2012-204A - Laserfiche WebLink

Home Browse Search

CONTRACTOR shall be allowed an extension of the Contract Times , directly attributable to any such suspension if CONTRACTOR makes a Claim for an extension as provided in paragraph 10 . 05 . CONTRACTOR shall not be allowed an adjustment of the Contract Price and CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other eco- nomic loss arising out of or resulting from such Work suspension . SC-15. 02 OWNER May .Terminate For Cause SCA 5 . 02 . A. 5 and SC- 15 . 02 .A. 6 Add the following new paragraphs immediately after paragraph GG15. 02. A . 4: 5 . CONTRACTOR's violation of Section 02225 — " Erosion Control and Treatment of Dewatering Water From the Construction Site . 6 . CONTRACTOR's failure to make payment to Subcontractors or Suppliers for materials or labor in accordance with the respective agreements between the CONTRACTOR and the Subcontractors or Suppliers . SC-15. 04 CONTRACTOR May Stop Work or Terminate SC- 15 . 04 Delete the following text from the first sentence of paragraph GG15. 04.A: SC- 15 . 04 Delete the following text from the second sentence of paragraph GC= 15. 04.A: 9F OWNER has failed fGF 30 days to pay GONTRAGTGR any sum f4nally deteFFAined to be SC-16 DISPUTE RESOLUTION SC-16. 02 Mediation SC- 16 Add the following new paragraph immediately after paragraph GC46. 010 SC- 16 . 02 Mediation A. OWNER and CONTRACTOR agree that they shall submit any and all unsettled Claims or counterclaims , disputes , or other matters in question between them arising out of or relating to the Contract Documents or the breach thereof, to mediation by a certified mediator of the 1 e Judicial Circuit in Indian River County unless delay in initiating arbitration would irrevocably prejudice one of the parties . The mediator of any dispute submitted to mediation under this agreement shall not serve as arbitrator of such dispute unless otherwise agreed . SC -17 Miscellaneous Add the following new paragraphs immediately after paragraph GC 17. 05: SC- 17 . 06 Liens A . This project is a " Public Works" under Chapter 255 , Florida Statutes . No merchant's liens may be filed against the OWNER . Any claimant may apply to the OWNER for a copy of this Contract . The claimant shall have a right of action 00800-9 00800 as Supplementary Conditions 06-09 rev. doc 00800 91P:1Public WorksIENGINEERING DIVISION PROJECTSN 102-Old Dixie Hwy Swk 8th St to SR 60-LAPWdmim\bid documentsVNaster Contract Documents100800 - Supplementary Conditions 06-09 rev.doc