Laserfiche WebLink
_I <br />� <br />Joe sorci, architect, assured them that all change orders and <br />responsibility for same could be discussed in great detail, but his <br />firm's commitment stands, and the construction manager is keeping <br />tally of all change orders. They are committed to timely <br />completion of the courthouse, and at the end, all parties will meet <br />and work out details as to who owes what and for what reason. <br />Mr. Glenewinkel advised that the building is supposed to be <br />finished the end of August and progress is being closely monitored. <br />He advised he and General Services Director Dean will review the <br />schedule versus actual progress, and make a judgment on whether the <br />contractor is going to make that date. <br />Commissioner Macht observed it was a 30 -day change from the <br />last report and the completion date keeps slipping. The building <br />was to have been completed last January, and now they're talking <br />about a shaky August date. <br />Administrator Chandler expressed concern about an end -of - <br />August completion date. He stated that he had reviewed each of the <br />changes and, in spite of shared frustration, there was no question <br />they were necessary. He went on to say the project manager <br />reviewed changes and made his recommendation. The changes are <br />well-documented and after completion of the project, they will be <br />reviewed and sorted out, and Administrator Chandler was confident <br />of complete recovery. <br />ON MOTION by Commissioner Macht, SECONDED by <br />Commissioner Eggert, the Board unanimously <br />approved the change orders listed in the memo, <br />as recommended by staff. <br />AMENDMENTS 3 AND 4 ON FILE IN THE <br />OFFICE OF THE CLERK TO THE BOARD <br />20 <br />