1999-009 - Laserfiche WebLink

Home Browse Search

Cl 40 11 of Unit Price Work times the estimated quantity of each items as indicated in the Agreement. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by CONTRACTOR will be made by ENGINEER in accordance with paragraph 9.10. 11.10 Each unit price will be deemed to include an amount considered by CONTRACTOR to be adequate to cover CONTRACTOR's overhead and profit for each separately identified item. 11.11 Where the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and significantly from the estimated quantity of such item indicated in the Agreement and there is no corresponding adjustment with respect to any other items of Wo , -K and if CONTRACTOR believes that CONTRACTOR has incurred additional expense as a result thereof, CONTRACTOR may make a claim for an increase in the Contract Price in accordance with Article 11 if the parties are unable to agree as to the amount of any such increase. CLE 12 - CHANGE OF CONTRACT T 12.1 The Contract Time may only be changed by a change order or a written amendment. any claim for an extension or shortening of the contract time shall be based on written notice delivered by the party making claim to the other party and to ENGINEER promptly (but in no event later than thirty (30) days) after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with suppoi+ng data shall 'we delivered within sixty (BO) days after such occurrence (unless ENGINEER allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time shall be determined by ENGINEER in accordance with paragraph 9.11 if OWNER and CONTRACTOR cannot otherwise agree. No claim for an adjustment in the Contract Time will be valid if not submitted in accordance with the requirements of this paragraph 12.1. 12..2 The Contract Time will be extended in an amount equal to time lost due to delays beyond the control of CONTRACTOR if a claim is made therefor as provided in paragraph 12.1. Such delays shall include, but not be limited to, acts or neglect by OWNER or others performing additional work as contemplated by Article i, or to fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God. Delays described in this paragraph shall not entitle the CONTRACTOR to any additional compensation. The sole remedy of the CON -1 RAC; T OR shaii be an extension ui' ilmu ubiair leu in � accordance With Article 12. 12.3 All time limits stated in the Contract Documents are of the essence of the Agreement. The provisions of this Article 12 shall not exclude recovery for damages (inrl-+ding but not limited to fees and charges of engineers, architects, attorrweys and other professionals and court and arbitration costs) for delay by either party. GENERAL CONDiTTOMS 69