2012-123A - Laserfiche WebLink

Home Browse Search

5 . CONTRACTOR ' s violation of Section 02225 — " Erosion Control and Treatment of Dewatering Water From the Construction Site . " 6 . CONTRACTOR ' s failure to make payment to Subcontractors or Suppliers for materials or labor in accordance with the respective agreements between the CONTRACTOR and the Subcontractors or Suppliers . SC -15 . 04 CONTRACTOR May Stop Work or Terminate SC- 15 . 04 Delete the following text from the first sentence of paragraph GC45. 04. A : er OWNER fails fer 30 days te pay GONT-RAGTOR aRy sum finally deterFR " RGd tG be dWGT SC- 15 . 04 Delete the following text from the second sentence of paragraph GC45. 04. A : due�y SC - 16 DISPUTE RESOLUTION SC - 16 . 02 Mediation SC- 16 Add the following new paragraph immediately after paragraph GC46. 01 . SC- 16 . 02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims , disputes , or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 19th Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties . The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed . SC - 17 Miscellaneous Add the following new paragraphs immediately after paragraph GC 1 T 05: SC- 17 . 06 Liens A . This project is a " Public Works " under Chapter 255 , Florida Statutes . No merchant ' s liens may be filed against the OWNER . Any claimant may apply to the OWNER for a copy of this Contract . The claimant shall have a right of action against the CONTRACTOR for the amount due him . Such action shall not involve the OWNER in any expense . Claims against the CONTRACTOR are subject to timely prior notice to the CONTRACTOR as specified in Florida Statutes Section 255 . 05 . The CONTRACTOR shall insert the following paragraph in all subcontracts hereunder: " Notice : Claims for labor , materials and supplies are not assessable against Indian River County and are subiect to proper prior notice to ( CONTRACTOR' S Name ) and to ( CONTRACTOR Surety Company Name ) , pursuant to Chapter 255 of the Florida Statutes . This paragraph shall be inserted in every sub- 00800- 9 00800 - Supplementary Conditions 06-09 rev . doc 00800 9F :\Public Works\ENGINEERING DIVISION PROJECTS\0391 -27th Ave at 5th St SW\Admim\Contract Documents\00800 - Supplementary Conditions 06-09 rev .doc