2003-118 - Laserfiche WebLink

Home Browse Search

payment, or ( 4) ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract Sum , 2 . 6 . 3 . 3 The Architect shall maintain a record of the Contractor's Applications for Payment. 2 . 6 . 4 SUBMITTALS 2 . 6 . 4 . 1 The Architect shall review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect's action shall be taken with -seeh - reasonable pr-emptness within two weeks of receipt of such submittals as to cause no delay in the Work or in the activities of the Owner, Contractor or separate contractors, while This document has important legal allowing sufficient time in the Architect's professional judgment to permit adequate review. consequences. Consultation with an Review of such submittals is not conducted for the purpose of determining the accuracy and attorney is encouraged with respect to completeness of other details such as dimensions and quantities, or for substantiating its completion or modification. instructions for installation or performance of equipment or systems, all of which remain the AUTHENTICATION OF THIS responsibility of the Contractor as required by the Contract Documents. The Architect's ELECTRONICALLY DRAFTED AIA review shall not constitute approval of safety precautions or, unless otherwise specifically DOCUMENT MAY BE MADE BY USING stated by the Architect, of any construction means, methods, techniques, sequences or AIA DOCUMENT D401. procedures. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. 2 . 6 . 4 . 2 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in accordance with the requirements of the Contract Documents , 2 . 6 . 4 . 3 If professional design services or certifications by a design professional related to systems, materials or equipment are specifically required of the Contractor by the Contract Documents, the Architect shall specify appropriate performance and design criteria that such services must satisfy. Shop Drawings and other submittals related to the Work designed or certified by the design professional retained by the Contractor shall bear such professional's written approval when submitted to the Architect. The Architect shall be entitled to rely upon the adequacy, accuracy and completeness of the services, certifications or approvals performed by such design professionals . 2 . 6 . 5 CHANGES IN THE WORK 2 . 6 . 5 . 1 The Architect shall prepare Change Orders and Construction Change Directives for the Owner's approval and execution in accordance with the Contract Documents . The Architect may, with proper approval of the Owner, authorize minor changes in the Work not involving an adjustment in Contract Sum or an extension of the Contract Time which are consistent with the intent of the Contract Documents. If necessary, the Architect shall prepare, reproduce and distribute Drawings and Specifications to describe Work to be added, deleted or modified, as provided in Paragraph 2.8.2. 2 . 6 . 5 . 2 The Architect shall review pr-epeFlypFepafed, -timely reasonable requests by the Owner or Contractor for changes in the Work, including adjustments to the Contract Sum or Contract Time. A pFeper}y prepared request-fer-a change-iff-theWoFk -&ha4-be aeeempenied- © 1997 AIA® by s Fieient in4e pefmit4he e ..Taehiteet4e-make -e r-easefiable- AIA DOCUMENT B141 - 1997 detefming iyitheut emte siveinvestigatieft -of pfeparation -of additieftal dmvvings --of - STANDARD FORM AGREEMENT specifltiens. If the Architect determines that requested changes in the Work are not materially different from the requirements of the Contract Documents, the Architect may The American Institute of Architects with the prior approval of the Owner, issue an order for a minor change in the Work or 1735 New York Avenue N .W. recommend to the Owner that the requested change be denied. Washington, D .C. 20006-5292 2 . 6. 5 . 3 If the Architect determines that implementation of the requested changes would result in a material change to the Contract that may cause an adjustment in the Contract ® 1917, 19261 1948s 19511 19531 1958, 1961s 1963* 1966, 19671 1970, 1974, 1977, 19871 0 1997 by Te American Institute of Architects . Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates U .S. copyright laws and will subject the violator to legal prosecution . This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. User Document: standard agreement admin bldg 97b141(4-8-03).aia -- 5/5/2003. AIA License Number 1127252, which expires on 7/31/2003. 23