2007-361 - Laserfiche WebLink

Home Browse Search

with the judgment of the CONTRACTOR regarding the need to level escarpments. Leveling will be conducted in compliance with sea turtle nesting permit conditions. 31 . 17Tilline . The CONTRACTOR shall , immediately following the completion of fill placement for the project, mechanically till the beach to a depth of 36 inches. Any marked sea turtle nests in the project area will be avoided during the tilling process. 31 . 18 Misplaced Material . The CONTRACTOR shall minimize loss and/or misplacement of fill material. If, during the progress of the work, the CONTRACTOR should lose, dump, throw overboard, sink, or misplace any material, plant, machinery, or appliance which in the opinion of the COUNTY should be removed, the CONTRACTOR shall recover and remove the material(s) immediately . The CONTRACTOR shall provide immediate notice to the COUNTY including a description of and DGPS coordinates for such obstructions. Should the COUNTY observe such obstruction, the COUNTY shall record the position or mark the obstruction and notify the CONTRACTOR. Removal of the obstruction and all associated costs shall be the responsibility of the CONTRACTOR. The COUNTY shall monitor any removal operations. Should the CONTRACTOR refuse, neglect, or delay compliance with the above requirements, such obstructions may be removed by the COUNTY, and the cost of such removal may be deducted from any money due or to become due to the CONTRACTOR or may be recovered under the CONTRACTOR's bond. The liability of the CONTRACTOR for the removal of a vessel wrecked or sunk without fault or negligence shall be limited to that provided in Sections 15 , 19, and 20 of the Rivers and Harbor Act of March 3, 1899 (33 -U .S .C. 410 et. seq .). 32. SITE RESTORATION Site restoration shall include the removal of the CONTRACTOR's plant(s) and all equipment or materials either for disposal or reuse. Plant(s) and/or equipment or materials for disposal shall be disposed of in an appropriate and legal manner at the expense of the CONTRACTOR. Unless otherwise approved in writing by the COUNTY, the CONTRACTOR shall not be permitted to abandon pipelines, pipeline supports, pontoons, or other equipment in the pipeline access areas, water areas, or other areas adjacent to the work site. Any stakes or other markers placed by the CONTRACTOR must be removed as a part of the final site restoration. Grade stakes placed during the fill operation, and pieces of stakes, shall be completely removed and shall not be buried in the fill . All costs associated with site restoration shall be included in the Site Restoration bid item. 33 . BATHYMETRIC SURVEY OF THE BORROW AREA Formatted: Not Highlight The CONTRACTOR shall provide a bathymetric survey of the designated Borrow Areaprior to and immediately after construction. All surveys shall be in accordance with professional standards and practices, and all survey documents shall be signed and sealed by a surveyor registered in the State of Florida. Said surveyor should carry Professional Liability Insurance. The land surveyor employed for this project must comply with the minimum Technical Standards for land surveyors in the State of Florida pursuant to Florida Statute 472.027 adopted rule 121 HH-6. The CONTRACTOR TECHNICAL AND ENVIRONMENTAL SPECIFICATIONS Rev October 5, 2007 TS-32