|
F. Uncovering Work as provided in paragraph
<br />13.03.E shall be at CONTRACTOR's expense unless
<br />CONTRACTOR has given ENGINEER timely notice
<br />of CONTRACTOR's intention to cover the same and
<br />ENGINEER has not acted with reasonable prompt-
<br />ness in response to such notice.
<br />13.04 Uncovering Work
<br />A. If any Work is covered contrary to the written
<br />request of ENGINEER, it must, if requested by ENGI-
<br />NEER, be uncovered for ENGINEER's observation
<br />and replaced at CONTRACTOR's expense.
<br />B. If ENGINEER considers it necessary or
<br />advisable that covered Work be observed by ENGI-
<br />NEER or inspected or tested by others, CONTRAC-
<br />TOR, at ENGINEER's request, shall uncover, expose,
<br />or otherwise make available for observation, inspec-
<br />tion, or testing as ENGINEER may require, that
<br />portion of the Work in question, furnishing all neces-
<br />sary labor, material, and equipment. If it is found that
<br />such Work is defective, CONTRACTOR shall pay all
<br />Claims, costs, losses, and damages (including but not
<br />limited to all fees and charges of engineers, architects,
<br />attomeys, and other professionals and all court or
<br />arbitration or other dispute resolution costs) arising out
<br />of or relating to such uncovering, exposure, observa-
<br />tion, inspection, and testing, and of satisfactory
<br />replacement or reconstruction (including but not
<br />limited to all costs of repair or replacement of work of
<br />others); and OWNER shall be entitled to an
<br />appropriate decrease in the Contract Price. If the
<br />parties are unable to agree as to the amount thereof,
<br />OWNER may make a Claim therefor as provided in
<br />paragraph 10.05. If, however, such Work is not found
<br />to be defective, CONTRACTOR shall be allowed an
<br />increase in the Contract Price or an extension of the
<br />Contract Times (or Milestones), or both, directly
<br />attributable to such uncovering, exposure,
<br />observation, inspection, testing, replacement, and
<br />reconstruction. If the parties are unable to agree as to
<br />the amount or extent thereof, CONTRACTOR may
<br />make a Claim therefor as provided in paragraph
<br />10.05.
<br />13.05 OWNER May Stop the Work
<br />A. If the Work is defective, or CONTRACTOR
<br />fails to supply sufficient skilled workers or suitable
<br />however, this right of OWNER to stop the Work shall
<br />00700 - 36
<br />F:\Public Works\ENGINEERING DIVISION PROJECTS \1314 -107th Ave Milling_90th St to 94th St\Ad
<br />13.doc
<br />any of them.
<br />Work
<br />all defective
<br />or
<br />by ENGI-
<br />it with
<br />shall pay
<br />but
<br />engineers,
<br />and all
<br />costs)
<br />or removal
<br />of repair or
<br />Substantial
<br />13.06 Correction or Removal of Defective
<br />A. CONTRACTOR shall correct
<br />Work, whether or not fabricated, installed,
<br />completed, or, if the Work has been rejec`.ed
<br />NEER, remove it from the Project and replace
<br />Work that is not defective. CONTRACTOR
<br />all Claims, costs, losses, and damages (ncluding
<br />not limited to all fees and charges of
<br />architects, attorneys, and other professionals
<br />court or arbitration or other dispute resolution
<br />arising out of or relating to such correction
<br />(including but not limited to all costs
<br />replacement of work of others).
<br />13.07 Correction Period
<br />A. If within one after the date
<br />year of
<br />by Laws or Regulations by
<br />the terms of
<br />by the
<br />prescribed or
<br />any applicable special
<br />guarantee required
<br />Contract Documents, any Work is found
<br />to be
<br />to the land
<br />use by
<br />a:,
<br />defective, or if the repair damages
<br />of any
<br />or areas made available for CONTRACTOR's
<br />OWNER or by Laws Regulations
<br />permitted and
<br />defective, CONTRACTOR
<br />without cost
<br />shall promptly,
<br />instructions: (i) repair such defective land
<br />or areas, or
<br />defective
<br />it from
<br />(ii) correct such defective Work if the
<br />or,
<br />Work has been rejected by OWNER,
<br />remove
<br />defective, and (iii) satisfactorily
<br />or repair or
<br />Work, to the
<br />there
<br />comply
<br />or in an
<br />risk of
<br />defective
<br />the rejected
<br />costs,
<br />Milted to all
<br />attorneys,
<br />or
<br />or relating
<br />and
<br />all costs of
<br />I be paid by
<br />a particular
<br />correct
<br />remove and replace any damage to
<br />other
<br />work of others or other land
<br />or areas resulting
<br />from. If CONTRACTOR does
<br />not promptly
<br />with the terms of such instructions,
<br />emergency where delay would cause serious
<br />loss or damage, OWNER may have the
<br />Work corrected or repaired or may have
<br />Work removed and replaced, and all Claims,
<br />losses, and damages (including but not I
<br />fees and charges of engineers, architects,
<br />and other professionals and all court or arbitration
<br />other dispute resolution costs) arising out of
<br />to such correction or repair or such removal
<br />replacement (including but not limited to
<br />repair or replacement of work of others) wi
<br />CONTRACTOR.
<br />B. In special circumstances
<br />where
<br />item of equipment is in
<br />placed continuous
<br />service
<br />00700 - General Conditions
<br />min\bid documents\Master Contract Documents \00700 - General Conditions
<br />REV 5-10-13.doc
<br />REV 5-10-
<br />
|