1999-338A - Laserfiche WebLink

Home Browse Search

40 r1q SUPPLEMENTARY CONDITIONS TO GENERAL, CONDITIONS I. A. lamdttat These Supplementary Conditions amend or supplement the General Conditions (GC) of the Construction Contract and other provisions of the Contract Documents as indicated below. All provisions which are not so amended or supplemented remain in full force and effect. No fbrfeiture due to delay shall be made because of any delays in the completion of the work due to unforeseeable causes beyond the control and widiout the fault or negligence of the CONTRACTOR {including but not restrided to Acts of God or of the public enemy, acts of the govemm ait, acts ofthe OWNER, or acts of another CONTRACTOR hi the performance of a contract with the OWNER, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes and unusually severe weather or delays of subcontractors due to such causes or delays caused by the failure of the OWNER or the owner of a utility to provide for removal or relocation of existing utility facilities). Any such delays shall not entitle die CONTRACTOR to any additional compensation. The sole remedy of the CONTRACTOR shall be an extension of time obtained in accordance with this section. 2. The CONTRACTOR shall, within five days from the beginning of any such delay, notify the OWNER in writing of the cause of delay, whereupon the OWNER shall ascertain tie facts and extent of the delay and extend the time for completing the work if, in his judgment, the fundings of fact justify such an extension, and his findings of facts thereon shall be final and conclusive. r C. Permits 1. As set forth in paragraph 6. 15 of the GC, the OWNER has obtained the fallowing ,permits: a. IRC - Land Clearing, and Tree Removal b. FDOT Driveway Connection C. FDEP Coastal Systems d. FDEP Stermwater Management 2. The CONTRACTOR shall obtain and pay for all other required permits and licenses. The COFACTOR shall provide copies of these permits to die OWNER and Engineer and shall comply with all conditions contained in the permits at no extra cost to the OWNER. 3. The CONTRACTOR shall be familiar with all permit requirements during construction and shall be responsible for complying with these requirements. The cost of this effort shall be included in die pay item which the work is most closely associated with. h. if dewatering is required, tie CONTRACTOR shall coordinate with the St. Johns River Water Management District regarding the applicable rules an(] regulations. If a dewatering permit is required, the contractor shall prepare an application to die District and pay any fee, 1) The CONTRACTOR is assumed to be familiar with and shall comply with all Federal, State and Local laws, ordinances, rides, codes, and regulations that may affect the work. Ignorance on the part I SUPPLENIENiARY COMMONS SC - 1