2012-124A - Laserfiche WebLink

Home Browse Search

1. changes in the Work which are: (i) claimant believes it is entitled as a result of said event. ordered by OWNER pursuant to paragraph The opposing party shall submit any response to 10.01.A, (ii) required because of acceptance of ENGINEER and the claimant within 30 days after defective Work under paragraph 13.08.A or receipt of the claimant's last submittal (unless OWNER's correction of defective Work under ENGINEER allows additional time). paragraph 13.09, or (iii) agreed to by the parties; B. ENGINEER's Decision: ENGINEER will render a formal decision in writing within 30 days after 2. changes in the Contract Price or receipt of the last submittal of the claimant or the last Contract Times which are agreed to by the submittal of the opposing party, if any. ENGINEER's parties, including any undisputed sum or written decision on such Claim, dispute, or other amount of time for Work actually performed in matter will be final and binding upon OWNER and accordance with a Work Change Directive; and CONTRACTOR unless: 3. changes in the Contract Price or 1. an appeal from ENGINEER's Contract Times which embody the substance of decision is taken within the time limits and in any written decision rendered by ENGINEER accordance with the dispute resolution pursuant to paragraph 10.05; provided that, in procedures set forth in Article 16; or lieu of executing any such Change order, an appeal may be taken from any such decision in 2, if no such dispute resolution accordance with the provisions of the Contract procedures have been set forth in Article 16, a Documents and applicable Laws and Regula- written notice of intention to appeal from tions, but during any such appeal, ENGINEER's written decision is delivered by CONTRACTOR shall carry on the Work and OWNER or CONTRACTOR to the other and to adhere to the progress schedule as provided in ENGINEER within 30 days after the date of paragraph 6.18.A. such decision, and a formal proceeding is instituted by the appealing party in a forum of 10.04 Notification to Surety competent jurisdiction within 60 days after the date of such decision or within 60 days after A. If notice of any change affecting the general Substantial Completion, whichever is later scope of the Work or the provisions of the Contract (unless otherwise agreed in writing by OWNER Documents (including, but not limited to, Contract and CONTRACTOR), to exercise such rights or Price or Contract Times) is required by the provisions remedies as the appealing party may have with of any Bond to be given to a surety, the giving of any respect to such Claim, dispute, or other matter such notice will be CONTRACTOR's responsibility, in accordance with applicable Laws and The amount of each applicable Bond will be adjusted Regulations, to reflect the effect of any such change, C. If ENGINEER does not render a formal 10.05 Claims and Disputes decision in writing within the time stated in paragraph 10.053, a decision denying the Claim in its entirety A. Notice: Written notice stating the general shall be deemed to have been issued 31 days after nature of each Claim, dispute, or other matter shall be receipt of the last submittal of the claimant or the last delivered by the claimant to ENGINEER and the other submittal of the opposing party, if any. party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise D. No Claim for an adjustment in Contract Price thereto. Notice of the amount or extent of the Claim, or Contract Times (or Milestones) will be valid if not dispute, or other matter with supporting data shall be submitted in accordance with this paragraph 10.05. delivered to the ENGINEER and the other party to the Contract within 60 days after the start of such event (unless ENGINEER allows additional time for claimant ARTICLE 11 -COST OF THE WORK; CASH to submit additional or more accurate data in support ALLOWANCES; UNIT PRICE WORK of such Claim, dispute, or other matter). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of paragraph 12.01.8. 11.01 Cost of the Work A Claim for an adjustment in Contract Time shall be prepared in accordance with the provisions of A. Costs Included The term Cost of the Work paragraph 12.02.B. Each Claim shall be accom- means the sum of all costs necessarily incurred and panied by claimant's written statement that the adjust- paid by CONTRACTOR in the proper performance of ment claimed is the entire adjustment to which the the Work. When the value of any Work covered by a 00700-General Conditions REV 04-07.doc 00700-30 FAPublic Works1ENGINEERING DIVISION P ROJ ECTSX1 21 O-S a ndridge Driving Range Tee Renovation\Admimlbid documents100700_General Conditions REV 04-07.doc SmeadSoft Reprint Date:Monday,January 11,2016-09:22:09-OfficialDocuments:9069,Attachment Id 1,Page 97