Laserfiche WebLink
40 <br />3.2 Liquidated Damages.. OWNER and CONTRACTOR recognize that <br />time is of the essericp of this Agreement and that OWNER will <br />suffer financial loss if the work is not completed within the <br />times specified in Paragraph 3.1 above, plus any extensions <br />thereof allowed in accordance with Article 12 of the General <br />Conditions. They also recognize the delays, expense and <br />f difficulties involved in proving in a legal or arbitration <br />proceeding the actual loss suffered by OWNER if the work is <br />not completed on time. Accordingly, instead of requiring any <br />such proof, OWNER and CONTRACTOR agree that as liquidated <br />damages for delay (but not as a penalty) CONTRACTOR shall pay <br />OWNER three hundred dollars ($300.00) for each day that <br />expires after the time specified in Paragraph 3.1 for <br />Substantial Completion, if CONTRACTOR shall neglect, refuse or <br />fail to complete the remaining work within the Contract Time <br />or any proper extension thereof granted by OWNER, CONTRACTOR <br />shall pay OWNER three hundred dollars ($300.00) for each day <br />that expires after the time specified in Paragraph 3.1 for <br />completion and readiness for final payment. <br />Article 4. CONTRACT PRICE. <br />4.1 OWNER shall pay CONTRACTOR for completion of the work in <br />accordance with the Contract Documents in current funds in the <br />amount of $40,948.94. <br />Article 5. PAYMENT PROCEDURES. <br />CONTRACTOR shall submit Applications for Payment in accordance <br />with Article 14 of the General Conditions. Applications for <br />Payment will be processed by ENGINEER as provided in the <br />General Conditions. <br />5.1 Progress Payments. OWNER shall make progress payments on <br />account of the Contract Price on the basis of CONTRACTOR"s <br />Applications for Payment as recommended by ENGINEER, on or <br />about the 30th day of each month during construction as <br />provided below. All progress payments will be on the basis of <br />the progress of the work measured by the scnedule of values <br />established in Paragraph 2.9 of the General Conditions (and in <br />the case of Unit Price Work based on the number of units <br />completed), or, in the event there is no schedule of values, <br />as provided in the General Requirements. <br />FA -3 <br />