for reimbursing
OWNER for all costs incurred by OWNER to third party consultants
including, without limiting the generality of the foregoing, any ENGINEER in
administering the construction of the Project beyond the Substantial
Completion date as specified in the Contract or beyond an approved extension
of time granted to CONTRACTOR, whichever date is later.
Article 3. THE CONTRACT SUM: The COUNTY will pay the CONTRACTOR for
performance of the Contract, subject to additions and deductions provided
therein, in current funds as follows:
Numerical Amount $ 206,772.50
Written Amount Two Hundred Six Thousand, Seven Hundred
Seventy Two Dollars and Fifty Cents
Article 4. PAYMENT AND RETAINAGE: Progress payments on the Contract amount
for the value of work completed and component material on site will be made
upon request at not less than monthly intervals. The request must be made
through the ENGINEER on an approved estimate showing the component
breakdown of the work for each item completed at the time of the request.
Except as may be modified herein, ten percent (10%) of all amounts earned
will be retained by the COUNTY until final completion and acceptance of the
Contact. CONTRACTOR shall allow adequate processing time for County
Commission final acceptance and approval for final payment. The
CONTRACTOR shall make the following certification (Affidavit) on each
Request for Payment: "I hereby certify that the labor and materials listed on
this Request for Payment have been used in the construction of this Work and
payment received from the last request for payment has been used to make
payments to all subcontractors, laborers, material, men and suppliers except as
listed below:
Notice of Non -Payment. If one or more "Notice of Non -Payment" or "Notice
to OWNER" is received by the OWNER, no further payments will be
approved until non-payment(s) have been satisfied and a "Lien Waiver" for
each "Notice" has been submitted to the OWNER. Upon request,
CONTRACTOR shall furnish acceptable evidence that all such claims have
been satisfied. The CONTRACTOR may, with consent of Surety and
indemnification of the COUNTY against any claims, receive payment for
work for which there is an outstanding Notice of Non -Payment or Notice to
OWNER.
Article 5. ACCEPTANCE AND FINAL PAYMENT: Upon receipt of written notice
that the work is ready for final inspection and acceptance, the ENGINEER
will promptly make such inspection and when he finds the work acceptable
under the terms of the Contract and the Contract fully performed, he will
promptly issue a final completion certificate, over his own signature, stating
that the work provided for in this Contract has been completed, and
acceptance by him/her under the terms and the conditions thereof is
recommended and the entire balance found to be due the CONTRACTOR,
will be paid to the CONTRACTOR by the OWNER following County
Commission approval of the final Contract payment.
Before issuance of a final completion certificate, the contractor shall submit
evidence satisfactory to the COUNTY Coastal Engineer that all payrolls,
material bills, and other indebtedness connected with the work have been
paid. An affidavit must be submitted by the CONTRACTOR to the OWNER
stating that all indebtedness connected with the work has been paid. Such
affidavit will be signed by a duly authorized officer of the contractor, will bear
the firm's seal, and will be notarized and attested by two witnesses. A Waiver -
of -Lien form signed by a duly authorized officer of all Subcontractors,
notarized and attested by two witnesses is required from each Subcontractor
engaged under the scope of this Contract, and must accompany the request for
final payment.
Acceptance of Final Payment as Release. The acceptance by the
CONTRACTOR of final payment shall be and shall operate as a release to the
OWNER from all claims and all liability to the CONTRACTOR other than
claims in stated amounts as may be specifically excepted by the
CONTRACTOR for all things done or furnished in connection with this Work
and for every act and neglect of the OWNER and others relating to or arising
out of this Work. Any payment, however, final or otherwise, shall not release
the CONTRACTOR or his/her sureties from any obligations under the
Contract Documents or the Payment and Performance Bonds.
Article 6. INDEMNIFICATION: CONTRACTOR agrees to indemnify and hold
harmless the OWNER, together with its agents, employees, elected officers
and representatives, from liabilities, damages, losses, and costs, including but
not limited to, reasonable attorney's fees, to the extent caused by the negligence,
recklessness or intentionally wrongful conduct of the CONTRACTOR and
persons employed or utilized by the CONTRACTOR in the performance of this
Contract. This indemnification and hold harmless provision shall survive the
termination or expiration of this Contract.
Article 7. PUBLIC CONSTRUCTION PAYMENT AND PERFORMANCE BOND:
The CONTRACTOR shall furnish the COUNTY immediately upon execution
of this Contract a Performance Bond in an amount equal to 125% of the
contract price and a Payment Bond in an amount equal to 100% of the
contract price with good and sufficient sureties, conditioned upon the
performance of this Contract by the CONTRACTOR in accordance with the
terms and conditions hereof, within the time herein provided, and with the
additional obligation that such CONTRACTOR shall promptly make
payments to all persons supplying him labor, materials and supplies, used
directly or indirectly by the said CONTRACTOR in the prosecution of the
work provided for in this Contract.
The CONTRACTOR shall record the Payment and Performance Bond with
the Public Record Section of the Indian River Courthouse located at 2000 16th
Avenue, Vero Beach, Florida, 32960. The recorded bonds will be forwarded
to the Purchasing Division within one week.
The CONTRACTOR shall provide two separate bonds; a combined Payment
and Performance Bond for 125% of the contract price is not an acceptable
substitute.
Article 8. REMEDIES AND CHOICE OF LAW:
This Agreement shall be governed by the laws of the State of Florida. Any legal
actions instituted under this Agreement that are justiciable in state court shall be
instituted in Indian River County. Any legal actions instituted under this
Agreement that are justiciable in federal court shall be instituted in the Southern
District of Florida. No remedy herein conferred upon any party is intended to be
exclusive of any other remedy and each and every such remedy shall be
cumulative and shall be in addition to every such remedy given hereunder or now
or hereafter existing at law or in equity or by statute or otherwise. No single or
partial exercise by any party or any right, power, or remedy hereunder shall
preclude any other or further exercise thereof.
Article 9. GENERAL PROVISIONS
9.1 . Independent Contractor. The parties expressly recognize that the
relationship between the COUNTY and CONTRACTOR is that of
OWNER and independent contractor, and that neither the
CONTRACTOR nor any of his servants, agents, or employees shall ever
be considered to be an agent, servant or employee of the COUNTY.
9.2. Pledge of Credit. The CONTRACTOR shall not pledge the
COUNTY'S credit or make it a guarantor of payment or surety for any
Agreement, debt, obligation, judgment, lien or any form of indebtedness. The
CONTRACTOR further warrants and represents that it has no obligation of
indebtedness that would impair its ability to fulfill the terms of the
Agreement.
9.3. Counterparts. This Agreement may be executed in one or more
counterparts, but all such counterparts, when duly executed, shall constitute
one and the same Agreement.
9.4. Public Records. The COUNTY and the CONTRACTOR shall comply
with the provisions of Chapter 119, Florida Statutes (Public Records Law) in
connection with this Agreement.
9.5. Notices. All notices, requests, demands, approvals, consents, and other
communications required or permitted under this Agreement shall be in
writing and shall be (as elected by the person giving such notice) hand
delivered by messenger; delivered by commercial overnight courier service;
sent by facsimile/telecopier; or mailed by registered or certified mail (postage
prepaid) return receipt requested and addressed to:
As to COUNTY: James D. Gray, Jr.
Department: Indian River County Public Works Dept.
Address: 1840 25th Street
Vero Beach, FL 32960
With a required copy to:
As to CONTRACTOR:
Henry Fischer and Sons, Inc.
Mr. Jim Davis, P.E.
(address as above)
10729 US Rt. # I Sebastian, FL 32958
or to such other address as any party may designate by notice complying
with the terms of this Section. Each such notice shall be deemed delivered
and effective on the date of hand delivery, or on the second day after the
date of deposit of notice with an overnight courier service, or on the date
upon which the return receipt is signed or delivery is refused or the notice is
designated by the postal authorities as not deliverable, as the case may be, if
mailed.
Ll
IN WITNESS WHEREOF, the parties hereto have executed this agreement the day and
year first written above.
Signed and sealed by the
CONTRACTOR in the presence of
C#Aaw�A wi4...JA
INDIAN RIVER COUNTY
(OWNER)
Kenneth R. Macht, Chairman
BCC Approved: December 16, 2004
(Seal)
TO FORM
IRFICIENCY
b'(
AA7 *. V&Ar - l'
�.P4 Ya
zx'ot� ))7 l
IJeffrey K. Barton, Clerk
AA7 *. V&Ar - l'
�.P4 Ya
zx'ot� ))7 l
IJeffrey K. Barton, Clerk
BK: 1683 PG: 305
its obligatious on this Bong, and it does hereby waive notice of any such change, extension of
time, alteration or addition to the terms of the Contract or to the work or to the Specifications and
Drawings. Principal and Surety expressly acknowledge that any and aU provisions relating to
liquidated damages contained in the Contract Documents are expressly covered by and made a
part of this Bond_ Principal and Surety acknowledge that any such provisions tie within their
obligations and within the overages and limitations of this Bond
AND, the said Principal and Surety jointly and severally covenant and agree that this Bond will
remain in M force and effect for a period of one year commencing on the date of Final
Completion as established on the Certificate of Final Completion as issued by the County of
ladian River.
Signed, sealed and delivered in the presenoe of
Witness
-0. �RMMMTJ�1111111
PERFORMANCE BOND PE -2
A TRUE COPY
CERTIFICATION ON LAST PAGE
J.K. BARTON, CLERK
BK: 1683 PG: 306
TRADE NAME
-
Signed, sealed and deliver'ecI in the presence of:
Witness
Witness
Name of Firm
Witness
Witness
• :♦ p
PE -3
A TRUE COPY
CERTIFICATIONON LAST PAGE
J.K. BARTON, CLERK
BK: 1683 PG: 307
Henry Fischer Sons Inc.
Name of Corporation
By:
(Affix Cmparnte Seat}
Henry A. Fischer
Friated Name
Secretary
Official Title
iw
. ... LJ t. �.. 1'. 1 �. 1 ' ¢ . .. . I • I • ' 1 1: .
1
11 • .
00-430.ration by aWbodtyof A .
I . 4. .
By. sx
(Affix Corporate 5 c
David B. Shick y;0 . `2
Atton=y-ln-Fact ip• t �. .:C?�
The Pro:Sure Grauer Ime
A TRUE COPY
CERTIFICATION ON LAST PAGE
J.K. BARTON, CLERK
BK: 1683 PG: 308
Telephone: ( 813) 243-1110
STATE OF FLORIDA
COUNTY OF INDIAN RWER
Befbre1•- Notary1 dulycommissioned, 11 i. •1acting, pemnaUy appeared
David B. Shick to ine well knowm6 who being by me
first duly •• / 1 .: 1
Capitol. says that he/she is the aftorney-in-fact for *e
Indemnity••
b�c Of the Coll TRAUM named thmin in
favor of the
200148
My nnumsio Expires
Aoo _
,••"�o/• , Marianas Bamola
5C�mm# CC920277
:�2 ins i[ay
ar '" 1� ildon
5, 2005
'•+��.. drP: Bonded Tera
i 18110 •. AlIntle Bonding Cm, T=
PE -5
A TRUE COPY
CERTIFICATION ON LAST PAGE
J.K. BARTONr CLERK
BK: 1683 PG: 309
INDIAN RIVER COUNTY
BAYTREE, MARBRTSA. AND SE GRAPE TRAM DUNE RESTORATION PROJECT
PAYMENT BOND
.KNOW ALL MEN BY THESI, PRESENTS:
That we Heresy Fischer & Sons, Inc. as Principal, and Capitol Irdermity
as Surety, are held and firmly around unto the County of Indian .River in the sum of-�
irio raaSix lrror-
�and Seven
Dollars ($ 206,772.50 1, amounting•to 100% of the total bid price, for the paymentai� we bind 01100
ourselves, our heirs, executors, administrators and assigns, jointly and severally, for the faithful performance
of a certain written c:ottract, d: tied thel l�3 day of 2003, entered intofbetween the
Principal and the County of Indian River, Florida, for.
Baytree Mar)risa and Seaeram mit ,a . e
A copy of said Contract is incorporated herein by reference and is made a part hereof as if fully copied
herein.
NOW, TMREFORE, THE CONDITIONS OF TRIS OBLIGATION ARE SUCH, that, if the Principal shall
Promptly make payments to all claimants, as herein below defined, then this obligation shall be void;
otherwise, this Bond shall remain in full force and efi'ect, subject to the following terms and conditions:
A. A claimant as defined in Florida Statutes section 255.05 (1) supplying the Principal with
labor, matciels, or supplies, used directly or indirectly by the Principal in the prosecution
of the work pr )vided for in tate Contract;
B. The provisions of Section 255.05 Florida Statutes, together with all notice and time
provisions contained therein, shall apply to this Bond.
This Bond shall remain in full force and effect for a period of One (1) year from the completion of
Performance of the labor or completion of delivery of the materials and supplies under the Contract,
No action on this Bond shall ba brought other than in a state conn of competent jurisdiction in and for Indian
River County, Florida, or in the United States District Court for the Southern District of Florida, and not
elsewhere.
The Principal and the Surety jointly and severally. shall repay the County of Indian River any sum which it
may be compelled to pay beutuse of any lien for labor or materials furnished for any work included in or
provided by said Contact
The Surety, for value received, bereby agrees that no change, extension of time, alteration of or addition to
the terms of the Contract or to the work to be performed thereunder or to the Speciticaiions applicable
thereto, or compliance or nonc7mplialtoe With any formalities connected with the Contract or any changes in
or under the Contract shall in any way affect its obligations on this Bond, and the Surety hereby waives
notice of any such change, exitw5lon of time, alterations of or addition to the terms of the Contract, or to the
work or to the Specifications,
1N WITMSS WJUREOF, tht, above bounded parties executed this instrument under their several seals this
k day of Tr. 2003) the name and corporate seal each corporate party being hereto
affixed and these presents trly signed by its undersigned representative, pursuant to authority of its
governing body.
PAYMENT BOND PA -I
A TRUE COPY
CERTIFICATION ON LAST PAGE
J.K. BARTON, CLERK
BK: 1683 PG: 310
W}31�N THE PRfiICTPAL TS Ax txn�UAT,;
Address
is ,
Address
r . 11 • 1 I.'
Signed, sealed and delivered in the presence of
Witness
M
Witness
Address
HAM•1 LZRINCIPAL
delivercd in the pre$eWe of!
PAYMENT BOND
Printed Nam of individual
Name of Firm
PA -2
A TRUE COPY
CERTIFICATION ON LAST PAGE
J.K. BARTON, CLERK
BK: 1683 PG: 311
MWF
Henry Fischer & Sona, Inc.
Name of Corporation
By:
(AMx Corporate Seal)
Henry g, Fischer
Primed Name
Secretary
Oficial Title
Ir
"ER 1 I
certify that I gun the S=etarY Of t1- . . I . ,1 named
6140� who
hen signed
1said corporation;1
I >f 1 I
g=dM; :I• 1: I i. •.. duly
'11-1
1,11 bChalf4Df Said cOrPoradoa by authority of Its govardag body.
P.O. Box 5900, Madison, WI 53705
Business Address'':aii,;<,a
C 231-41
Telephone:
>1 a
((Affix Corporate S e :.�� ,„,� • h �,._;
David B• J111.:R ¢ 'Vy' �••�H� �''�,4'
Attorney -la -Fact `�Axl,Vk�.............:.Wi..•
PAYNWNT BOND PA -3
A TRUE COPY
CERTIFICATION ON LAST PAGE
J.K. BARTON, CLERK
. BK: 1683 PG: 312
7217 Benjamin Road, Tmnpa, FL 33634
Business Address
Telephone: (813) 2+3-1110
STATE OF FLORIDA
COUNTY OF INDIAN RI1BR
Before me, a Notary -public, dulY c0mulisw=4 qualified and
1- • Y acting, rte. 1. appeared.to = well known, who being bY Me first duly swor-,be/shc 11" been authorized by CaPitol IndemrLityC4=p=tj0n to execute the foregoingbond on behalf of the CONTRACTOR named therein in �fitvor of the Couuty of Indian River,Florida. Subscribed and svA)rn to before r= this 15th 11.day of .4painy 20V
My sios E ires
0!1
MarlanellaBarnola
±f' pam
y i1 i�1•`, Atlantic 1102 Bm-. In6
A TRUE COPY
CERTIFICATION ON LAST PAGE
J.K. BARTON, CLERK
a I , BK: 1681 PG: 1440
Y9 INDEMNITY CORPORATION
4610 UNIVERSFY AVENUE, SUITE 1400, MADISON, WISCONSIN 53705-0900
PLEASE ADDRESS REPLY TO P.O. BOX 5900, MADISON, WI 53705-0900
PHONE (608) 231-4450 r FAX (608) 231-2029
o. y
alma ME uvnub, unQerMKtngS And contfactsofeur
suretyship executed under this Authority shall excbed ,jn Amat
oezqRmfy in r•T~. wry w m U
e nature one or more fasldent vice<F�dents, ds nt•eoretarma anti
usual ro such offices to the b loess of Chia canpany: the atgnalure of Such oHtoere end Seal of iiia
arty ceftifio n relating thereto by facsimile, and any Such power of attamey or cxrditeate bas Uig
bind" upon the Cpmparry, and any such power so exeeuted and aertifR+d by faealmfle aignafureb a
in the iuRue witty respect to any bond or unde laking or o wd ng.p lio t" in the.ngture thareori
(of"cause. or without cause, by any of said officers, at any tions,"
IN WITNESS WHEREOF, the CAPITOL INDEMNITY 6ORPORATH
its officer undersigned and its fxnporate seai'.to ire fierft affiixed duly atte§l
w ru ur: lis Perim, as surety, and as its act and
that ncr bond or undertaking or contract of
Vile under and by tate authority of the following
�ORPORATION at a meeting duly called and
fndi4iduatl_". _ .yaroti erwIse, be andttratr hereby arepranietf
- ry va.,va
T"ny!rowtmik tbany Such power of attorney or to
h facs5tiite 1 i19ndWiag or fe66lm4e 8681i1hall be vatid and
resirnlle seal shah be valid and binding upon the company
tloh"le atEacKed, Any etch appointment: may be revoked, ;
has caused these presents to be signed by
by its Tteastrrer, this 15th day of May; 2002;
PITOL INiDEMNITY CORPORATION
no DAVid,P Pauly, to the known, Who being by me duly
ane, State. of WiSwri=M; that he is the Secretary of
1411 ]9MI w61n1a. auto"v{ww1 ♦L.- .L �.._.._a... ... ..
WIIFaWw
e
W..IV.l&.P!
signed his
auk,, c„ urt,rur-ace neat; tyra2
thereto
n
was so affixed
name by like order."
•e00 mtolt
' •
k -I�N-
SUPPLEMENTAL INFORMATION
BOND No. 0000915991
NAME, PRINCIPAL BUSINESS ADDRESS, AND PHONE NUMBER OF THE CONTRACTOR, as
Principal:
Henry Fischer & Sons, Inc.
P.O. Box 780068
Sebastian, Florida 32978-7731
(772) 589-7731
NAME, PRINCIPAL BUSINESS ADDRESS, AND PHONE NUMBER OF SURETY, as Surety:
Capitol Indemnity Corporation
4610 University Avenue, Suite 1400
Madison, Wisconsin 53705
(608) 231-4450
Owners and Addresses Of The Within Described Property:
Baytree Condominium Association
8384 Calamandren Way
Vero Beach, Florida 23963
(772) 234-0417
Indian River County Board of County Commissioners
1840 25th Street
Vero Beach, Florida 32960-3365
(772) 567-8000
Marbrisa Homeowner's Association
540 North Monterey Drive
Vero Beach, Florida 32963
(772) 234-6344
Description of the Project and the Improvement:
Supplying, trucking and placing compatible upland fill to restore beach
dunes along 2000 feet of Atlantic Ocean shoreline between a point 200
feet north of Department of Environmental Protection (DEP) reference
monument T-46 and a point 200 feet south of DEP reference monument R-48.
01/15/2004 THU 12:00 FAX. 772 589 4689 SID BANACS INS [1001
ACORD
DATE (hWDDAfY)
TM. CERTIFICATE OF LIABILITY INSURANCE JAN 1504
FRO
$ID BAWAW CK INSURANCE AGENCY THE CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
2046 14TH AVE. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
P O BOX t30 HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THECO RDED BY TH P ES BELOW,
VERO BEACH FL 32961
PHONE: 772462-3359 INSURERS AFFORDING COVERAGE I NAIC i)
INSURED INSURERA; TRANSPORTATION INSURANY
NOON ...NNOOO
R B; CONTINENTAL CASUALTY CO
HENRY FiSCHER 8 SONS INC, NORTH CYPRESS RESERVE, INC !
NsuRE CE COMPANY
DBA ENVIRONMENTAL MULCH, INC DBA HENRY FISCHER & •• INSURER C: VALLEY FORGE INSURANCE COMPANY
0617200
SONG L 0�
EASING BfBURER D
...
INSURER E: �
E
THE POLICIES OF INSURANCE LWMD BELOW HAVE BEEN 1041JEA TO THE INSURED NAMED ABOVE FOR THE POLICYPERIOD INDICATED, NOTWRHSTANDINO
ANY REQUIRWIENT, TERM OR CONDITION OF ANY CONTRACT CR OTHER DOCUMENT WIYH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES, AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
_ �_. _...P.
_..w_...,...
IN TYPE OF[ NSURANCE POLICY NUMSER POLICY FFFECTI! POLICY WRATION LIMITS
N
iN4RA4 LIABILITY C 1022578176 OCT 22 03 OCT 22 04 SACH OCCURRENCE g 1,000,
E ..
6 _pAEM12F.8 me To►� wev4) 50,000
X�I COONMERCIAL GENERAL LIABILITY DAMAGE
NNONI
CLAIMS MADE �( OCCUR MeO. EXP (Ary Orr Posen) @ 31000
....I .... _. PERSONALSAOVINJURY `S 1.000,
000
., _I ..... I6 2000,000
0EN'1 AGGREGATE LIMfCAPPLES PER:
PRODUCTS COMP OP AGD ...S 20000,000
FOLICY
AUTOMOBILE LIABILITY C 10225713193 OCT 22 03 OCT 22 04 COMBINED SINGLE LIMIT
X ANYAUTp I(Eaowident) E 1,000,000
��.,... ,
ALL OWNED AUTOS BODILY INJURY
A SCHEDULED AU705 (Per on)
X HIRED AUTOS
BODILY INJURY f
WX NON-OWNED AUTOS
(Px acddent)
._ PROPERTY DAMAGE E
GARAGE LIABILITY
AUTO ONLY. EAACCIDEN'I
'
ANY AUTO .'� .. .
OTHER THAN EA ACC S
AUTO ONLY?
LGXCBSBIUMIIGRGLLALIASILMY EACH OCCURRENCE 1
OCCUR
CLAIMS NWOE t AGGREGATE 6
........
DEDUCTIBLE
j RETENTION g _ �.'
9
WORKERS COMPENSATION AND WC 173727133 JAN 104 JAN 105 TORVTUM�rrs 1 __ _
EMPLOYERS LLABILITY OTHER
W
C I ENT IRKWMETO@TARMEt OIXIECUTNE E.L. EACH ACCIDENT Jm�Z y 100,000
[Nvec Eevlbc �lExa7 E.L. 0166ASE-EA EMPLOYEE S 100,000
9P9aALPROYISIONSee4m ' I E.L. DISEASE-POLICY LIMIT 1 $ 5001000
OTHER: NLAND MARINE C1022978176 OCT 22 03 OCT 22 04 SCHEDULED EQUIPMENT ON FILE WITH
EB THE COMPANY
DESCRIPTION OF OPERATIONWLOCATIONIVEMCLES/EXCLUSIONS ADDED ENDORSEMENT/ SPECIAL PROVISIONS
INDIAN RIVER COUNTY FLORIDA, MARBRISA HOMEOWNERS ASSOCIATION INC,, AND BAYT'REE CONDOMINIUM ASSOCIATION, INC ARE
NAMED AS ADDITIONAL INSURED ON BOTH THE GENERAL LIABILITY AND AUTO LIABILITY BUT ONLY WITH RESPECT TO THE NAMED
INSUREDS OPERATIONS, WAIVER OF SUBROGATION APPLIES TO WORKERS COMPENSATION, FAXED TO 794-7447
HOLDER i AQWONAL IN.3URED; INSURER LJEITER: CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO NAIL tO
DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT
FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE
INDIAN RIVER COUNTY INSURER ITS AGENTS OR REPRESENTATIVES.
BOARD OF COUNTY COMMISSIONERS
1840 26TH STREET AUTHORIZED REPRESENTATIVE
VERO BEACH, FL 32960-3365
Attentonq
ACORD 26 (2001/08) Certificate 9 73990 Michael W. Harris
James
From: Fran Powell
Sent: Tuesday, January 20, 2004 2:54 PM
To: Beth Jordan; James Gray
Subject: RE: COI Henry Fischer and Sons
Received Beth's OK on the COI today for bid #6002 baytree, marbrisa and
seagrape.
Fran Powell, Manager
Purchasing Division
-----Original Message -----
From: Beth Jordan
Sent: Tuesday, January 20, 2004 2:43 PM
To: James Gray
Cc: Fran Powell
Subject: RE: COI Henry Fischer and Sons
I received one from Purchasing for this project, but I don't remember if it was for Fischer; please check
with Fran Powell to see if it was the one I signed off on. Thanks
-----Original Message -----
From: James Gray
Sent: Tuesday, January 20, 2004 1:23 PM
To: Beth Jordan
Subject: COI Henry Fischer and Sons
Beth,
I was wondering if you had received the COI from Henry Fischer and Sons for the Baytree and Marbrisa
Dune Restoration Project IRC Bid # 6002.
Thank you,
James
James Gray, Jr.
Coastal Engineer
Indian River County Public Works
1840 25th Street
Vero Beach, Florida 32960-3365
(772) 567-8000 x 1344
Fax (772) 778-9391
jgray@ircgov.com
1