2012-055 - Laserfiche WebLink

Home Browse Search

§ 4 . 2 Time limits stated in the Contract Documents are of the essence . The Work to be performed under this Part 2 Agreement shall commence upon receipt of a notice to proceed unless otherwise agreed and , subject to authorized Modifications , Substantial Completion shall be achieved on or before the date established in Article 14 . § 4 . 3 Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so the Owner can occupy or utilize the Work for its intended use . § 4 .4 Based on the Design/ Builder' s Proposal , a construction schedule shall be provided consistent with Section 4 . 2 above . § 4 . 5 If the Design/Builder is delayed at any time in the progress of the Work by an act or neglect of the Owner , Owner' s employees , or separate contractors employed by the Owner , or by changes ordered in the Work , or by labor disputes , fire , unusual delay in deliveries , adverse weather conditions not reasonably anticipatable , unavoidable casualties or other causes beyond the Design/Builder's control , or by delay authorized by the Owner pending arbitration , or by other causes which the Owner and Design/ Builder agree may justify delay , then the Contract Time shall be reasonably extended by Change Order . ARTICLE 5 PAYMENTS § 5 . 1 PROGRESS PAYMENTS § 5 . 1 . 1 The Design /Builder shall deliver to the Owner itemized Applications for Payment in such detail as indicated in Article 14 . § 5 . 1 . 2 Upon the Owner' s receipt of a properly submitted and correct Application for Payment , the Owner shall make payment to the Design /Builder in accordance with the Florida Prompt payment Act , FS4 218 . 70 et seq . § 5 . 1 . 3 The Application for Payment shall constitute a representation by the Design / Builder to the Owner that the design and construction have progressed to the point indicated , the quality of the Work covered by the application is in accordance with the Contract Documents , and the Design /Builder is entitled to payment in the amount requested . § 5 . 1 . 4 Upon receipt of payment from the Owner , the Design/Builder shall promptly pay the Architect , other design professionals and each contractor the amount to which each is entitled in accordance with the terms of their respective contracts . § 5 . 1 . 5 The Owner shall have no obligation under this Part 2 Agreement to pay or to be responsible in any way for payment to the Architect , another design professional or a contractor performing portions of the Work . § 5 . 1 . 5 Neither progress payment nor partial or entire use or occupancy of the Project by the Owner shall constitute an acceptance of Work not in accordance with the Contract Documents . § 501 . 7 The Design /Builder warrants that title to all construction covered by an Application for Payment will pass to the Owner no later than the time of payment . The