2016-126 - Laserfiche WebLink

Home Browse Search

Contract#28730 Recipient shall use the District's Project Progress Report form,Attachment B. Recipient shall submit the Project Progress Reports to the District's Project Manager and District's Budget Coordinator within thirty(30)days after the closing date of each calendar quarter (March 31,June 30,September 30 and December 31). (b) Performance Monitoring.For as long as the Project is operational,the District shall have the right to inspect the operation of the Project during normal business hours upon reasonable prior notice. Recipient shall make available to the District any data that is requested pertaining to performance of the Project. 10. FAILURE TO COMPLETE PROJECT. (a) Should Recipient fail to complete the Project, Recipient shall refund to the District all of the funds provided to Recipient pursuant to this Agreement. However,the District,in its sole judgment and discretion, may determine that Recipient has failed to complete the Project due to circumstances that are beyond Recipient's control,or due to a good faith determination that the Project is no longer environmentally or economically feasible. In such event,the District may excuse Recipient from the obligation to return funds provided hereunder. If the Project has not been completed within thirty(30)days after the Completion Date, Recipient shall provide the District with notice regarding its intention as to completion of the Project.The parties shall discuss the status of the Project and may mutually agree to revise the time for Project completion or the scope of the Project. Failure to complete the Project within ninety(90)days after the Completion Date shall be deemed to constitute failure to complete the Project for the purposes of this provision. (b) In the event the Project constitutes a portion of the total functional project,this paragraph shall apply in the event the total functional project is not completed. In such event,the 90- day timeframe provided herein shall commence upon the date scheduled for completion of the total functional project at the'time of execution of this Agreement,unless extended by mutual agreement of the parties. Paragraphs 10(a)and 10(b)shall survive the termination or expiration of this Agreement. 11. TERMINATION. If Recipient materially fails to fulfill its obligations under this Agreement,including any specific milestones established herein,the District may provide Recipient written notice of the deficiency by forwarding a Notice to Cure,citing the specific nature of the breach. Recipient shall have thirty(30)days following receipt of the notice to cure the breach. If Recipient fails to cure the breach within the thirty(30)day period,the District shall issue a Termination for Default Notice terminating this Agreement without further notice. In such event,Recipient shall refund to the District all funds provided to Recipient pursuant to this Agreement within thirty(30)days of such termination. The District may also terminate this Agreement upon ten(10)days written notice in the event of any material misrepresentations in the Project Proposal. Delay or failure by the District to enforce any right, remedy or deadline hereunder shall not impair,or be deemed a waiver of,any such right,remedy or deadline,or impair the District's rights or remedies for any subsequent breach or continued breach of this Agreement. Page 6 of 14