10/15/2019 - Laserfiche WebLink

Home Browse Search

COUNCIL Daniel Kolodny, Project Manager IRL Council 1235 Main Street Sebastian, Florida 32858 (772) 216-7148 E-mail: kolodnyAirlcouncil.org RECIPIENT Beth Powell, Assistant director Indian River County Parks and Conservation Resources 5500 77th Street Vero Beach, Florida 32967 (772) 226-1873 E-mail: bpowellRircgov.com (b) The Council's Project Manager shall have sole responsibility for transmitting instructions, receiving information, and communicating Council policies and decisions regarding all matters pertinent to performance of the Project. The Council's Project Manager may issue a Council Supplemental Instruction (CSI) form, Attachment C, to authorize minor changes in the Project that the parties agree are not inconsistent with the purpose of the Project, do not affect the Council cost -share or Completion Date, or otherwise significantly modify the terms of the Agreement. 10. PROGRESS REPORTS AND PERFORMANCE MONITORING (a) Progress Reports. Recipient shall provide to the Council Project update/status reports as provided in the Statement of Work. Reports will provide detail on progress of the Project and outline any potential issues affecting completion or the overall schedule. Reports may be submitted in any form agreed to by Council's Project Manager and Recipient but must include Council's Quarterly Report Summary Cover Sheet, and may include emails, memos, and letters. (b) Performance Monitoring. For as long as the Project is operational, the Council shall have the right to inspect the operation of the Project during normal business hours upon reasonable prior notice. Recipient shall make available to the Council any data that is requested pertaining to performance of the Project. 11. FAILURE TO COMPLETE PROJECT. (a) Should Recipient fail to complete the Project, Recipient shall refund to the Council all of the funds provided to Recipient pursuant to this Agreement. However, the Council, in its sole judgment and .discretion, may determine that Recipient has failed to complete the Project due to circumstances that are beyond Recipient's control, or due to a good faith determination that the Project is no longer environmentally or economically feasible. In such event, the Council may excuse Recipient from the obligation to return funds provided hereunder. If the Project has not been completed within 30 days after the Completion Date, Recipient shall provide the Council with notice regarding its intention as to completion of the Project. The parties shall discuss the status of the Project and may mutually agree to revise the Completion Date or the scope of the Project. Failure to complete the Project within 90 days after the Completion Date shall be deemed to constitute failure to complete the Project for the purposes of this provision. 24