2022-052 - Laserfiche WebLink

Home Browse Search

claimant within 30 days after receipt of the claimant's last submittal (unless ENGINEER allows additional time). B. ENGINEER's Decision: ENGINEER will render a formal decision in writing within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any. ENGINEER's written decision on such Claim, dispute, or other matter will be final and binding upon OWNER and CONTRACTOR unless: 1. an appeal from ENGINEER's decision is taken within the time limits and •n accordance with the dispute resolution procedures set forth in Article 16; or 2. if no such dispute resolution procedures have been set forth in Article 16, a written notice of intention to appeal from ENGINEER's written decision is delivered by OWNER or CONTRACTOR to the other and to ENGINEER within 30 days after the date of such decision, and a formal proceeding is instituted by the appealing party in a forum of competent jurisdiction within 60 days after the date of such decision or within 60 days after Substantial Completion, whichever is later (unless otherwise agreed in writing by OWNER and CONTRACTOR), to exercise such rights or remedies as the appealing party may have w4h respect to such Claim, dispute, or other matter in accordance with applicable Laws and Regulations. C. If ENGINEER does not render a formal decision in writing within the time stated in ;paragraph 10.05.13, a decision denying the Claim in its entirety shall be deemed to have been issued 31 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any, D. No Claim for an adjustment in Contract Price or Contract Times (or Milestones) will be valid if not submitted in accordance with this paragraph 10.05. ARTICLE 11 - COST OF THE WORK; CASH ALLOWANCES; UNIT PRICE WORK 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sum of all costs necessarily incurred and paid by CONTRACTOR in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to CONTRACTOR will be only those additional or incremental costs required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by OWNER, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall include only the following items, and shall not include any of the costs itemized in para- graph 11.01.6. 2. Cost of all materials and equipment furnished and incorporated in the Work, includ- ing costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts shall accrue to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with which to make payments, in which case the cash discounts shall accrue to OWNER. All trade discounts, rebates and refunds and returns from sale of surplus materials and equipment shall accrue to OWNER, and CONTRACTOR shall make provisions so that they may be obtained. 3. Payments made by CONTRACTOR to Subcontractors for Work performed by Subcontractors. If required by OWNER, COW TRACTOR shall obtain competitive bids from subcontractors acceptable to OWNER and CONTRACTOR and shall deliver such bids to OWNER, who will then determine, with the advice of ENGINEER, which bids, if any, will be acceptable. If any subcontract provides that the 00700 - General Conditions 00700-31 FAPublic Works\ENGINEERING DIVISION PROJECTS\2020 JRTC Ticket Office P,enovations\1-Adorn\Bids\Bid Documents\Rebid\00700 - General Conditions.doc