2012-211A - Laserfiche WebLink

Home Browse Search

dE1a; SCA 6 DISPUTE RESOLUTION SC-16 .02 Mediation SCA 6 Add the following new paragraph immediately after paragraph GC46. 01 . SC- 16 . 02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims , disputes , or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19"' Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties. The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed . SCA7 Miscellaneous Add the following new paragraphs immediately after paragraph GC17. 05F SC- 17 . 06 Liens A. This project is a " Public Works" under Chapter 255 , Florida Statutes . No merchant's liens may be filed against the OWNER. Any claimant may apply to the OWNER for a copy of this Contract. The claimant shall have a right of action against the CONTRACTOR for the amount due him . Such action shall not involve the OWNER in any , expense . Claims against the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in Florida Statutes Section 255 . 05 . The. CONTRACTOR shall insert the following paragraph in all subcontracts hereunder: " Notice : Claims for labor, materials and supplies are not assessable against Indian River Countv and are subject to proper prior notice to (CONTRACTOR'S Name) and to (CONTRACTOR Surety Company Name) , pursuant to Chapter 255 of the Florida Statutes . This paragraph shall be inserted in every sub- subcontract hereunder. " The payment due under the Contract shall be paid by the OWNER to the CONTRACTOR only after the CONTRACTOR has furnished the OWNER with an affidavit stating that all persons , firms or corporations who are defined in Section 713 . 01 , Florida Statutes, who have furnished labor or materials , employed directly or indirectly in the Work , have been paid in full . The OWNER may rely on said affidavit at face value . The CONTRACTOR does hereby release , remiss and quit-claim any and all rights he may enjoy perfecting any lien or any other type of statutory common law or equitable lien against the job . + + END OF SUPPLEMENTARY CONDITIONS ++ 00800-9 00800 - Supplementary Conditions 06-09 rev.doc 00800 9F:\Public Works\ENGINEERING DIVISION PROJECTS\1131 -IR Blvd Resurfacing 41st St to 53rd St-SEE PROJ 0927%drdm\Contract Documents\00800 -