2011-051 - Laserfiche WebLink

Home Browse Search

A . The Contractor agrees that whenever it becomes apparent from the current monthly schedule that delays to the critical path have resulted , and hence, that the contract completion date will not be met or when so directed by the Owner, he will take some or all of the following actions at no additional cost to the Owner, submitting to the Owner for approval , a written statement of the steps lie intends to take to remove or arrest the delay to the critical path in the approved schedule . l . Increased construction manpower in such quantities and crafts as will substantially eliminate, in the judgment of the Owner, the backlog of Work. 2 . Increase the number of working hours per shift, shifts per working days per week, the amount of construction equipment, or any combination of the foregoing, sufficiently to substantially eliminate, in the judgment of the Owner, the backlog of work. 3 . Reschedule activities to achieve maximum practical concurrency of accomplishment of activities, and comply with the revised schedule . 4 . Costs incurred by the Owner arising from such lengthening of hours , including furnishing of Inspectors , shall be the Contractor ' s responsibility and shall be deducted from monies due him . Failure of the Contractor to comply with the requirements of the Owner may be grounds for determination by the Owner that the Contractor is not proceeding at such rates as will insure completion within the specified time and may result in the termination of the right of the Contractor to continue the Work . 3 . 02 ADJUSTMENT OF CONTRACT SCHEDULE AND COMPLETION TIME A . If the Contractor desires to make changes in his method of operating which affect the approved schedule , he shall notify the Owner in writing stating what changes are proposed and the reason for the change . If the Owner approves these changes, the Contractor shall revise and submit for approval , without additional cost to the Owner, all of the affected portion of the schedule . The schedule shall be adjusted by the Contractor only after prior approval of his proposed changes by the Owner . B . Adjustments may consist of changing portions of the activity sequence and/or activity durations, division of approved activities, or other adjustments as may be approved by the Owner. The addition of extraneous , non -working activities and/or activities which add unapproved restraints to the schedule shall not be approved . C . If the completion of any activity , whether or not critical , falls more than 100 percent behind its approved duration , the Contractor shall submit for approval a schedule adjustment showing each such activity divided into two activities reflecting completed versus uncompleted work. D . Shop drawings which are not approved on the First submittal or within the scheduled time shall be immediately rescheduled , as well as pipelines and tanks which do not pass leak tests . E . The contract completion time will be adjusted only for causes specified in this contract. In the event the Contractor requests an extension of any contract completion date , he shall furnish such justification and supporting evidence as the Owner may deem necessary for determination as to whether the Contractor is entitled to an extension of time under the provisions of the contract. Owner will , after receipt of such justification and supporting evidence make findings of fact and will advise the Contractor in writing thereof. If the Owner finds that the Contractor is entitled to any extension of any contract 01311 - 3