|
ARTICLE 8 TIME
<br /> § 8.1 DEFINITIONS
<br /> § 8.1 . 1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in
<br /> the Contract Documents for Substantial Completion of the Work.
<br /> § 8.1 .2 The date of commencement of the Work is the date established in the Agreement.
<br /> IF
<br /> IF
<br /> § 8.1 .3 The date of Substantial Completion is the date certified by the Architect in accordance with Section 9 . 8 .
<br /> § $. 1 .4 The term "day as used in the Contract Documents shall mean calendar day unless otherwise specifically
<br /> IF .IF
<br /> IF 1 11 defined.
<br /> IF I
<br /> § 8.2 PROGRESS AND COMPLETION
<br /> .11 r IFIrrr rr IF " I § 8:2. 1 Time limits stated in the Contract Documents are of the essence of the Contract. By executing
<br /> the Agreement
<br /> the Contractor confirIrlms that the Contract Time is a reasonable period for performing the Work.
<br /> § 8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, prematurely
<br /> commence operations on . the IF site or elsewhere prior to the effective date of insurance required by Article 11 to be
<br /> IF
<br /> furnished by the Contractor and Owner. The date of commencement of the Work shall not be changed by the
<br /> I :Neffective date of such,ainsurance.
<br /> § 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion
<br /> win the Con
<br /> ithtract Time. ;
<br /> rr
<br /> § ,1.3 DELAYS AND EXTENSIONS OF TIME
<br /> § 8.3.11f the Contractor is delayed at any time in the commencement or progress of the Work by an act or neglect of
<br /> Irl I the Owner or Architect, or of 'nn 'employee of either, or of a separate contractor employed by the Owner; or by
<br /> changes orderedlin thrrre Work :-, by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other
<br /> 11
<br /> causes beyond the Contractor' s control; or by delay authorized by the Owner pending mediation and arbitration; or
<br /> ir
<br /> b" I rI . y other causes that the Architect determines may justify delay, then the Contract Time shall be extended by Change
<br /> IF 1 .11Order for� such reasonable time as the Architect may determine.
<br /> IF - Fit 1
<br /> r1rr . I
<br /> § 8.3.2 Claims IF
<br /> reto tilating me shall be made in accordance with applicable provisions of Article 15 .
<br /> r IF
<br /> § 8.3.3 This Section 8.3 does not IF
<br /> preclude recovery of damages for delay by either party under other provisions of
<br /> IF
<br /> the Contract Documents.
<br /> ARTICLE 9 PAYMENTS AND COMPLETION
<br /> § 9. 1 CONTRACT SUM
<br /> The Contract Sum is stated in the Agreement and, including authorized adjustments, is the total amount payable by
<br /> the Owner to the Contractor for: performance of the Work under the Contract Documents.
<br /> rr
<br /> 'IF r § 9.2•SCHEDULE OF VALUES
<br /> Where the Contract is based on a stipulated sum or Guaranteed Maximum Price, the Contractor shall submit to the
<br /> Fri .IF
<br /> IF r Architect, before:the first Application for Payment, a schedule of values allocating the entire Contract Sum to the
<br /> IF : 2FIF
<br /> F arious portions of the Work and prepared in such form and supported by such data to substantiate its accuracy as
<br /> IF r , Ithe Architect may require. This schedule, unless objected to by the Architect, shall be used as a basis for reviewing
<br /> Air the Contractor' s Applications for Payment.
<br /> IF IF I
<br /> § 9.3 APPLICATIONS FOR PAYMENT
<br /> IF
<br /> § 9.3.1 At least ten days before the date established for each progress payment, the Contractor shall submit to the
<br /> 111I IF
<br /> Architect an itemized Application for Payment prepared in accordance with the schedule of values, if required under
<br /> IF
<br /> rr
<br /> SeIF
<br /> ction 9,2, for completed portions of the Work. Such application shall be notarized, if required, and supported by
<br /> Ill
<br /> such data substantiating the Contractor' s right to payment as the Owner or Architect may require, such as copies of
<br /> requisitions from Subcontractors and material suppliers, and shall reflect retainage if provided for in the Contract
<br /> Documents.
<br /> Init. AIA Document A201 TM — 2007. Copyright © 1911 , 1915, 1918, 1925, 1937, 1951 , 1958, 1961 , 1963, 1966, 1970, 1976, 1967, 1997 and
<br />2007 by The American
<br /> Institute of Architects. All rights reserved. WARNING : This AIA® Document Is protected by U.S. Copyright Law and International Treaties. Unauthorized
<br /> 24
<br /> reproduction or distribution of this AIA® Document, or any portion of It, may result in severe civil and criminal penalties, and will be prosecuted
<br /> to the
<br /> maximum extent possible under the law. This document was produced by AIA software at 11 :28: 34 on 12/21 /2012 under Order No.4386727979 1 which
<br /> expires on 02/05/2013, and is not for resale.
<br /> User Notes: (811102566)
<br />
|